The URL can be used to link to this page

Home My WebLink About13 Award of Cont - Dev Svcs Lobby design-buildSTAFF REPORT CITY OF PALM DESERT PUBLIC WORKS DEPARTMENT MEETING DATE: November 18, 2021 PREPARED BY: Chris Gerry, Project Manager REQUEST: Authorize the award of Contract No. C42400 for the design -build of the Development Services Lobby Renovations to Tilden -Coil Constructors, Inc. of Riverside, California, in the amount of $950,000 (Project No. 727- 20) Recommendation By Minute Motion: 1. Award Contract No. C42400 for the design -build of the Development Services Lobby Renovations to Tilden -Coil Constructors, Inc. of Riverside, California, in the amount of $950,000; 2. Authorize the Finance Director to transfer $100,000 from the Council Chambers Improvements (Account No. 4004161-4400100) to the Development Services Lobby Renovations (Account No. 4504161-4400100); 3. Authorize the Director of Finance to set aside contingency for unforeseen conditions in the amount of $100,000; 4. Authorize the City Manager or designee to review and approve written change order requests for unanticipated conditions, per Section 3.30.170 of the Palm Desert Municipal Code; and 5. Authorize the City Manager or his designee to execute the agreement and any documents necessary to effectuate the actions taken herewith. Funds are available in Account No. 4504161-4400100 (Building Maintenance). Strategic Plan The project advances the City's Strategic Plan goal of streamlining the permitting process. Background In the Fiscal Year 2020-21 budget, the City Council appropriated $1,000,000 for improvements to the Development Services lobby and adjacent administrative areas. The purpose of the project is to renovate the lobby and surrounding area of the Development November 18, 2021 - Staff Report Development Services Lobby Renovations Page 2 of 4 Services Department to enhance the customer experience, increase functionality, and promote a safe environment. The proposed renovation also complements the new Palm Desert Permit Center, which provides an efficient and convenient one -stop shop for residential and commercial permit needs. On June 24, 2021, the City Council amended the professional services agreement with Holt Architecture, Inc. in an amount not -to -exceed $50,000 for support services to complete design -build specifications and provide support to the City for bidding and construction. Design -Build Project Delivery City staff typically implements the design -bid -build process to construct capital improvement projects. This traditional project delivery method is linear; that is, projects are chronologically designed by an architect and/or engineer, bid for construction to contractors, and constructed according to the respective plans and specifications. Note that in the design -bid -build process the City contracts separately for design and construction services. City staff is proposing the design -build process for this project. Design -build is a method of project delivery in which one entity — the design -build team — works under a single contract with the City to provide design and construction services. Some of the benefits to the design - build process typically include faster project delivery due to collaborative project management (i.e., faster construction with fewer issues); cost savings due to efficiency and innovation; and better -quality construction due to focusing on project needs and not necessarily just minimum design standards. Furthermore, the design -build process creates a singular responsibility for accountability pertaining to cost, schedule, and performance. Preliminary Scope of Work As previously mentioned, the purpose of the project is to renovate the lobby and surrounding area of the Development Services Department to enhance the customer experience, increase functionality, and promote a safe environment. Note the scope of work is subject to revisions based upon collaboration with the design -build team following contract award. Notwithstanding, the preliminary scope of work generally includes: • Lobby Area: Removing the sculpture garden; installing a new concierge station, kiosk, and seating area; installing new reinforced counters and service stations; adding new flooring; painting (if necessary); and replacing lighting and controls. • Development Services Conference Room: Adding new flooring; painting (if necessary); installing furniture for storage; and replacing lighting and controls. • Development Services Conference Room Corridor: Adding new flooring; painting (if necessary); removing the alcove adjacent to the exterior automatic sliding door; and replacing lighting and controls. November 18, 2021 - Staff Report Development Services Lobby Renovations Page 3 of 4 • Building and Safety Area: Adding new flooring; installing new office furniture systems; painting (if necessary); removing the existing counter and an interior door between offices; and replacing lighting and controls. • Planning and Code Compliance Area: Removing and replacing existing counters; installing new workstations and furniture adjacent to new counters; painting (if necessary); constructing new offices; installing appropriate furniture; and replacing lighting and controls. • Americans With Disabilities (ADA) Improvements: Constructing required ADA improvements within the facility. The preliminary schematic can be found as Attachment A. Request For Proposal A request for proposal (RFP) for design -build services of the Development Services Lobby Renovation was advertised in PlanetBids on September 16, 2021. City staff hosted a virtual pre -proposal meeting on September 23, 2021, and two in -person site visits for interested bidders on September 28-29, 2021. Proposals were due October 13, 2021, and the City subsequently received one proposal from Tilden -Coil Constructors, Inc. Design -Build Team Tilden -Coil Constructors, Inc. and STK Architecture, Inc. (Design -Build Team) are uniquely qualified in programming, design, and full -service construction of municipal administrative projects throughout Southern California, including the Coachella Valley. While the Design - Build Team has its headquarters in Riverside, they have office space in Palm Desert as well. The proposal of the Design -Build Team can be found in the design -build agreement (Attachment B) as Attachment 1-1. Preliminary Schedule The Design -Build Team submitted a preliminary schedule accounting for the project budget and supply chain -related material delays being experienced in the construction industry. The initial schedule indicates final design and permitting by March 2021; bidding and contracting by April 2021; and construction by August 2021. City staff and the Design -Build Team have already held multiple discussions regarding reducing material delays within the scope of work and shortening the project completion timeline. Therefore, City staff and the Design -Build Team anticipate reducing the total project schedule accordingly. The preliminary schedule of the project can be found within the proposal in the design -build agreement (Attachment B) as Attachment 1-1. November 18, 2021 - Staff Report Development Services Lobby Renovations Page 4 of 4 Fiscal Analysis The fiscal impact associated with this action is the cost of the design, construction and any potential change orders from the contingency noted below. Also as an added action herein, the City recently received bids for the Council Chambers Improvements, and is recommending a construction contract award recommendation under a separate staff report which is lower than the project budget. This project award is within the project budget, however, City staff recommends transferring excess funds from the Council Chambers Improvement project to the Development Services Lobby Renovations to bolster the budget allowing for a fair contingency, particularly the required ADA improvements. The Development Services Lobby Renovations are summarized in the following table. Project Element Vendor Funding Source Amount Architectural Support for Bidding & Construction Construction Contingency Design -Build Contract Tilden -Coil Constructors, Inc. Holt Architecture, Inc. Building Maintenance Fund $50,000 Building Maintenance Fund $100,000 $950,000 Total: $1,100,000 Building Maintenance Fund Bolded amounts are the subject of this request. Funds are available in Account No. 4504161-4400100 (Building Maintenance). LEGAL REVIEW DEPT. REVIEW RWH Robert W. Hargreaves City Attorney .Andy Firestine Andy Firestine Assistant City Manager City Manager: L. Todd Hileman: Attachments A. Preliminary Schematic B. Design -Build Agreement FINANCIAL REVIEW Janet Moore Director of Finance L. Todd Hilevu.aw ASSISTANT CITY MANAGER .Andy Firestine Andy Firestine Assistant City Manager CITY COUNCIL ACTION APPROVED Ni DENIED RECEIVED . OTHER MEETING DATE 11 lc?) 202t AYES:-r4RV i K,TOYIG)ihA►1NeS nde, intan►I on -Kell y NOES: lv o e- ABSENT: One ABSTAIN: N Ole VERIFIED BY: N l l S rS Original on File with City Clerk's Office SCOPE CtriNvRrr Aitalt »t BUILDING & SAFETY SCOPE OF WORK AREA #1 LOBBY ■ 0 0 0 to f0 21 0 co 0 2 v To 0 0 0 V C 0 a 0 N cp om = N co 4, N N � CON 1 BLDG. INSP. BLDG. INSP. BLDG. INSP. DIR. BLDG & SAFETY BLDG. INSP. BLDG. INSP. SCOPE Of- WORK AREA #4 CORRIDOR (;l:(.)1-r, i.IIin dul„Ir';,l1L ";I.::%ik *:�:1 CONFERENCE ROOM SCOPE OF WORK AREA #3 1 PLANNING & CODE COMPLIANCE PLANS EXAM OFFICE ASST. Tilt(nlnllwt111111 ►tnititntin11111 iintnnninnnniltin11111I i ifitTIriWflti r SUP. PLAN EXAM ADMIN SEC. No work this area 111111111111111111111111 New Walls to match existing in Orange (typical) 1141111Nif111t1111111ili atfulWIMkHIIIIIIIIURIlllll11tfllllilti1111111111111111111 CONFERENCE ROOM _ re _ ASSOC. PLANNER ASST. PLANNER PRINCL. PLANNER 1 DIR. OF COMM. DEV. 9 Nis Sin len R 11111111111111111111111111 M 1111 11111111111111 11111111111111111111 fi CONFERENCE ROOM Area for (2) to (4) Workstations 12 5" MGMT. SPECT. 5,4. 11111111111,1111111111 r 3'-0- ■ ■ ■ ■ V • 5--6. IIIIIII�IIIlilil LOBBY Kiosk or Seating Area Options Service Counters Concierge Station lllllllllllllllll MGMT. SPECT. MGMT. = ANALYST j 10111111111111111111111111111 ■ ■ ■ Video Wall or Kiosk location options II ILL 5'-ti" .,VI`..I .I •I CODE COMP. OFFICER J CODE COMP. OFFICER r CODE COMP. OFFICER L CLOSET Area tor (2) Workstations r 27.-T CODE COMP. OFFICER NOT IN SCOPE New Office n CODE COMP. TECH. New Office c7 MGMT. ANALYST New Office MGMT. SPEC. PUBLIC ARTS TECH. CODE COMP. SUP. )))1O)a ta MED ittttNiftflt}tH}Itf4tffMif1111f1111H1HHifilfllltillltiH}iIII11fiH11}1llllffilfltl}H11iiH}filHlfl1111}1Hlfifil}I11}Illltffl}iiIHif1111114NIf1111fl1111111tiH1tHt}t}tiltl}Htr REFER TO THE SCOPE OF WORK FOR ADDITIONAL INFORMATION. CLIENT City of Palm Desert 73510 Fred Waring Dr Palm Desert, CA 92260 COMPUTER SERVER ROOM FACILITIES MANAGER TRAFFIC CONTROL CENTER FIRE BREAK ROOM - 4 DEP. FIRE MARSHAL FIRE OFFICES P.W. CONFERENCE ROOM MAINT. TECH. EMERG. SERV. COORD. 10.559.27 st LAND. INSP. LAND. INSP. LAND. INSP. ENGINEER( NG ASSISTANT LANDSCAPE SUPERVISOR EMPTY CUBICLE WORK AREA NOT IN SCOPE MAINT. TECH. MGMT. ANALYST P.W. INSP. P.W. INSP. P.W. INSP. P.W. INSP. MGMT. ANALYST PROJECT MANAGER NOT IN SCOPE SR. MANAGEMENT ANLYST 1 0' 6' DEVELOPMENT SERVICES LOBBY SPACE PLANNING ACCOUNTING TECHNICIAN 16' DIR. OF PUBLIC WORKS CITY ENGINEER PROJECT MANAGER E PROJECT MANAGER 114. SURVEY EQUIPMENT S—ORAGE ROOM ASSISTANT CITY MANAGER 36' Ne E SD-100 113HOLT Date: 11/02/21 ARCHITECTURE CITY OF PALM DESERT DESIGN/BUILD CONTRACT FOR DEVELOPMENT SERVICES LOBBY RENOVATIONS Contract No, C42400 City of Palm Desert Public Works Department 73-510 Fred Waring Drive Palm Desert, CA 92260 1 DESIGN -BUILD CONTRACT BETWEEN CITY OF PALM DESERT AND TILDEN-COIL CONSTRUCTORS, INC. FOR THE DEVELOPMENT SERVICES LOBBY RENOVATIONS This Design -Build Contract ("Contract") is made and entered into this day of , 2021 by and between the CITY OF PALM DESERT, (hereinafter referred to as "Agency") and TILDEN-COIL CONSTRUCTORS, INC. (hereinafter collectively referred to as "Design -Build Entity" or "DBE"). Agency and DBE are sometimes individually referred to as "Party" and collectively as "Parties." RECITALS A. Agency desires to enter a single project for the turnkey design and construction for the Development Services Lobby Renovations ("Project") as set forth in this Contract. Because of the unique nature of the Project, Agency desires to engage a single design -build entity to engineer and implement the Project. B. The DBE submitted a Proposal for the Project, which was selected as providing the best -value for the Project. C. DBE desires to perform and assume responsibility for the provision of the design and construction services, and such other services as required by the Agency on the terms and conditions set forth in this Contract and DBE represents that it is experienced in providing professional planning, design, and construction services to public entities, is appropriately licensed in the State of California to perform such services, and is familiar with the Scope of Work. TERMS 1. Incorporation of Contract Documents. The above referenced recitals are true and correct and are incorporated into this Contract by this reference. This Contract includes and hereby incorporates in full by reference the following Contract Documents, including all exhibits, drawings, specifications and documents therein, and attachments and addenda thereto: (a) Design -Build Contract (b) Attachment 1 to this Contract — Scope of Services (c) Attachment 1-1 to this Contract — Proposal (d) Attachment 2 to this Contract - General Conditions (e) Attachment 3 to this Contract — Special Conditions (f) Attachment 4 to this Contract — Performance Bond (g) Attachment 5 to this Contract — Payment Bond (h) Attachment 6 to this Contract — Rate Schedule (i) Attachment 7 to this Contract — Workers' Compensation Certification (j) Request for Proposal ("RFP") and all addenda, attachments and appendices (k) Agency approved Change Orders (I) Completed and approved Construction Documents in accordance with the General Conditions 2 2. The DBE's Basic Obligations; Compensation. The DBE promises and agrees, at its own cost and expense, to furnish to the Agency all design and construction services, labor, materials, tools, equipment, services, and incidental and customary work necessary to fully and adequately complete the Project as described in the Contract Documents (hereinafter the "Scope of Work" of "Work"). Agency shall pay to the DBE as full compensation for the performance of the Contract, subject to any additions or deductions as provided in the Contract Documents, and including all applicable taxes and costs, the sum of Nine Hundred Fifty Thousand Dollars ($950,000.00) ("Contract Price"). Payment shall be made as set forth in the General Conditions. Unless otherwise stated in the Contract Documents, the Contract Price shall pay for all costs and expenses required to design and construct the Project. 3. Standard of Care. The DBE's performance shall be consistent with the standards set forth in the Contract and the General Conditions. The DBE warrants to Agency that all Design Work will be performed in accordance with the highest professional standards and degree of care applicable to those design professionals who specialize in designing and providing services for projects of the type, scope, quality and complexity of the Project utilizing the Design -Build contracting mode. The DBE warrants to Agency that all labor, materials, equipment and furnishings used in, or incorporated into, the Construction Work will be of good quality, new (unless otherwise required or permitted by the Contract Documents), and all work will be free of liens, claims and security interests of third parties; that the work will be of the highest quality and free from defects and that all work will conform with the requirements of the Contract Documents. The DBE shall supervise, inspect, and direct the Project competently and efficiently, devoting such attention thereto and applying such skills and expertise as may be necessary to perform the Project in accordance with the Contract Documents. The DBE shall be solely responsible for the means, methods, techniques, sequences, and procedures of design and construction of the Project. DBE shall perform, at its own cost and expense and without reimbursement from the Agency, any services necessary to correct errors or omissions which are caused by the DBE's failure to comply with the standard of care provided for herein. 4. Period of Performance: Liquidated Damages. Time is of the essence. The DBE guarantees that it shall perform and complete all Work required by the Contract Documents for completion by the Project Completion Date. The Project Completion Date shall be up to One Hundred Twenty (120) calendar days from the commencement date stated in the Notice to Proceed with Construction. The DBE agrees that it shall be liable to the Agency for liquidated damages in an amount of Two Thousand Dollars ($2,000.00) per day for each and every calendar day beyond the Project Completion Date that completion of the Project has not been achieved at the Project Site. If not completed by the Project Completion Date, it is understood that the Agency will suffer damage, and that it is and will be difficult and/or impossible to ascertain and determine the actual damage which the Agency will sustain in the event of and by reason of the DBE's failure to complete the work, and therefore the DBE shall pay to the Agency the stipulated sum as fixed and liquidated damages and not as a penalty. Any money due or to become due the DBE may be retained to cover liquidated damages. 3 5. Approval of Design; Commencement of Construction. (a) The Scope of Work shall consist of two phases: the Construction Document Phase and the Construction Phase. The Agency shall issue a Notice to Proceed for each Phase. (b) The DBE shall commence the Construction Document Phase after receipt of Agency's Notice to Proceed and complete the Construction Document Phase work within One Hundred Twenty (120) calendar days of the Notice to Proceed date. The design shall consist of preparation of the Construction Documents as set forth in the General Conditions. The Bridging Documents may be utilized to assist in scoping the Project, but responsibility for the design shall rest solely with the DBE. (c) DBE shall submit the following to Agency for approval: (i) Schematic Design; (ii) 50% Construction Documents; and (iii) 100% Construction Documents. (d) The Agency's review and approval of the design shall not relieve the DBE from its responsibilities under the Contract. Such review shall not be deemed an approval or waiver by the Agency of any deviation from, or of the DBE's failure to comply with, any provision or requirement of the Contract Documents, unless such deviation or failure has been identified as such in writing in the Document submitted by the DBE and approved by the Agency. The Agency Representative, or an Agency Engineer designated to review and approve Construction Documents, shall be authorized to approve the Construction Documents and any amendments or changes to the design. (e) The Contract Schedule shall indicate the time for the Agency to review the proposed Construction Documents and shall provide a reasonable time for review of same, not less than ten (10) days. DBE shall not be entitled to damages, liquidated or otherwise, for any delays during the Construction Document Phase. (f) DBE shall not commence construction until the Agency approves the completed Construction Documents and issues a Notice to Proceed with Construction. DBE may request a Notice to Proceed with Construction prior to completion of the 100% Construction Documents, and Agency may issue same, provided that DBE shall not construct any portion of the Project until the design of such portion has been approved. The Project Completion Date shall run from the Notice to Proceed with Construction even if issued prior to completion of the 100% Construction Documents. 6. Agency's Representative. The Agency hereby designates Assistant City Manager, Andy Firestine, or his or her designee, as the person to act as its representative for the performance of this Contract ("Agency's Representative"). The Agency's Representative shall be authorized to act as liaison between Agency and the DBE in the administration of this Contract and all work on the Project. The Agency's Representative shall have the power to act on behalf of the Agency for all purposes under this Contract, including for the purpose of approving the design. Agency may 4 designate new and/or different individuals to act as Agency's Representative from time to time upon written notice to the DBE. 7. DBE's Representative. The DBE hereby designates Project Executive, Marty Greenwood, or his or her designee, to act as its representative for the performance of this Contract ("DBE's Representative"). DBE's Representative shall have full authority to represent and act on behalf of the DBE for all purposes under this Contract. DBE's Representative shall supervise and direct all work on the Project, using his best skill and attention, and shall be responsible for all means, methods, techniques, sequences and procedures and for the satisfactory coordination of all portions of the work pursuant to this Contract. 8. DBE's Contractor's License and Registration. The DBE shall have only appropriately licensed contractors performing work on the Project as required by the Business and Professions Code. The DBE (License No. CA#208556) shall act as the licensed contractor for the Project. DBE shall perform all services required under the Contract Documents in a skillful and competent manner, consistent with the standards generally recognized as being employed by professionals qualified to perform such services in the same discipline in the State of California, and the DBE shall be fully responsible to the Agency for any damages and/or delays to the Project as specified in the Contract. The licensed contractor shall be registered with the Department of Industrial Relations to perform public work (DIR Registration No. 1000000518). 9. DBE's Design Professional. The DBE shall name a specific person to act as the Design Professional as described in the General Conditions, subject to the approval of the Agency. The DBE hereby designates Camille Pulliam Acton (License No.: CA#C24181) to act as the Design Professional for the Project. DBE's Design Professional shall perform all services required under the Contract Documents in a skillful and competent manner, consistent with the standards generally recognized as being employed by professionals qualified to perform such services in the same discipline in the State of California, and the DBE shall be fully responsible to the Agency for any damages and/or delays to the Project as specified in the indemnification provisions of the Contract. Any change in the Design Professional shall be subject to the Agency's prior written approval, which approval shall not be unreasonably withheld. The new Design Professional shall be of at least equal competence as the prior Design Professional. In the event that Agency and DBE cannot agree as to the substitution of a new Design Professional, the Agency shall be entitled to terminate this Contract as described in the General Conditions. 10. Authority of Signatories. The persons executing this Contract on behalf of their respective Parties represent and warrant that they have the authority to do so under law and from their respective Parties. [SIGNATURES CONTINUED ON NEXT PAGE] 5 Entered into as of the Effective Date first above written, the Parties hereby execute this Design -Build Contract, as follows: CITY OF PALM DESERT TILDEN-COIL CONSTRUCTORS, INC. By: By: L. TODD HILEMAN, CITY MANAGER ATTEST: By: NORMA ALLEY, CITY CLERK Its: Printed Name: By: Its: Printed Name: APPROVED AS TO FORM: Contractor's License Number By: DIR Registration Number BEST BEST & KRIEGER LLP 6 ATTACHMENT 1 DRAFT SCOPE OF SERVICES 1. Lobby Area A. Demolition 1. Central Sculpture Garden 2. Tile Flooring 3. Counters B. Relocation 1. Defibrillator 2. Fire Extinguisher Cabinet C. New Cabinetry and Casework 1. Material Similar to New Council Chamber Dias 2. Customer Service Stations and Glass Dividers on New Countertops 3. ADA Customer Service Stations on New Countertops 4. Reinforced Counters for Security D. New Metal -Stud, Gypsum -Board Walls with Sound -Insulation and Access - Control Door and Frames E. New Lighting/Controls F Furniture, Furnishings and Equipment 1. Lobby Seating 2. Concierge Station 3. Kiosk G. Finishes 1. Commercial Grade Flooring and Base 2. Paint in Selection Locations 3. Acoustical Wall Panels 4. Keep/Protect Exposed Masonry 2. Building and Safety A. Demolition 1. Building and Safety and Planning Counters 2. Interior Door Between Offices Conference Room and Office 3. Exterior Door B. Furniture, Furnishings and Equipment 1. Office Furniture Systems to Accommodate Six (6) Staff Members C. Finishes 1. Commercial Grade Carpet and Base 2. Paint in Select Locations 3. Planning and Code Compliance A. Demolition 1. Code Compliance/Licensing Counter B. Construct New Offices (3) with Hard Walls C. Construct Doorway between New Offices and adjacent Existing Office D. New Lighting/Controls E. Furniture, Furnishings and Equipment Al-7 1. Two (2) Workstations and Office Furniture adjacent to the New Code Compliance Counter 2. Two (2) to Four (4) Workstations and Office Furniture adjacent to the New Planning Counter 3. Three (3) Office Furniture and Chairs in the New Offices (Hard Wall) 4. Office Furniture and Chairs for Plan Production Area F. Finishes 1. New Paint in Select Locations 4. Conference Room Corridor A. Demolition 1. Alcove (Adjacent to Exterior Door) B. New Wall to Match Existing (Adjacent to Exterior Door) C. New Lighting/Controls D. Finishes 1. Commercial Grade Flooring and Base 2. Paint in Select Locations 5. Conference Room A. New Lighting/Controls B. Furniture, Furnishings and Equipment 1. Furniture for Storage and Supplies C. Finishes 1. Commercial Grade Flooring and Base 2. Paint 6. Building Official/Code Required Improvements A. Title 24 Lighting/HVAC Improvements B. Fire Sprinkler C. Fire Alarm D. Americans With Disabilities Act (ADA) Compliance according to the City's Accessibility Report (10/06/2018) 7. Low -Voltage Systems A. CCTV (Lobby Area) B. Access Control C. Telephone D. Data E. Security F. Kiosk (Lobby Area) G. Concierge Station (Lobby Area) H. Panic Notification (Lobby Area Counters and Concierge Station) Audio -Visual (Conference Room) Al-8 ATTACHMENT 1-1 PROPOSAL A1-3-9 DEVELOPMENT SERVICES LOBBY RENOVATION City of Palm Desert WOO CONSTRUCTORS 'f»> Building Integrity s ,� ! $ . h )11. >e , &.& »»> / > . )1K a2\«& Tilden -Coil Constructors, Inc. DESIGN -BUILD SERVICES Table of Contents Cover Letter 1 Executive Summary 3 Proposed Scope of Services 5 Personnel 9 Understanding of the Project 17 References 21 List of Representative Projects 22 Proposal Form 31 Required Forms 35 gi Tilden -Coil CONSTRUCTORS — Building with Integrity Since 1938 October 13, 2021 City of Palm Desert 73-510 Fred Waring Drive Palm Desert, CA 92260 Submitted Via PlanetBids Re: Response to RFP for Development Services Lobby Renovations Dear City Council Members, We are excited for the opportunity to serve the City of Palm Desert as your design -builder for the Development Services Lobby Renovations Project. Our design -build team, comprised of Tilden -Coil Constructors, Inc. and STK Architecture, Inc. is uniquely qualified in programming, design, and full -service construction of municipal administrative projects throughout Southern California including the Coachella Valley. Tilden -Coil has an 83 year reputation for serving public clients throughout Southern California and we currently have multiple projects underway throughout the Coachella Valley, including for the City of Indio. STK Architecture has an equally strong reputation for serving public clients in the region for 52 years. Together, our team offers service, experience and certainty of results that comes from two highly respected local firms. You will find that our approach to deliver the project revolves around service, adaptability and partnership in order to provide the City with the greatest value for the defined budget. We will serve the City by listening to what is important to you, gain a thorough understanding of the project constraints, and plan around existing operations. We will remain adaptable as a team, knowing that planning is a dynamic process which must remain flexible to meet City requirements. Finally, our project approach will be developed as partnership with the City to ensure it best meets your needs. Thank you for the opportunity to share our qualifications and our proposal for design -build services. We look forward to developing a relationship with the City through earned confidence, trust and delivering on all dimensions of success that your project demands. si� ly, :�. Dayde Qrassard Pr 'sid nt and CEO Tilden -Coil Constructors, Inc. Building with Integrity Since 1938 dbrassard@tilden-coil.com Cell: 951-712-3410 5:\L' ami e Pulliam Acton Architect/NCARB CEO STK Architecture, Inc. cacton@stkinc.com Cell: 951-313-4116 36951 Cook Street, Suite # 103, Palm Desert, CA 92211 1 T. 760.423.2904 1 www.tilden-coil.com 1 License #208556 Development Services Lobby Remodel I Tilden -Coil Constructors, Inc. I 1 Pictured: Roy's Desert Springs Lobby Quality performance to the highest professional standards. What sets the Tilden -Coil / STK team apart from the rest is our focus on service and our proposed process moving forward with the City. We understand there are much needed improvements to the Development Services Lobby and surrounding areas and the City is working within a constrained budget. Instead of dictating what we think should be accomplished within the budget, our approach is to partner with the City to learn what is most important and to come up with innovative solutions together so that the end result is a project that works for the City, its staff and the public. Ultimately, our goal is to maximize the scope of work within the defined budget. To do this we will follow our process for understanding your expectations, charting the course and collaborating as a team (more info on "Understanding of the Project" on page 17). Using our target value design process, our team will then monitor the progression of the Project Cost against the Target Value Design. We continually communicate and track how decisions during the design process shape the projected cost, ensuring we stay on budget. We have provided a preliminary schedule which was developed based upon our limited understanding of City expectations. The schedule was developed to save cost at the expense of time. This is intended to be the starting point for a discussion with the City to come up with the best schedule possible which balances City expectations, cost and time. We look forward to a very collaborative process moving forward with the City and are team is prepared to begin serving the City immediately upon award. Executive Summary Design -Builder Tilden -Coil Constructors, Inc. Type of Firm Corporation Tilden -Coil was founded in 1938 and has been Incorporated since January 31, 1962, California Corporate #C042723 Contractors License California Contractors License #208556 (B) General Contracting and (A) General Engineering CA DIR Registration 1000000518 Insurance Over $20 Million in General Liability Coverage Office Locations Palm Desert 36951 Cook Street, Suite #103 Palm Desert, CA 2211 Headquarters 3612 Mission Inn Avenue Riverside, CA 92501 Pictured: City of Corona Corporate Yard Lobby <) Scope of Services Our objective is provide the most scope within the defined budget. Project Summary Palm Desert Development Services Building Renovation including entrance lobby, administrative services, support, and circulation. Improvements entail Interior Design and Space Planning, including but not limited to, functional layout, fixtures, furnishings, finishes, HVAC, Lighting, and Low Voltage per the program and bridging documents previously completed. Design Objectives Improved customer experience via: • Improving functionality in public spaces • Improving employee work space functionality and therefore their delivery of services • Improving public perception of Development Services and their delivery of ministrations • Improving the visual aesthetics of the public and administrative spaces • Improving circulation and connections between public and employee spaces • Providing excellent support spaces for systems, occupants, visitors, technology, and future improvements • *Reference plan in RFP dated 9/14/31 Scope of Work The City has communicated its desired scope of work in Attachment No.1 of the RFP and the City has also communicated the desire to design the most value into the project, as the team believes prudent, while remaining within the lump sum. Upon our preliminary review of the project it is apparent that not all of the desired scope will fit within the City's desired budget of $850,000. Therefore, our approach will be to work with the City to develop a prioritized list of scope that can be accomplished within the budget. We will use our target value design process (see page 18) to ensure the project remains within the budget during the design phase. LFH ELEC ILONFERENCE ROOM 1q ;."' ooEoo.. c.1 o D OF OFF R NOT IN SCOPE REFER TO THE SCOPE OF WORK (ATTACHMENT 1) FOR ADDITIONAL INFORMATION.I ��•aE,�mo�. CONFERENCE ROOM LAND. EMPTY INSP. CUBICLE NOT IN SCOPE NOT IN SCOPE ASSISTANT ER x NI EGI SD_100 ARCHITECTURE Development Services Lobby Remodel 1 Tilden -Coil Constructors, Inc. I 5 Design Services Architecture: • Plans (including demolition) Code Analysis (including ADA), Ceiling Plans, Interior Elevations, Details, Schedules, Notes/ Symbols/ Legends, Emergency Egress Plan • Architectural details • Finish, door, furniture, and hardware schedules Structural Engineering: • Incidental structural calculations for support as needed Mechanical: • Mechanical Schedules, Floor and Roof Plans, Energy calculations, Plumbing Electrical: • Electrical Floor Plans, Power, Data/Telephone, Lighting, Fire Alarm, Lighting, switching, fixture, Distribution, Equipment Schedules, component, Load Calculations Specifications/Project Manual, material board, presentation drawings Plan Check/Permitting Document Deliverables Updated Schedule: Updated Schedule with Critical Path Preconstruction Services 1. Design management 2. Collaboration and input from critical subcontractor trades 3. Target value design and estimating 4. Value engineering suggestions 5. Constructability and design coordination 6. Existing condition 3D laser scanning for design 7. Scope development 8. Open book subcontractor bid process and GMP development 9. Long lead procurement and supply chain review 10. Development of critical path schedule 11. Development of phasing and logistics plan Construction Phase Services Prior to the start of construction, we will run a series of large group and small group meetings, from preconstruction meetings to weekly production meetings, to individual company meetings to review documents, staging plans, and general procedures for specific building components. The purpose is to familiarize contractors with the other contractors involved, the sequencing, scope, and schedule. The outcome of these meetings will be "coordination drawings" that are the field -level road maps for the contractors, and a listing of what systems need mock-ups. When scheduling the work, our methodology can be summarized as follows: • establish the overall project plan and parameters by developing a master schedule • plan and schedule the construction in detail during preconstruction by developing a detailed project schedule, which conforms to the master schedule • develop subproject schedules (i.e., infrastructure, sitework, buildings, etc.), which conform to the detailed project schedule. We will consult with key contractors to facilitate the process • conduct weekly production meetings with subcontractors, superintendents, and foremen toverifyschedulecompliance and coordinate trade sequencing • update the schedule through direct field observation during construction to create constant focus, including updates for evaluating monthly progress payment applications • manage by exception, focusing on the critical path and noting items at risk of falling behind (sub -critical paths) • communicate accurately with all members of the team on schedule performance Our construction -phase services can be summarized as follows: 1. Full -Time On -Site Supervision 1. Part -Time Management 2. Part -Time Engineering 3. Part -Time Administrative Support 4. Safety Management 5. COVID-19 Protocols 6. Quality Assurance/Control (including submittal review, shop drawing coordination, Building information modeling as applicable, RFI's etc.) 7. Budget management 8. Scheduling 9. Project closeout 10. Warranty management Development Services Lobby Remodel Tilden -Coil Constructors, Inc. I 7 1104011 IN 'AL PIPE f Pictured: Western Municipal Water District Operations Center Lobby Project Team Rich Swan Safety Director Design Marty Greenwood Project Executive Tilden -Coil Drew Collins Project Manager Tilden -Coil Jarrod Baumann BIM Manager Tilden -Coil Robert Krzyszkowski Production Director Construction Project Project Engineer Superintendent Project Administrator Development Services Lobby Remodel I Tilden -Coil Constructors, Inc. I 9 Marty Greenwood Project Executive I Tilden -Coil Constructors, Inc. About Marty Greenwood is a results -oriented, hands-on project executive with 32 years of industry experience. He has a verifiable track record of successful projects that range from the $32 Million Expansion of the North Annex Jail Adult Detention Facility in Fresno to multiple public school facility improvement projects. Marty has a diverse range of skills and has successfully managed teams, company departments and entire organizations at the VP level. Marty has over 15 years experience as a Senior Project Manager and 12 years of experience as a Vice President for a public works construction company. Marty is now focused on on -site leadership for individual projects for the last 8 years at Tilden -Coil Constructors, where his results -oriented approach has yielded consistently positive results. Role Marty will lead the team throughout both preconstruction and construction. He provides mentoring and problem solving expertise to the entire team. Marty will drive the team to meet the project schedule and budget and will hold the project team accountable to meet deliverables. He will be dedicated part-time to the project and will be in regular communication with the County. Experience (Partial List) Project / Client RUHS Behavioral Health Restorative Transformation Center The County of Riverside Arlington Recovery Community & Sobering Center The County of Riverside Adult Detention Facility Expansion The County of Fresno Project Phoenix Community Center The City of Twentynine Palms Nuview Library Replacement The County of Riverside Roy's Desert Resource Center The County of Riverside Mental Health Crisis Service Center The County of Riverside Smith Correctional Facility Clinic and Laundry Expansion The County of Riverside Riverside County Law Library Renovation Riverside County Law Library Twentynine Palms Community Center City of Twentynine Palms RUHS Medical Center ED Negative Pressure The County of Riverside Indio Public Safety Campus City of Indio Value $13 Million $17 Million $32.2 Million $10 Million $3.3 Million $20 Million $11 Million $10 Million $3.5 Million $11 Million $5 Million $46 Million Education Bachelors of Science Degree in Construction Management, California State University, Fresno Associates Arts Degree in General Education, Hartnett Junior College, Salinas Training and Certification Forklift Certification Scaffolding Excavation 30 Hour OSHA Certified Open Water Diver (PADI) Qualified SWPPP Practitioner (QSP) CPR/First Aid Estimating Project Management Scheduling (Primavera) 10 I Development Services Lobby Remodel Tilden -Coil Constructors, Inc. Drew Collins Project Manager I Tilden -Coil Constructors, Inc. About Drew Collins has been a member of the Tilden -Coil team for four years, and in this time he has focused exclusively on public works projects. Drew has an engineering degree from California Baptist University and excels at solving technical challenges. He is very proficient in utilizing the latest Building Information Modeling (BIM) tools and programs to aid in the coordination process. Role As Project Manager, Drew will lead the team throughout both preconstruction and construction. Specific responsibilities include financial management, client satisfaction, quality control, schedule and safety. Drew will be the main point of contact and will start working on the project at the beginning stages of design and preconstruction to ensure a smooth transition and continued momentum through construction. Experience (Partial List) Project / Client Etiwanda HS Auditorium Chaffey Joint Union High School District Highgrove ES Improvements Riverside Unified School District Poly High School Improvements Riverside Unified School District Poly High School New Gymnasium Riverside Unified School District Rancho Cucamonga HS Auditorium Chaffey Joint Union High School District Rancho Cucamonga HS Science Renovation Chaffey Joint Union High School District Value $44 Million $20 Million $13 Million $9 Million $15 Million $3 Million Education Bachelor of Science Degree, Engineering, California Baptist University Training CPR/First Aid Tilden -Coil Safety Program Pull Planning CPM Scheduling Advanced Building Information Modeling Bluebeam As-Builts Steel Fabrication Shop Drawings Project Management Software Preventing Underground Utility Strikes Development Services Lobby Remodel Tilden -Coil Constructors, Inc. I 11 Jarrod Baumann BIM Manager About Jarrod Baumann is a leading professional in his field of virtual design and construction. Jarrod is a Revit Architecture Certified Professional, and has filled educational roles at Autodesk University, California Baptist University Engineering, and Construction Management Programs. Jarrod has a background in drafting MEP construction documents the old fashioned way, in 2D, beginning in 1995. He moved into the 3D revolution as soon as it began, and is now recognized as an expert in his field, which includes reality capture, clash detection, 3D content creation and pushing the limits of current technological capabilities. Role As BIM Manager, Jarrod's role is much more than managing the composite building information model. It encompasses our entire VDC (virtual design and construction) offerings, which include 3D laser scanning, and site surveying. Experience (Partial List) City of Indio - Indio Public Safety Campus City ofTwentynine Palms Community Center The County of Riverside Arlington Recovery Community The County of Riverside Arlington Sobering Center The County of Riverside RUHS BH Restorative Transformation Center The County of Riverside RUHS Medical Center Ed Negative Pressure The County of Riverside Smith Correctional Facility Clinic The County of Riverside Mental Health Crisis Service Center The County of Riverside Roy's Desert Springs Remodel The County of Riverside Nuview Library Replacement Norco Operations Center (EOC) Mt. SAC Facilities Plan Room and EOC Parkview Emergency Department Expansion Bonita USD Center for the Performing Arts RCCD Coil School for the Arts ChaffeyJUHSD Etiwanda HS Auditorium ChaffeyJUHSD Chaffey HS GWS Auditorium Modernization Cerritos College Performing Arts RCCD Culinary Arts Academy Cerritos College Liberal Arts / DSPS Cerritos College Fine Arts / CIS & Mathematics Mt. SAC Food Services (Mountie Cafe) Mt. SAC Student Success Mt. SAC Business & Computer Technology Mt. SAC Building 12 Renovation Mount Saint Mary's University Wellness Pavilion CBU New School of Business CBU New School of Engineering ChaffeyJUHSD Ontario HS Classroom Addition Education Associate of Applied Science Degree for CAD and Design, ITT Tech Technical specialist training for Autodesk Training Autodesk University BIM Software Technical Training Revit Technical Training FARO Laser Scanning Robotic Total Station Navisworks Technical Training Primavera P6 Scheduling LEED V.4.0 SWPPP Safety 12 I Development Services Lobby Remodel I Tilden -Coil Constructors, Inc. Camille Pulliam Acton Principal, CEO I STK Architecture About Ms. Acton joined STK in 1988 as a project manager and became an owner in 1997. She has managed and acted as the project architect and principal -in -charge on community buildings and a variety of projects including mixed -use entertainment developments, libraries, athletic centers/ gymnasiums, parks, and churches. Camille leads the design department at STK, as well as the Energy Efficiency Analysis campaign established by her in 2009. Role As the leader of the Architectural and Interior Design departments at STK, Ms. Acton will play an active role throughout the project, leading the design team through the collaborative planning, programming and design efforts. Relevant Experience (Partial List) 1. Highland Community Complex Master Plan, Highland, CA 2. Library & Environmental Learning Center, Highland, CA 3. Oceanside Fire Station #1, Design Consultation 4. Multi Plex Movie Theatres, Nation-wide 5. Soboba Fire Station Architectural Design 6. Highland Community Center, Highland, CA Education Bachelor of Architecture University of Kansas, 1985 Environmental Design University of Colorado, 1978-81 Professional Registration: CA Architect License #C24181 NCARB #45876 VA Architect License #017260 HI Architect License #16382 D.C. Architect License #102811 MA Architect License #32343 Development Services Lobby Remodel 1 Tilden -Coil Constructors, Inc. I 13 Jonie Romano Project Manager I STK Architecture About Ms. Romano joined STK in 2017 as a Designer and Project Manager. She has 16 years overall professional experience that includes 8 years in the UAE. Additional experience is residential & commercial architecture and design. Jonie has active involvement in projects from design conceptualization, construction documentation & implementation. Role In her role as Project Manager, Jonie is responsible for the development and coordination of the designschedule,directingthe preparation ofdocuments, leadingalldesign meetings,coordinating quality control efforts, and ensuring the design team is supported with the appropriate resources as necessary throughout the project. Relevant Experience (Partial List) 1. Desert Hot Springs City Hall 2. Launch Pointe RV Park and Resort, Lake Elsinore, CA 3. Oceanside Fire Station #1, Oceanside, CA 4. St. Regis Hotel, Dubai, UAE 5. Dubai Festival City, Dubai, UAE 6. Mina Al Arab Resort Community- Ras Al Khaimah, UAE 7. Cleveland Clinic (Multi -Specialty Hospital), Abu Dhabi, UAE 8. New York University, Abu Dhabi, UAE Education BS-Architecture University of San Carlos Cebu City, PhiEs., 2005 Professional Registration: NCARB #862028 United Architects of the Philippines - UAP #22713 14 I Development Services Lobby Remodel 1 Tilden -Coil Constructors, Inc. Roberto Rubini Designer I STK Architecture About Mr. Rubini joined STK in 1994. Roberto's multi -talents, hard work and diligence has made him a valuable asset for STK and our clients. Roberto possesses a rare combination of creative talent and technical excellence— attributes perfectly suited to successful architectural design. He has a wide variety of design experience from mufti -million dollar theatre/entertainment centers to local fire stations. Roberto is well versed in coordination of construction documents — implementing his outstanding designs and making them reality. He is the Revit expert at STK, and has taken on the role of teacher/ mentor for the rest of the staff. Roberto's strengths are design, document implementation, and rendering. Role As the designer, Roberto will collaborate with the team to interpret and translate the project program into design options/alternatives, assist in the presentation and communication of alternatives to the City and refine the design solutions in response to City input. Relevant Experience (Partial List) 1. Desert Hot Springs City Hall 2. Lake Elsinore City Hall and Cultural Center Restoration 3. Menifee Fire Station 4. Kerasotes Boston, MA 5. Kerasotes Santa Clara Education Bachelor of Architecture Ricardo Palma University Lima, Peru, 1990 Professional Registration: NCARB #862028 United Architects of the Philippines - UAP #22713 Development Services Lobby Remodel I Tilden -Coil Constructors, Inc. I 15 ictured: RCOE Sky Canyon Office TI Understanding of the Project Our objective is to provide the City flexibility by providing multiple design solutions. Approach Understanding expectations: Our first duty as a design -build team will be to gain an intimate understanding of City expectations; this includes as many stakeholders as possible. This exercise goes beyond understanding the project scope requirements, and also includes budget, schedule, quality and other areas, which will serve as the basis for our design -build team's shared goals. Once we understand your expectations, we document them and rigorously track our progress in meeting them. Charting the course: Once our team has a clear understanding of stakeholder expectations, including a clear understanding of schedule and budget constraints, we chart a course to the construction start date through the use of a preconstruction schedule. We hold a collaborative meeting to identify all the actions that must take place by all team members in order to achieve the desired construction start date. In this meeting, team members provide input and feedback on items they are responsible for and ultimately commit to meeting critical milestones. This exercise is extremely effective at getting the team and client aligned to a realistic and clear schedule early on, and allows for team accountability throughout preconstruction. Teamwork: Once we have a clear course that all team members have agreed to, we start our collaborative design process. The integrated team process will include regularteam meetings to status design, schedule and budget to ensure we are on track. Concurrent with design, our team will be reviewing the drawings for constructability, value and quality, and coordination (clash detection). Our superintendent will begin planning for construction and developing a detailed construction schedule and logistics and phasing plans, which will be included in subcontractor bid packages. ///71F W2 TAKE A PROACTIVE fLOc-E IN T!-IE �U �--jES�(A6LISN STANhAR.h� �" 9 ENACE FRcx,YAMS ��AY.S�aS AKa�F_ I Su6Le.�TwRS -rt P. _ '(1s 5G'I 1/19Fw7 v-I'7 2- 17 zlz-3117 I t > mdn 9/zzh71 zhSIV 3/1117 .1410 f.. mA + z�rn-� Development Services Lobby Remodel Tilden -Coil Constructors, Inc. I 17 Pre -Design • Review and understand existing program, concept, requirements and parameters • Update requirements, if necessary, with current needs assessment, if changed • Update criteria, where it has changed, with current considerations • Update resulting parameters, where they have changed, to reflect current standards, criteria, needs, and desires • Verify sizes, relationships, volumes, objectives, goals, criteria and adjacencies. • Publish application and deliverables required for planning approval • Obtain approval of updated program, concept, requirements and parameters Building Design • Implement plan and space requirements according to the bridging documents and updates (if applicable) • Finishes, Furniture, and Fixtures to be designed in keeping with the context of Desert Valley design and preferences of the client. • The design is to be representative of the functional, clean, elegant and honest aesthetic demonstrated in the best of desert community design. • Palm Desert has numerous examples of excellent design (both functionally and aesthetically) that may serve as inspiration for the appropriate application of forms, materials, and lighting for this project. Tilden -Coil CONSTRUCTORS— Budder4 <AIM, spas 19>8 DESCRIPTION I Light Fixture Package Alternates Alternate lighting package 2 Lighting Inverter Eliminate the 2 lighfing inverters 3 Generator Eliminate the 5020W generator 4 Fencing Provide custom fabncoted fencing 5 Site Concrete vs Site Pavers Add site concrete paving of Amval Court ILO Pavers Remove pavers from Anal Court and provide concrete in place 6 Skylight Roller Shades Provide only blackout shades Reduce electrical requirements Target Value Design Process Our team will utilize a "target value design process" to manage the project budget. We know the City's budget expectation is to maintain an $850,000 budget. Our team will then use the scope list provided earlier in the proposal to maintain a running list of scope with current market pricing. Our team will then monitor the progression of the Project Cost against the Target Value Design. We continually communicate and track how decisions during the design process shape the projected cost. We utilize milestone estimates and real time estimates through our Design Evolution Process. Through the Design Evolution Process, our team tracks design decisions which shows accepted changes, suggested changes and not accepted changes that are pending a decision. It is a tool that allows our team to track and collaborate on design decisions that affect cost in real time. It is presented in weekly meetings and discussed for quick resolution to pending decisions. The use of the Design Evolution Log allows our team to keep track of the project cost in-between milestone estimates, which greatly reduces the potential of exceeding the Target Value during design. This added information eliminates surprises and facilitates weekly collaboration between design -build team members regarding ongoing design decisions. When we identify a cost prohibiting design element in real time, our team quickly develops an alternative approach and we can change direction before wasting time and resources. Sample Client / Project Design Evolution Log CURRENT UNIT UPDATED UNIT SAVINGS/ REDUCTION COST COST 019 T-C 000 REDUCTION (ROM) - $ (9200000) 1 $ - $ (56.000001 1 $ - $ (10400000) 1 $ - $ (210,00000) I $ - $ 73.25000 - $ (150,000.00) $ 92,000 $ 56.000 $ 104.000 $ 210.000 $ - $ (73.250) $ - $ 150,000 $ - $ (70,000.001 I $ $ - $ (4,00000) I $ 9, Date: 10/27/20 Owner Accepted / ESTIMATE NOTES Rejected Refer fo the proposed alternate submittal package $ 56,000 The 500KW (800amp) generator should SIIISCO over She inverter,. Added VE in the enclosure Keep the 2 lighting inverters and remove the generator. Added VE in the enclosure $ 21$'$$$ Provide custom fence ILO specified manufactured fencing. There will need to be a cost to paint fence Concrete to be finished with topcast in 6'x6' sections Accepted pending design team review Accepted pending design team review Rejected Accepted Rejected - $ 70,000 _ Reduce quantity from 40 dual shades 10 20 single shades, reduction in Accepted - $ 4,000 power requirements as well 7 New Trees Add new 92' box trees 8 North Parking Lot Pavers Provide AC paving ILO of Pavers Remove pavers from North Parking Lot $ 75,000.00 $ 8000000 I $ 75,000 $ (5,000) $ $ - $ 13,500.00 I $ - $ (13,500) - $ (130,00000) I $ - $ 130,000 Cost to install 4 new frees 8 $5k more than relocating existing frees pending discussion but come with a warranty. Client to discuss with Jacinto for possible with Larry Jacinto tree donation which would result in additional savings Accepted Total $ 548,500.00 18 I Development Services Lobby Remodel Tilden -Coil Constructors, Inc. Project Schedule rTilden CONSTRUCTORS - Building. with Integrity Since I938 Proiect I I I 2021 Sept Oct Nov Contracting/Design/Approval Milestones Design -Build RFP Release - 9-16-21 Pre -Proposal Meeting - 9-23-21 Site Visit #1 - 9-28-21 Site Visit #2 - 9-29-21 Requests for Clarifications Due - 10-4-21 Design -Build Proposals Due - 10-13-21 Interviews - 10-18-21 Staff Selection of design -Build Entities - 10-29-21 Design -Build Team City Council Award Construction Documents Phase Notice to Proceed - 12-6-21 Design Kick -Off (2 Meetings - 2 Days) - 12-8-21 Preliminary Due Diligence & Research (11 Work Days) - 12-23-21 90% CD's (21 Work Days) - 1-26-22 QA/QC - Client Reviews (11 Work Days) - 2-11-22 100% CD's (11 Work Days) - 3-1-22 Permitting (21 Work Days)-3-31-22 Bid/Contracting Milestones Procurement of Long Lead Items (3 Months) - 2-11-22 to 5-11-22 Issue Bid Documents/Job Walk - 3-2-22 Bid (27 Work Days) - 4-8-22 Owner Approval & Authorization to Proceed (5 Work Days) - 4-15-22 Execute Contracts (10 Work Days) - 4-29-22 Construction Construction (4 Months) - 5-2-22 to 8-31-22 Our project schedule was developed to ensure the project is completed as economically as possible. We are avoiding overtime and weekend work which can add overall cost to the project. We have strategically chosen to bid the project out to our subcontractors early in the year, to avoid seasonal price escalation. Long Lead Items The following items, if included in the final scope of work, may present procurement challenges due to industry -wide shortages and availability. 1. Ballistic rated glass 2. Ballistic rated doors 3. Automatic sliding entrance doors 4. FF&E (by City) 5. Casework 6. Doors, frames and hardware 7. Kiosk 8. Access controls 9. Light fixtures 10. Plumbing fixtures In order to mitigate any schedule impacts due to long lead items, our approach will be to identify and procure the items early. This will likely mean that our team will require approval from the City to Dec I Jan • City of Palm Desert Development Services Lobby Renovations 2022 Feb Mar Apr May Jun July Aug Sept Oct Nov Dec IIIIIIIIIIIII- procure certain items early (prior to permit). We will partner with subcontractors early in the design phase to provide input on lead times and alternative equipment and materials. Phasing and Logistics Because the building will be occupied during the remodel activity, our primary objective will be to reduce the impact to City staff and the public while maintaining a safe environment. We have a vast amount of experience completing work within occupied spaces and some of the strategies we use to make them successful include: • Regular communication of upcoming construction activities through meetings and look -ahead schedules • Planning for staff moving and relocation • Clear signage and separation of work areas and public spaces • Dust and noise control as necessary We understand thatthe lobby area must remain publicly accessible during hours of operation. A secondary entrance with clear public directional signage will be utilized when necessary to maintain this access. One permit counter will be open at all times, so our detailed construction schedule will be phased to accomplish this. Development Services Lobby Remodel Tilden -Coil Constructors, Inc. I 19 Project Compliance The RFP stated that "The Design -Build Team's goal is to design the most value into the project, as you believe prudent, while remaining within the lump sum". Based upon current market conditions the City will not be able to complete all the desired scope that was included within the RFP, therefore our team will work with the City to develop a list of scope that is attainable within the lump sum budget amount. Under this approach, we feel that our proposal meets the requirements of the RFP. Value Added Enhancements In order to increase the speed and accuracy of design our team will utilize our in-house laser scanning process. We have the ability to perform laser precision surveys of existing conditions, or as -built construction conditions in-house and we would propose to use this technology to scan the building in order to take advantage of the benefits outlined below. Our owned equipment scans a space with a laser, taking distances from millions of points, depending on the resolution of the scan. The result looks like an actual picture, but everything is to scale in 3 dimensions. The BIM model can be created from the point cloud, where we can relocate and add MEP components and ensure they fit within the actual spaces we have. Our BIM department can then plot out relocations of systems as needed to ensure systems fit properly, and don't clash with one another. Removing these clashes while in a computer model means not discovering problems midway through the construction process. We can model areas 3 dimensionally in a parallel fashion to the completion of design documents, which means the parts and pieces will fit together right the first time. In addition to the coordination advantages offered by laser scanning, our team will be able to begin design using exact as - built dimensions. This data will enable our team to precisely communicate existing conditions to the design team, bidders and the City which will not only expedite design but will be less intrusive the City staff. Schematic Drawings Not required per Q&A issued by the City. 20 I Development Services Lobby Remodel Tilden -Coil Constructors, Inc. References We invite you to contact our references below to learn more about what makes the TCC/ST< team unique! Tilden -Coil Constructors Project: Public Safety Campus (info attached) City of Indio Scott Trujillo, Deputy City Manager (760) 391-4014 strujillo@indio.org Project: Roy's Desert Springs Remodel (info attached) The County of Riverside Anna rodriguez, Development Manager (951) 955-0911 as rod riguez@rivco.org Project: Twentynine Palms Community Center (info attached) City of Twentynine Palms Frank Luckino, City Manager (760) 367-6799 fluckino@29palms.org Project: Sky Canyon TI (info attached) Riverside County Office of Education Matt Snellings, Director II (951) 856-6582 msnellings@rcoe.us Project: RMC Clinic Remodel (info attached) Riverside Medical Center Marshal Stevens, VP Facilities and Support Services (951) 321-6331 marshaLstevens@rmcps.com STK Architecture Project: Highland Police Station(info attached) City of Highland Joseph Hughes, City Manager (909) 864-6861 jhughes@cityofhighland.org Project: Desert Hot Springs City Hall (info attached) City of Desert Hot Springs Chuck Maynard, City Manager (760) 329-6411 x260 cmaynard@clmconsultant.com Project: Lake Elsinore Cultural Center (info attached) City of Lake Elsinore Jason Simpson (951) 674-3124 jsimpson@lake-elsinore.org Project: Highland Corporate Yard City of Highland Joseph Hughes, City Manager (909) 864-6861 jhughes@cityofhighland.org Development Services Lobby Remodel 1 Tilden -Coil Constructors, Inc. I 21 PUBLIC SAFETY CAMP. City of Indi Project Description The campus expansion includes a new 22,596 sf Public Safety Service building, a 7,336 sf single -story Communication Dispatch Center, and a 13,445 sf, single -story, 4-apparatus bay, 15 bed fire station. Location I Indio, CA Size 143,400 sf Architect I Holt Architecture Value I $43 Million Completed I In Progress (Pre -construction) Tilden Coil CONSTRUCTORS — Building with Integrity Since 1938 22 I Development Services Lobby Remodel I Tilden -Coil Constructors, Inc. ROY'S DESERT RESOURCE CENTER REMODEL The County of Riverside f Project Description The mental health facility offers in -patient care including forensic, augmented and clinic spaces for the County of Riverside. The Project consists of construction of approximately 46,000 sf tenant improvement of an existing Concrete Tilt -Up Building in Palm Springs, CA. Location I Palm Springs, CA Size 122,676 sf Architects Holt Architecture Value I $20 Million Completed I August 2020 Tilden Coil CONSTRUCTORS — Building with Integrity Since 1938 Development Services Lobby Remodel I Tilden -Coil Constructors, Inc. I 23 TWENTYNINE PALMS COMMUNITY CENTER City of Twentynine Palms PROJECT PHOENIX COMMUNITY CENTER Project Description The project, located at the intersection of Yucca Ave and Twenynine Palms Highway in Downtown Twentynine Palms includes two new buildings. The first building is a new Multi -purpose community center (10,000 to 14,000 sf) housing office, gymnasium, kitchen and meeting/conference facilities. The second building is a new Cultural and Visitor Center (4,500 sf) will become the new home of the Joshua Tree National Park Visitor's Center in Twenty -Nine Palms. One special feature of this center will be the incorporation of a cultural museum component centered around telling the human history of the area and containing artifacts from the Campbell Collection. Location Indio, CA Size 116,500 sf Architect Holt Architecture Value $11 Million Completed In Progress (construction) Tilden- C oil CONSTRUCTORS, Building with Integrity Since 1938 24 I Development Services Lobby Remodel Tilden -Coil Constructors, Inc. SKY CANYON OFFICE TI Riverside County Office of Education Project Description The Project consists of the tenant improvement of the entire second floor, approximately 19,500 square feet, of an existing office building. The improved space is occupied by multiple administrative and program departments of the Riverside County Office of Education and include new conference rooms, office spaces and support spaces. The core (first floor, restrooms, and elevator) remained and was slightly adjusted to create a new reception area. The first floor was occupied during construction which required a detailed logistics plan and careful consideration of sequencing the work. Our team was continually in communication with the first floor tenants in order to ensure minimal disruption during construction. Our team performed a 3D laser survey of the second floor prior to construction which allowed for a precise clash analysis and constructability review of the progress drawings. Several issues were resolved early on such as a conflict with the main supply duct, architectural ceiling and a support beam for a folding door. This issue, if not discovered early, would have added cost and time to the project during construction. Location I Murrieta, CA Size 119,570 sf Architect I HMCArchitects Value I $3 Million Completed I February 2018 Tilden- C oil CONSTRUCTORS, Building with Integrity Since 1938 Development Services Lobby Remodel Tilden -Coil Constructors, Inc. I 25 SURGERY C LITER REMODEL Riverside Medic - in'c-- Project Description This design -build project consists of the remodel and reconfiguration of the first floor of the Riverside Medical Clinic Surgery Center in Riverside, CA. The remodel includes the addition of one new operating room bringing the total to four operating rooms. Other remodeled spaces include decontamination, sterilization, clean storage, equipment storage, locker rooms and restrooms, nurses station, post -op recovery area, pre -op area, administrative spaces, and a new lobby. Location I Riverside, CA Size 19,990 sf Architect I HPI Architecture Value I $3 Million Completed I December2018 TA Tilden -Coil CONSTRUCTORS — Building with Integrity Since 1938 26 I Development Services Lobby Remodel I Tilden -Coil Constructors, Inc. DESERT HOTSPRINGS CITY HALL City:of Desert Hot Springs Project Description This design -build project consists of the remodel and reconfiguration of the first floor of the Riverside Medical Clinic Surgery Center in Riverside, CA. The remodel includes the addition of one new operating room bringing the total to four operating rooms. Other remodeled spaces include decontamination, sterilization, clean storage, equipment storage, locker rooms and restrooms, nurses station, post -op recovery area, pre -op area, administrative spaces, and a new lobby. Location I Hot Springs, CA Size 113,090 sf Value I $5 Million ARCHITECTURE,INC. Development Services Lobby Remodel I Tilden -Coil Constructors, Inc. I 27 HIGHLAND POLICE STATION City of Highland Redevelopment Agency Riverside County Sheriff's Department _ POLICE STATION Project Description The City of Highland Redevelopment Agency, in conjunction with the Riverside County Sheriff's Department, contracted STK to research, program, design and document a new police station for the Highland Police Department. Located on Baseline near the civic center in Highland, the 30,000S.F.facility (plus independent storage building) accommodates the forecasted needs of the Police Department for 20 years. The site housed the existing Police Department building, which was demolished after completion of the new station. Location I Highland, CA Size 130,000 sf Value I $9 Million ARCHITECTURE, INC. 28 I Development Services Lobby Remodel I Tilden -Coil Constructors, Inc. LAKE EL�`IfE RENOVATION — City of Lake Elsinore Project Description After the seismic upgrade was performed on this structure, the City wished to convert the choir loft into a "Class A" conference room. The design services included full interior/material finishes. We incorporated two 5 foot flat screen televisions with internet/tele-conference capabilities. Also included was a service counter with refrigerator/dishwasher and sink. Stained oak shutters, replacement windows, oak crown molding and custom conference table completed the design. Location I Lake Elsinore, CA Value I $350K ARCHITECTURE, INC. Development Services Lobby Remodel I Tilden -Coil Constructors, Inc. I 29 HIGHLAND CORPORATE YARD City of Highland „m „'!!IIIIII IHIi IIIIIIIIII Project Description The Highland Corporate Yard is a 20,000 S.F. municipal material and vehicle storage yard with administration services located in Highland, CA. The project program includes office spaces (including lobby, conference room, kitchen and bath facilities), and a variety of storage spaces: temperature controlled, weather protected, building material storage pits, open bays and covered truck parking bays. The corporate yard is part of a larger complex developed by City of Highland and designed bySTK Inc. consisting of athletic center and swimming pool, community park and public library and environmental learning center. 30 I Development Services Lobby Remodel I Tilden -Coil Constructors, Inc. Location I Highland, CA Size 120,000 sf Value I $7 Million ARCHITECTURE, INC. Forms ATTACHMENT 2 PROPOSAL FORM Proposal form must be completed in their entirety or the Design -Build Team may be deemed non -responsive in the City's sole discretion. PROPOSAL TO: City of Palm Desert 73-510 Fred Waring Drive Palm Desert, California 92260 PROPOSAL FOR: A. SUBMITTAL Tilden -Coil Constructors, Inc. (1) IDENTIFICATION OF DESIGN -BUILD TEAM: Legal Name of Design -Build Entity: Federal I.D. Number: Contractor's License Number: License Expiration Date: License Classification: Business Address: Business Telephone: Business Facsimile Number: Primary Contact Name: Contact Email Address: (2) ADDENDUM: Tilden -Coil Constructors, Inc. 95-2213902 CA #208556 8/31/2023 A, B 3612 Mission Inn Ave. Riverside, CA 92501 951-684-5901 951-684-0725 Tommy Palmieri tr almierir tilden-coiI.com Receipt of the following Addenda is hereby acknowledged: Number Date 1 9/22/21 2 9/27/21 3 9/30/21 4 9/30/21 5 10/7/21 6 10/8/21 A2-1 Development Services Lobby Remodel Tilden -Coil Constructors, Inc. I 31 B. COST PROPOSAL The undersigned hereby proposes and agrees to furnish all design services, construction labor, materials, equipment, including management and oversight, to perform all work required for the Project in the manner and time described in the undersigned's design proposal and documents. The Cost Proposal, set forth below, includes all costs of the scope of work as requested in the RFP, and required by the provisions of the Design -Build Agreement, including the cost of bonds, insurance, sales tax, and every other item of expense, direct or indirect, incidental to the scope of work. (1) COST PROPOSAL BUDGET: ITEM DESCRIPTION 1. Design and Preconstruction Services 2. Construction Services (General Conditions) 3. Construction Cost 4. Allowances 5. Fee (Includes GL/PL insurance, builder's risk, bonds and fee) 6. Contingency (11.8% City Owned) Total COMPLETE SCOPE OF WORK FOR THE LUMP SUM PRICE OF: "See assumptions and clarifications on the following page A. PROPOSAL CERTIFICATION (1) LUMP SUM PRICE: BUDGET AMOUNT $ 160,000 $ 116,000 $ 438,629 $ TBD $ 135,371 $ 100,000 $950,000 The undersigned, having fully examined the RFP and any and all attachments, exhibits, and addenda thereto, and site of the Project, proposes to furnish all design and construction labor, materials, and equipment, and do all work in compliance with the terms and conditions of the RFP, without exception, and the herein proposal, for a Lump Sum Price of: Nine Hundred Fifty Thousand Dollars ($ $950,000 The Lump Sum Price includes City Owned Contingency, the amount of which is specified in the RFP. Any funds from City Owned Contingency not expended pursuant to written approval by City shall revert to City and shall not accrue for the benefit of the undersigned. "See assumptions and clarifications on the following page (2) TIME FOR COMPLETION: The undersigned agrees to comply with City's Master Project Schedule as specified in this RFP. The undersigned further agrees that completion of work required by the Design -Build Agreement resulting from this RFP and the herein Proposal shall be no later than March 18, 2021. *See assumptions and clarifications on the following page (3) CERTIFICATION: (a) The undersigned has read and understands the RFP. (b) The undersigned has become familiar with local site conditions under which the A2-2 32 I Development Services Lobby Remodel Tilden -Coil Constructors, Inc. work is to be performed and has correlated personal observations with the requirements of the RFP. (c) The proposal submitted by the undersigned is made in accordance with the RFP and is based upon the materials, systems, and equipment specified therein that will support or exceed the minimum quality, service, utilization, performance, and other levels specified therein, without exception; and the undersigned agrees that City is not responsible for any error or omission in this proposal or in its preparation. (d) The undersigned will design and construct facilities that are fully functional and meet or exceed all function, program, performance, and other requirements of City as identified in the RFP, and for the Lump Sum Price specified above. *See assumptions and clarifications on the following page (e) If City recommends the undersigned be awarded the Design -Build Agreement, the undersigned will meet with City to review in detail this proposal and will make any necessary changes or revisions to this proposal, including any and all design submittals and proposed materials, systems and equipment to ensure delivery to City of fully functional facilities which meet or exceed all requirements of City as identified in the RFP without revision to the Lump Sum Price. (f) (g) The undersigned acknowledges and warrants that the Design -Build Team includes, at a minimum, architects, engineers, other necessary or specified design professionals and consultants, and a general contractor as identified in its Proposal. Substitutions of architects, engineers and other design professionals and consultants, or general contractors as in this Proposal, will not be made without City's written consent to such substitution(s). The undersigned and each of its subconsultants, contractors, and subcontractors shall at all times during the execution of the work contemplated by the RFP, be qualified to complete the work, and each shall comply with all applicable State of California and City of Palm Desert professional and business licensing and registration requirements. (h) The undersigned will not modify, amend, revoke or withdraw this proposal, without written permission of City for a period of not less than ninety (90) calendar days following the submission due date and time specified in the RFP or until a final Design -Build Agreement has been executed, whichever occurs first. (i) The undersigned, or any member of the Design -Build Team, or any agent or representative thereof, has not collaborated or communicated with, or entered into any understanding agreements, whether written or oral, whether direct or indirect, or otherwise, with any other Design -Build Team, or any agent or representative thereof, in the preparation of this Proposal. (j) The undersigned has reviewed in detail the Design -Build Agreement attached to this RFP and takes no exception to its terms and conditions and warrants that nothing contained in the Design -Build Agreement would preclude the Design - Build Team from entering into the Design -Build Agreement unless so qualified in writing in the Proposal and understands that taking exceptions may result in *See assumptions and clarifications on the following page A2-3 Development Services Lobby Remodel Tilden -Coil Constructors, Inc. I 33 disqualification of said proposal as non -responsive. Exceptions to the bond forms, insurance requirements and indemnity provisions included in the Design - Build Agreement will not be considered and such exceptions may result in disqualification of the proposal as non -responsive. (k) This Proposal is genuine and is not a sham or made in the interest of, or on behalf of, any person or entity not herein named. (I) The undersigned, or any member of the Design -Build Team, or any agent or representative thereof, has not engaged in any communication or contact with City or any City employee, or any City consultants, except as specifically allowed and limited by this RFP. DESIGN -BUILD TEAM SIGNATURE (Seal Required): Signature below shall bind the Design -Build Team to all representations included in this Proposal and all attachments and exhibits hereinto. Dayne Brassard, President & CEO Signatuy Name and Title Tilden -Coil Constructors, Inc. Legal Name of Design -Build Team *Assumptions and clarifications: October 13, 2021 Date 1. Our team has deviated from the RFP Schedule as clarified in the Addendum. 2. Per our proposal, the entire scope of work can not be provided within the lump sum amount. Our proposal is based upon a partnership approach to develop a prioritized scope of work that can be attained within the defined budget. 3. "Construction Costs" defined above includes 4% construction contingency. A2-4 34 I Development Services Lobby Remodel Tilden -Coil Constructors, Inc. ATTACHMENT 3 IRAN CONTRACTING ACT CERTIFICATION (Public Contract Code sections 2202-2208) Prior to bidding on, submitting a proposal, or executing a contract or renewal for a public entity contract for goods or services of $1,000,000 or more, a vendor must either: a) certify it is not on the current list of persons engaged in investment activities in Iran created by the California Department of General Services ("DGS") pursuant to Public Contract Code section 2203(b) and is not a financial institution extending $20,000,000 or more in credit to another person, for 45 days or more, if that other person will use the credit to provide goods or services in the energy sector in Iran and is identified on the current list of persons engaged in investment activities in Iran created by DGS; or b) demonstrate it has been exempted from the certification requirement for that solicitation or contract pursuant to Public Contract Code section 2203(c) or (d). To comply with this requirement, please insert your vendor or financial institution name and Federal ID Number (if available) and complete one of the options below. Please note: California law establishes penalties for providing false certifications, including civil penalties equal to the greater of $250,000 or twice the amount of the contract for which the false certification was made, contract termination, and three-year ineligibility to bid on contracts. (Pub. Cont. Code § 2205.) OPTION #1 - CERTIFICATION I, the official named below, certify I am duly authorized to execute this certification on behalf of the vendor/financial institution identified below, and the vendor/financial institution identified below is not on the current list of persons engaged in investment activities in Iran created by DGS and is not a financial institution extending twenty million dollars ($20,000,000) or more in credit to another person/vendor, for 45 days or more, if that other person/vendor will use the credit to provide goods or services in the energy sector in Iran and is identified on the current list of persons engaged in investment activities in Iran created by DGS. I certify (or declare) under penalty of perjury under the laws of the State of California that the foregoing is true and correct. Vendor Name/Financial Institution (Printed) Tilden -Coil Constructors, Inc. By (Authorized Signature) Printed Name and Title of Person Signing Davne Brassard. President & CEO OPTION #2 — EXEMPTION Federal ID Number (or n/a) 95-2213902 Date Executed October 13.2021 Pursuant to Public Contract Code sections 2203(c) and (d), a public entity may permit a vendor/financial institution engaged in investment activities in Iran, on a case -by -case basis, to be eligible for, or to bid on, submit a proposal for, or enters into or renews, a contract for goods and services. If you have obtained an exemption from the certification requirement under the Iran Contracting Act, please fill out the information below, and attach documentation demonstrating the exemption approval. Vendor Name/Financial Institution (Printed) N/A By (Authorized Signature) N/A Printed Name and Title of Person Signing N/A Federal ID Number (or n/a) N/A Date Executed N/A A3-1 Development Services Lobby Remodel Tilden -Coil Constructors, Inc. I 35 ATTACHMENT 4 WORKERS' COMPENSATION CERTIFICATION Labor Code Section 3700 provides in relevant part: Every employer except the State shall secure the payment of compensation in one or more of the following ways: (a) By being insured against liability to pay compensation in one or more insurers duly authorized to write compensation insurance in this State. (b) By securing from the Director of Industrial Relations a certificate of consent to self -insure, which may be given upon furnishing proof satisfactory to the Director of Industrial Relations of ability to self -insure and to pay any compensation that may become due to his employees. I am aware of the provisions of Section 3700 of the Labor Code which require every employer to be insured against liability for workers' compensation or to undertake self-insurance in accordance with the provisions of that code, and I will comply with such provisions before commencing the performance of the work of this contract. Design -Build Team: Tilden -Coil Constructors, Inc. By: Name: DayBrassard Its: President & CEO In accordance with article 5 (commencing at Section 1860), chapter 1, part 7, division 2 of the Labor Code, the above certificate must be signed and filed with the City prior to performing any work under the contract. 36 I Development Services Lobby Remodel A4-1 Tilden -Coil Constructors, Inc. ATTACHMENT 5 NON -COLLUSION DECLARATION TO BE EXECUTED BY DESIGN -BUILD TEAM AND SUBMITTED WITH PROPOSAL The undersigned declares: I am the President & CEO of Tilden -Coil Constructors, Jnthe party making the foregoing proposal. The proposal is not made in the interest of, or on behalf of, any undisclosed person, partnership, company, association, organization, or corporation. The proposal is genuine and not collusive or sham. The respondent has not directly or indirectly induced or solicited any other respondent to put in a false or sham proposal. The respondent has not directly or indirectly colluded, conspired, connived, or agreed with any respondent or anyone else to put in a sham proposal, or to refrain from responding. The respondent has not in any manner, directly or indirectly, sought by agreement, communication, or conference with anyone to fix the proposal price of the respondent or any other respondent, or to fix any overhead, profit, or cost element of the proposal price, or of that of any other respondent. All statements contained in the proposal are true. The respondent has not, directly or indirectly, submitted his or her proposal price or any breakdown thereof, or the contents thereof, or divulged information or data relative thereto, to any corporation, partnership, company association, organization, proposal depository, or to any member or agent thereof to effectuate a collusive or sham proposal and has not paid, and will not pay, any person or entity for such purpose. Any person executing this declaration on behalf of a respondent that is a corporation, partnership, joint venture, limited liability company, limited liability partnership, or any other entity, hereby represents that he or she has full power to execute, and does execute, this declaration on behalf of the respondent. I declare under penalty of perjury under the laws of the State of California that the foregoing is true and correct and that this declaration is executed on October 13 2021 [date], at Riverside Signed: Print Name: Da`Gne Brassard [city], California [state]. A5-1 Development Services Lobby Remodel Tilden -Coil Constructors, Inc. I 37 ATTACHMENT 6 DESIGNATION OF SUBCONTRACTORS In compliance with the Subletting and Subcontracting Fair Practices Act of the Public Contract Code of the State of California, sections 4100 et seq., Design -Build Team shall set forth below: (a) the name and the location of the place of business and (b) the portion of the work which will be done by each subcontractor who will perform work or labor or render service to the Design -Build Team in or about the construction of the work in an amount in excess of one-half of one percent (1/2%) of the Design -Build Team's Lump Sum Price. Notwithstanding the foregoing, if the work involves streets and highways, then the Design -Build Team shall list each subcontractor who will perform work or labor or render service to Design -Build Team in or about the work in an amount in excess of one-half of one percent (1/2%) of the Design -Build Team's total Lump Sum Price or $10,000, whichever is greater. No additional time shall be granted to provide the below requested information. If no subcontractor is specified, for a portion of the work, or if more than one subcontractor is specified for the same portion of work, then the Design -Build Team shall be deemed to have agreed that it is fully qualified to perform that work, and that it shall perform that portion itself. Portion of Work CSLB License Subcontractor Name Location of Business Number None identified at this time A6-1 DIR Registration Number 38 I Development Services Lobby Remodel Tilden -Coil Constructors, Inc. ATTACHMENT 7 PUBLIC WORKS CONTRACTOR REGISTRATION CERTIFICATION Pursuant to Labor Code sections 1725.5 and 1771.1, all contractors and subcontractors that wish to bid on, be listed in a bid proposal, or enter into a contract to perform public work must be registered with the Department of Industrial Relations. See http://www.dir.ca.gov/Public- Works/PublicWorks.html for additional information. No bid will be accepted nor any contract entered into without proof of the contractor's and subcontractors' current registration with the Department of Industrial Relations to perform public work. Bidder hereby certifies that it is aware of the registration requirements set forth in Labor Code sections 1725.5 and 1771.1 and is currently registered as a contractor with the Department of Industrial Relations. Name of Bidder: Tilden -Coil Constructors, Inc. DIR Registration Number: 1000000518 Bidder further acknowledges: (1) Bidder shall maintain a current DIR registration for the duration of the project. (2) Bidder shall include the requirements of Labor Code sections 1725.5 and 1771.1 in its contract with subcontractors and ensure that all subcontractors are registered at the time of bid opening and maintain registration status for the duration of the project. Name of Bidder Tilden -Coil Constructors, Inc. Signature Name and Title Dated i Dayne Brassard, President & CEO October 13, 2021 A7-1 Development Services Lobby Remodel Tilden -Coil Constructors, Inc. I 39 ATTACHMENT 2 GENERAL CONDITIONS ARTICLE 1 - DEFINITIONS AND TERMINOLOGY 1.1 Defined Terms. A. Wherever used in the Contract Documents and printed with initial capital letters, the terms listed below will have the meanings indicated which are applicable to both the singular and plural thereof. In addition to terms specifically defined below, terms with initial capital letters in the Contract Documents include references to identified articles and paragraphs, and the titles of other documents or forms. 1. Act of God -- Act of God is an earthquake of magnitude 3.5 or higher on the Richter Scale or a tidal wave. 2. Additional Work — New or unforeseen work will be classified as "Additional Work" when Agency's Representative determines that it is not covered by the Contract. 3. Applicable Laws -- The laws, statutes, ordinances, rules, codes, regulations, permits, and licenses of any kind, issued by local, state or federal governmental authorities or private authorities with jurisdiction (including utilities), to the extent they apply to the Work. 4. Application for Payment -- The form acceptable to Agency's Representative which is to be used by the Design -Build Entity during the course of the Work in requesting progress or final payments and which is to be accompanied by such supporting documentation as is required by the Contract Documents. 5. Architect of Record or Engineer of Record ("A/E") -- The individual, partnership, corporation, joint venture, or other legal entity named as the Design Professional in the Contract or any succeeding entity designated by Agency. 6. Bridging Documents -- Includes, but is not limited to, the portions of the Contract Documents which constitute an outline of design requirements, Work, Project Program, Performance Specifications and schematic drawings. 7. Certificate for Payment -- The form signed by Agency's Representative attesting to the Design -Build Entity's right to receive payment for certain completed portions of the Work on the Project in accordance with Article 12. 8. Change Order ("CO") -- A document that authorizes an addition, deletion, or revision in the Work or an adjustment in the Contract Price or the Project Completion Date, issued on or after the Effective Date of the Contract, in accordance with the Contract Documents and in the form contained in the Contract Documents. 9. Change Order Request ("COR") -- A request made by the Design -Build Entity for an adjustment in the Contract Price and/or Project Completion Date as the result of a Design -Build Entity -claimed change to the Work. A2-10 10. Claim -- A demand or assertion by Agency or Design -Build Entity seeking an adjustment of the Contract Price or Project Completion Date, or both, or other relief with respect to the terms of the Contract. A demand for money or services by a third party is not a Claim. 11. Construction Documents -- The plans and Technical Specifications prepared by the Design -Build Entity for the Project and approved by Agency. The Construction Documents shall set forth in detail all items necessary to complete the construction (other than such details customarily provided by others during construction) of the Project in accordance with the Contract Documents. Following commencement of the Construction Phase, Construction Documents become part of the Contract Documents upon their completion and approval by Agency. All amendments and modifications to the Construction Documents must be approved by Agency in writing. 12. Construction Documents Phase — The first phase of the Work and will commence with the issuance of the Notice to Proceed. 13. Construction Phase -- The second phase of the Work and will commence upon final approval of the Construction Documents by Agency and a Notice to Proceed with Construction. 14. Construction Work -- That portion of the Work on the Project consisting of the provision of labor, materials, furnishings, equipment and services in connection with the construction of the Project as set forth in the Contract Documents. 15. Contract -- The entire integrated written agreement between Agency and Design - Build Entity concerning the Work. "Contract" may be used interchangeably with "Agreement" in the Contract Documents. The Contract supersedes prior negotiations, representations, or agreements, whether written or oral, and includes all Contract Documents. 16. Contract Documents -- The documents listed in Section 1 of the Contract. Some documents provided by Agency, including but not limited to reports and drawings of subsurface and physical conditions are not Contract Documents. 17. Contract Times -- The number of days or the dates stated in the Contract Documents and Project Schedule to achieve defined Milestones, if any, and to complete the Work so that it is ready for final payment. 18. Critical Supply Shortage -- An unusual shortage in materials that is (a) supported by documented proof that Design -Build Entity made every effort to obtain such materials from all available sources; (b) such shortage is due to the fact that such materials are not physically available from single or multiple sources or could have been obtained only at exorbitant prices entirely inconsistent with current and standard rates taking into account the quantities involved and the usual industry practices in obtaining such quantities; and (c) such shortages and the difficulties in obtaining alternate sources of materials could not have been known or anticipated by Design -Build Entity at the time it submitted its bid or entered the Contract. Market fluctuations in prices of materials, whether or not resulting from a Force Majeure Event, does not constitute a Critical Supply Shortage. A2-11 19. Day - A calendar day of 24 hours measured from midnight to the next midnight. 20. Defective Work -- Work that is unsatisfactory, faulty, or deficient; or that does not conform to the Contract Documents; or that does not meet the requirements of any inspection, reference standard, test, or approval referenced in the Contract Documents. 21. Demobilization — The complete dismantling and removal by the Design -Build Entity of all of the Design -Build Entity's temporary facilities, equipment, and personnel at the Site. 22. Design -Build Entity -- The individual or entity with which Agency has contracted for performance of the Work. 23. Design -Build Entity Representative -- The person or firm identified as the primary contact person and representative of the Design -Build Entity as designated in the Contract and who shall not be changed without prior written consent of Agency. 24. Design Materials -- Any and all documents, shop drawings, electronic information, including computer programs and computer generated materials, data, plans, drawings, sketches, illustrations, specifications, descriptions, models and other information developed, prepared, furnished, delivered or required to be delivered by, or for, the Design -Build Entity: (1) to Agency under the Contract Documents or; (2) developed or prepared by or for the Design -Build Entity specifically to discharge its duties under the Contract Documents. 25. Design Professional -- The individuals or entities who will provide the Design - Build Entity with the required architectural, engineering, and other professional services required for the coordinated design of the Project and the administration of construction. 26. Design Work -- The portion of the Work on the Project consisting of the Design services and design deliverables required to be provided in connection with the Design of the Project as set forth in the Contract Documents. 27. Drawings -- The graphic and pictorial portions of the Contract Documents showing the design, location, and dimensions of the Work to be done on the Project, generally including plans, elevations, sections, details, schedules, and diagrams prepared as part of the Design Materials. The Drawings are listed in the List of Drawings. 28. Effective Date of the Contract — The date indicated in the Contract on which it becomes effective, but if no such date is indicated, it means the date on which the Contract is signed and delivered by the last of the two parties to sign and deliver. 29. Equipment Manufacturer -- Any Separate Contractor that fabricates and/or supplies any of Agency's provided equipment which is installed in the Project by the Design -Build Entity. A2-12 30. Force Maieure Event -- An event that materially affects a party's performance and is one or more of the following: (1) Acts of God or other natural disasters occurring at the Site; (2) terrorism or other acts of a public enemy; (3) orders of governmental authorities (including, without limitation, unreasonable and unforeseeable delay in the issuance of permits or approvals by governmental authorities that are required for the Work); (4) pandemics, epidemics or quarantine restrictions; (5) strikes and other organized labor action occurring at the Site and the effects thereof on the Work, only to the extent such strikes and other organized labor action are beyond the control of Contractor and its Subcontractors, of every Tier, and to the extent the effects thereof cannot be avoided by use of replacement workers; and (6) a Critical Supply Shortage. For purposes of this section, "orders of governmental authorities," includes ordinances, emergency proclamations and orders, rules to protect the public health, welfare and safety, and other actions of the Agency in its capacity as a municipal authority. 31. Governmental Approvals -- Those governmental actions required to be obtained by Agency and necessary for the completion of the Project. 32. Hazardous Materials — Any substance: the presence of which requires investigation or remediation under any federal, state or local law, statute, regulation, ordinance, order, action, policy, or common law; which is or becomes defined as a "hazardous waste," "hazardous substance," pollutant, or contaminant under any federal, state or local law, statute, regulation, rule or ordinance, or amendments thereto, including, without limitations, the Comprehensive Environmental Response, Compensation and Liability Act, 42 U.S.C. Section 9601 et seq. ("CERCLA"), as amended, or the Resource, Conservation and Recovery Act, as amended, 42 U.S.C. Section 6901 et seq. ("RCRA"); which is petroleum, including crude oil or any fraction thereof not otherwise designated as a "hazardous substance" under CERCLA including, without limitation, gasoline, diesel fuel, or other petroleum hydrocarbons; which is toxic, explosive, corrosive, flammable, infectious, radioactive, carcinogenic, mutagenic, or otherwise hazardous and is or becomes regulated by any regulatory agency or instrumentality or the United States; the presence of which on the Site causes or threatens to cause a nuisance upon the Site or to the adjacent properties or poses or threatens to pose a hazard to the health or safety of persons on or about the Site; the presence of which on adjacent properties could constitute a trespass by the Design -Build Entity or the Agency; or as defined in the California Health and Safety Code. For the purposes of this Contract, "Hazardous Materials" shall also include, but are not limited to, "Underground Storage Tanks." "Underground Storage Tank" shall have the definition assigned to that term by Section 9001 of RCRA, 42 U.S.C. Section 6991, and also shall include: any tank of one thousand one hundred (1,100) gallons or less capacity used for storing motor fuel; any tank used for storing heating oil for consumption on the premises where stored; any septic tank; and any pipes connected to the above items. 33. Holidays -- Holidays occur on: New Year's Day - January 1 Martin Luther King Jr. Day — Third Monday of January A2-13 President's Day — Third Monday of February Memorial Day - Last Monday in May Independence Day - July 4 Labor Day - First Monday in September Veteran's Day - November 11 Thanksgiving Day - Fourth Thursday in November Friday after Thanksgiving Christmas Eve — December 24 Christmas Day — December 25 If any Holiday listed above falls on a Saturday, Saturday and the preceding Friday are both Holidays. If the Holiday should fall on a Sunday, Sunday and the following Monday are both Holidays. 34. Liens — Charges, security interests, or encumbrances upon Project funds, or personal property, including without limitation Stop Payment Notices. 35. Milestones — A principal event specified in the Contract Documents associated with a required completion date or time prior to Completion of all the Work. Failure to achieve Milestones may result in Liquidated Damages as described in the Contract Documents. 36. Notice of Award — The written notice by Agency to the Design -Build Entity stating that upon timely compliance by the Design -Build Entity with the conditions precedent listed therein, Agency will sign and deliver the Contract. 37. Notice of Completion — The form which may be executed by Agency and recorded by the county where the Project is located constituting final acceptance of the Project. 38. Notice to Proceed -- A written notice given by Agency to the Design -Build Entity fixing the date on which the Design -Build Entity may proceed with the Work and when Contract Time will commence to run. 39. Partial Utilization — Use by Agency of a substantially completed part of the Work prior to Completion of all the Work. 40. Performance Specifications -- That part of the Contract Documents consisting of written requirements for materials, equipment, systems, standards and workmanship as applied to the Work, and certain administrative requirements and procedural matters applicable thereto included within the Bridging Documents. 41. Project -- The total design and construction of which the Work performed under the Contract Documents may be the whole, or a part, and which may include separate design or construction work performed by Agency or by Separate Contractors for the Project. 42. Project Completion Date -- The date by which the Design -Build Entity agrees that all Work described in the Contract Documents shall be completed. The Project Completion Date is set forth in the Contract. A2-14 43. Proiect Schedule -- The graphical representation of a practical plan to complete the Work on the Project within the Project Completion Date and other Contract Times. The detailed requirements for the Project Schedule are stated in Article 6. 44. Proposal -- The proposal submitted by the Design -Build Entity in response to the Request for Proposal for this Project. 45. Request for Proposal ("RFP") -- The request for proposal issued by Agency for the Project and includes all documents, exhibits, attachments, and addenda thereto. 46. Samples -- Physical examples of materials, equipment, or workmanship that are representative of some portion of the Work and which establish the standards by which such portion of the Work will be judged. 47. Separate Contractor -- A person, or firm, under separate contract with Agency performing other work at the Project site which may affect the Work. 48. Shop Drawings -- All drawings, diagrams, illustrations, schedules, and other data or information which are specifically prepared or assembled by or for Design - Build Entity and submitted by Design -Build Entity to illustrate some portion of the Work. 49. Site -- Lands or areas indicated in the Contract Documents as being furnished by Agency upon which the Work is to be performed, including rights -of -way and easements for access thereto, and such other lands furnished by Agency which are designated for the use of Design -Build Entity. 50. Stop Payment Notice -- A written notice as defined in Civil Code section 8044. 51. Subcontractor — An individual or entity that has a contract with the Design -Build Entity or with a Subcontractor of the Design -Build Entity to perform a portion of the Work on the Project. Unless otherwise specifically provided, the term Subcontractor includes Subcontractors of all tiers. 52. Submittal - Written or graphic information and physical samples prepared and supplied by the Design -Build Entity demonstrating various portions of the Work. 53. Supplier -- A manufacturer, fabricator, supplier, distributor, material man, or vendor having a direct contract with Design -Build Entity or with any Subcontractor to furnish materials or equipment used in the performance of the Work or to be incorporated in the Work. 54. Technical Specifications — All documents developed by the Design -Build Entity and which are ready for final construction. 55. Tier -- The contractual level of a Subcontractor or supplier or consultant with respect to the Design -Build Entity. For example, a first tier Subcontractor is under subcontract with the Design -Build Entity, a second tier Subcontractor is under subcontract with a first tier Subcontractor, and so forth. A2-15 56. Warranty -- A written guarantee provided to Agency by the Design -Build Entity that the Work remain free of defects and suitable for its intended use for the period required by the Contract Documents or the longest period permitted by the law of this State, whichever is longer. 57. Work -- The entire design and construction, or the various separately identifiable parts thereof, required to be provided under the Contract Documents. Work includes and is the result of performing or providing all labor, services, and documentation necessary to produce such design and construction, and furnishing, installing, and incorporating all materials and equipment into such design and construction, all as required by the Contract Documents. 1.2 Terminoloay. A. The words and terms below are not defined but, when used in the Contract Documents, have the indicated meaning. 1. The word "furnish," when used in connection with services, materials, or equipment, shall mean to supply and deliver said services, materials, or equipment to the Project site (or some other specified location) ready for use or installation and in usable or operable condition. 2. The word "install," when used in connection with services, materials, or equipment, shall mean to put into use or place in final position said services, materials, or equipment complete and ready for intended use. 3. The words "perform" or "provide," when used in connection with services, materials, or equipment, shall mean to furnish and install said services, materials, or equipment complete and ready for intended use. 4. Regardless of whether "furnish," "install," "perform," or "provide" is used in connection with services, materials, or equipment, an obligation of Design -Build Entity is implied. 5. Unless stated otherwise in the Contract Documents, words or phrases that have a well-known technical or construction industry or trade meaning are used in the Contract Documents in accordance with such recognized meaning. ARTICLE 2 - PRELIMINARY MATTERS 2.1 Delivery of Contract Documents. Within fifteen (15) Days after receipt of the Notice of Award and before Agency will execute the Contract, the Design -Build Entity shall furnish and file with Agency a signed Contract in duplicate and the necessary Performance Bond, Payment Bond, Certificates of Insurance and Endorsements, Escrow Agreement (if used) and Tax Identification Number, as well as any other documents specified in the Contract Documents. Notwithstanding the foregoing, if the Contract Price has yet to be established at Notice of Award, then the Performance Bond and Payment Bond may be provided after establishing the Contract Price and prior to the Construction Phase. A2-16 2.2 Bonds. Design -Build Entity shall submit the bonds on the forms provided with the Contract Documents, duly executed by a responsible corporate surety admitted to transact surety business in the State of California, as defined in Code of Civil Procedure section 995.120, and listed in the United States Department of the Treasury circular entitled "Companies Holding Certificates of Authority as Acceptable Sureties on Federal Bonds and as Acceptable Reinsuring Companies," authorized to do business in the State of California and acceptable to Agency conditioned upon the faithful performance by the Design -Build Entity of all requirements of the Contract Documents. Each of the bonds shall be in a sum no less than one hundred percent (100%) of the Contract Price. 2.3 Evidence of Insurance. Design -Build Entity shall obtain, at its sole cost and expense, all insurance required by Article 5. Certificates of such insurance and copies of the insurance policies and endorsements shall be delivered to Agency within fifteen (15) Days after receipt of the Notice of Award and before execution of the agreement for construction by Agency. 2.4 Execution of Contract. Upon receipt of the required Contract Documents, Agency will execute the Contract, establishing the Effective Date of the Contract. 2.5 Commencement of Contract Times: Notice to Proceed with Construction. The Agency will not issue a Notice to Proceed until after the Effective Date of the Contract. Construction Work shall commence within fifteen (15) Days of the date stated in Agency's Notice to Proceed with Construction. No Construction Work shall be done at the Site prior to the date on which the Contract Time commence to run. Nothing herein shall affect the Project Completion Date. 2.6 Copies of Documents. Agency will furnish to Design -Build Entity one (1) copy of the Bridging Documents. Additional copies will be furnished upon request at the cost of reproduction. 2.7 Preconstruction Conference; Designation of Authorized Representatives. Before any Work at the Project site is started, a conference attended by Agency, Design - Build Entity, Agency's Representative, and others as appropriate will be held to establish a working understanding among the parties as to the Work and to discuss the schedules referred to herein, procedures for handling Shop Drawings and other submittals, processing Applications for Payment, and maintaining required records. 2.8 Initial Acceptance of Schedules. At least ten (10) Days before submission of the first Application for Payment, a conference attended by Design -Build Entity, Agency's Representative, and others as appropriate will be held to review for acceptability to Agency's Representative the schedules submitted, as required by the Contract Documents. Design -Build Entity shall A2-17 have an additional ten (10) Days to make corrections and adjustments and to complete and resubmit the schedules. No progress payment shall be made to Design -Build Entity until acceptable schedules are submitted to Agency's Representative. Acceptance of the schedules by Agency's Representative will not impose on responsibility for accuracy, for sequencing, scheduling, or progress of the Work, or compliance with the Contract Documents. Acceptance will not interfere with or relieve Design -Build Entity from Design -Build Entity's full responsibility therefor. ARTICLE 3 - CONTRACT DOCUMENTS: INTENT, AMENDING, REUSE 3.1 Intent. A. The Contract Documents are complementary; what is required by one is as binding as if required by all. It is the intent of the Contract Documents to describe a functionally complete Project (or part thereof) to be designed and constructed in accordance with the Contract Documents. Any labor, documentation, services, materials, or equipment that reasonably may be inferred from the Contract Documents or from prevailing custom or trade usage as being required to produce the indicated result will be provided whether or not specifically called for, at no additional cost to Agency. Clarifications and interpretations of the Contract Documents shall be issued by Agency's Representative as provided in these General Conditions. B. If utilities to equipment/fixtures are not shown but are necessary to operate the equipment/fixtures, the utilities service installation is considered to be part of the Work. The implied Work will conform to the appropriate sections of the Contract Documents. C. Organization of the Contract Documents into divisions, sections, and articles, and arrangement of drawings shall not control the Design -Build Entity in dividing Work among Subcontractors or in establishing the extent of Work to be performed by any trade. 3.2 Standards, Specifications, Codes, Laws, and Regulations. A. Reference to federal specifications, federal standards, other standards, specifications, manuals, or codes of any technical society, organization, or association, or to Applicable Laws, whether such reference be specific or by implication, shall mean the standard, specification, manual, code, or Applicable Laws in effect at the time of opening of proposals (or on the Effective Date of the Contract if there were no proposals), except as may be otherwise specifically stated in the Contract Documents. B. No provision of any such standard, specification, manual, or code, or any instruction of a supplier, shall be effective to change the duties or responsibilities of Agency, Design -Build Entity, or Agency's Representative, or any of their Subcontractors, consultants, agents, or employees, from those set forth in the Contract Documents. No such provision or instruction shall be effective to assign to Agency or Agency's Representative, or any of their officers, directors, members, partners, employees, agents, consultants, or subcontractors, any duty or authority to supervise or direct A2-18 the performance of the Work or any duty or authority to undertake responsibility inconsistent with the provisions of the Contract Documents. 3.3 Order of Precedence. A. The intent of the Contract Documents is to include all necessary criteria to establish the scope and quality for completion of the Work on the Project by the Design -Build Entity. The Contract Documents are complementary and what is required by one shall be as binding as if required by all. Performance by the Design -Build Entity shall be required to the extent consistent with, and reasonably inferable from, the Contract Documents. B. Except as may be otherwise specifically stated in the Contract Documents, the provisions of the Contract Documents shall take precedence in resolving any conflict, error, ambiguity, or discrepancy between the provisions of the Contract Documents and the provisions of any standard, specification, manual, or code, or the instruction of any Supplier (whether or not specifically incorporated by reference in the Contract Documents); or the provisions of any Applicable Laws (unless such an interpretation of the provisions of the Contract Documents would result in violation of such Applicable Law). C. In resolving conflicts among any of the Contract Documents, the order of precedence shall be as follows: 1. Permits from other agencies as may be required by law; 2. Change Orders or Pending Change Orders, most recent first; 3. Design -Build Contract; 4. Special Conditions; 5. General Conditions; 6. RFP and all addenda, attachments and appendices; 7. Design -Build Entity Proposal in response to RFP; 8. Construction Documents prepared by Design -Build Entity; and 9. Drawings prepared by Design -Build Entity. D. With reference to the Drawings the order of precedence shall be as follows: 1. Figures govern over scaled dimensions; 2. Detail drawings govern over general drawings; 3. Change Order drawings govern over Drawings; and 4. Drawings govern over standard drawings. A2-19 E. Notwithstanding the orders of precedence established above, in the event of conflicts, the higher standard, higher quality and most expensive shall always apply. 3.4 Amending and Supplementing Contract Documents. The Contract Documents may be amended to provide for additions, deletions, and revisions in the Work or to modify the terms and conditions thereof only by a Change Order. 3.5 Interpretation and Use of Contract Documents. A. Agency and the Design -Build Entity acknowledge that the Contract Documents may differ in some respect(s) from the other documents included in the RFP upon which the Design -Build Entity based its Proposal. Prior to the commencement of construction on the Project, the parties shall confirm, in writing, the final form of the Contract Documents that are to be utilized. Specifically, once approved by Agency, the Construction Documents become a part of the Contract Documents and define the entire scope of work, so long as such documents incorporate all minimum requirements of the Bridging Documents, unless otherwise agreed to by the parties. The Design -Build Entity shall certify that the Construction Documents are in full compliance with the Contract Documents, except as noted. B. Organization of the Performance Specifications into various subdivisions and the arrangement of the Drawings shall not control the Design -Build Entity in dividing portions of the Work necessary for the Project among Subcontractors or in establishing the extent of Work to be performed by any trade. C. Unless otherwise stated in the Contract Documents, technical words and abbreviations contained in the Contract Documents are used in accordance with commonly understood design professional and construction industry meanings; nontechnical words and abbreviations are used in accordance with their commonly understood meanings. D. The Contract Documents may omit modifying words such as "all" and "any," and articles such as "the" and "an," but the fact that a modifier or an article is absent from one statement and appears in another is not intended to affect the interpretation of either statement. The use of the word "including," when following any general statement, shall not be construed to limit such statement to specific items or matters set forth immediately following such word or to similar items or matters, whether or not non limiting language (such as "without limitation," "but not limited to," or words of similar import) is used with reference thereto, but rather shall be deemed to refer to all other items or matters that could reasonably fall within the broadest possible scope of such general statement. E. Whenever the context so requires, the use of the singular number shall be deemed to include the plural and vice versa. Each gender shall be deemed to include any other gender, and each shall include a corporation, partnership, trust, or other legal entity, whenever the context so requires. The captions and headings of the various subdivisions of the Contract Documents are intended only for reference and convenience and in no way define, limit, or prescribe the scope or intent of the Contract Documents or any subdivision thereof. A2-20 F. Each and every provision of law required by law to be inserted in the Contract Documents shall be deemed to be inserted herein, and the Contract Documents shall be read and enforced as though it were included herein, and if through mistake or otherwise any such provision is not inserted, or is not correctly inserted, then upon application of either party the Contract shall be amended in writing to make such insertion or correction. G. Before commencing any Work on the Project, the Design -Build Entity shall check and review the Contract Documents, including the Construction Documents, for conformance and compliance with all laws, ordinances, codes, rules and regulations of all governmental authorities and public utilities affecting the construction and operation of the physical plant of the Project, all quasi -governmental and other regulations affecting the construction and operation of the physical plant of the Project, and other special requirements, if any, designated in the Contract. In the event the Design -Build Entity observes any violation of any law, ordinance, code, rule or regulation, or inconsistency with any such restrictions or special requirements of the Contract, the Design -Build Entity shall immediately notify Agency's Representative in writing of the same and shall cause to be corrected any such violation or inconsistency in the manner provided hereunder. The Design -Build Entity shall be solely liable for any such violation, inconsistency or special requirement, if Design -Build Entity fails to conduct such review or notification to Agency. H. Before commencing any Work on the Project, the Design -Build Entity shall carefully examine all Performance Specifications, the Contract, the Contract Documents and other information given to the Design -Build Entity as to Project requirements. The Design -Build Entity shall immediately notify Agency's Representative of any perceived or alleged error, inconsistency, ambiguity, or lack of detail or explanation in such documents in writing. Neither the Design -Build Entity nor any Subcontractor shall take advantage of any apparent error or omission which may be found in the Performance Specifications, the Contract, the Contract Documents or other information given to Design -Build Entity. If the Design -Build Entity or its Subcontractors, material or equipment suppliers, or any of their officers, agents, and employees performs, permits, or causes the performance of any Work under the Contract, which it knows or should have known to be in error, inconsistent, or ambiguous, or not sufficiently detailed or explained, the Design -Build Entity shall bear any and all costs arising therefrom including, without limitation, the cost of correction thereof without increase or adjustment to the Contract Price or the Project Completion Date. In no case shall any Subcontractor proceed with Work if uncertain without the Design -Build Entity's written direction and/or approval. 3.6 Reuse of Documents. Design -Build Entity and any Subcontractor shall not: have or acquire any title to or Ownership rights in any of the Construction Documents or other documents (or copies of any thereof) prepared by or bearing the seal of the A/E or its consultants, including electronic media editions; or reuse of any such Construction Documents, other documents, or copies thereof on extensions of the Project or any other project without written consent of Agency and A/E and specific written verification or adaptation by the A/E. The prohibitions of this Article will survive final payment, or termination of the A2-21 Contract. Nothing herein shall preclude Design -Build Entity from retaining copies of the Contract Documents for record purposes. 3.7 Electronic Data. A. The data furnished by Agency or Agency's Representative to Design -Build Entity, or by Design -Build Entity to Agency or Agency's Representative, that may be relied upon are limited to the printed copies (also known as hard copies). Files in electronic media format of text, data, graphics, or other types are furnished only for the convenience of the receiving party. Any conclusion or information obtained or derived from such electronic files will be at the user's sole risk. If there is a discrepancy between the electronic files and the hard copies, the hard copies govern. B. Because data stored in electronic media format can deteriorate or be modified inadvertently or otherwise without authorization of the data's creator, the party receiving electronic files agrees that it will perform acceptance tests or procedures within sixty (60) Days, after which the receiving party shall be deemed to have accepted the data thus transferred. Any errors detected within the 60-Day acceptance period will be corrected by the transferring party. C. When transferring documents in electronic media format, the transferring party makes no representations as to long term compatibility, usability, or readability of documents resulting from the use of software application packages, operating systems, or computer hardware differing from those used by the data's creator. 3.8 Ownership and Use of Construction Documents. The Construction Documents, and all copies thereof, furnished to, or provided by, the Design -Build Entity are the property of Agency. Agency and the Design -Build Entity explicitly agree that all materials and documents developed in the performance of this Contract are the property of Agency pursuant to the requirements of Agency. Agency shall have unlimited rights, for the benefit of Agency, in all drawings, designs, technical specifications, notes and any other documentation and other Work developed in the performance of this Contract for the Project, including the right to re -use details of the Design on any other Agency Work at no additional cost to Agency. The Design -Build Entity agrees to, and hereby does, grant to Agency a royalty free license to all such data that the Design -Build Entity may cover by copyright and to all designs as to which the Design -Build Entity may assert any right or establish any claim to under the patent or copyright laws. The Design -Build Entity, for a period up to five (5) years from the date of Completion of the Project, agrees to furnish and to provide access to the originals or copies of all such materials immediately upon the written request of Agency. Any use or reuse by Agency of the Construction Documents on any project other than this Project without employing the services of the Design -Build Entity shall be at Agency's own risk with respect to third parties. If Agency uses or re -uses the Construction Documents on any project other than this Project, it shall remove the A/E's seal from the Construction Documents and hold harmless Design -Build Entity, A/E, and their officers, directors, agents and employees from claims arising out of the use or re -use of the Construction Documents on such other project. Design -Build Entity shall not be responsible or liable for any revisions to the Construction Documents made by any party other than the A2-22 Design -Build Entity, a party for which the Design -Build Entity is legally responsible or liable, or anyone approved by the Design -Build Entity. 3.9 Administration of the Contract by Aciencv's Representative. A. During the term of this Design -Build Contract, Agency's Representative shall have the right to review the Design -Build Entity's Work at such intervals as deemed appropriate by Agency's Representative. However, no actions taken during such review or site visit by Agency's Representative shall relieve the Design -Build Entity of any of its obligations of single point responsibility for the design and construction of this Project nor form the basis for a Claim if such actions extend beyond the Project Completion Date. B. Agency's Representative will not have control over, will not be in charge of, and will not be responsible for design or construction means, methods, techniques, sequences, or procedures, or for safety precautions and programs in connection with the Work on the Project, since these are solely the Design -Build Entity's responsibility. C. Except as otherwise provided in the Contract Documents or when direct communications have been specifically authorized, Agency and the Design -Build Entity shall communicate through Agency's Representative. Communications by the Design -Build Entity with Agency's consultants and Agency's Representative's consultants shall be through Agency's Representative. Communications by Agency and Agency's Representative with Subcontractors will be through the Design -Build Entity. Communications by the Design -Build Entity and Subcontractors with Separate Contractors shall be through Agency's Representative. The Design -Build Entity shall not rely on oral or other non -written communications. D. Based on Agency's Representative's Project site visits, review of the Work, and evaluations of the Design -Build Entity's Applications for Payment, Agency's Representative will recommend amounts, if any, due the Design -Build Entity and will issue Certificates for Payment in such amounts. E. Agency's Representative will have the authority to reject Work on the Project, or any portion thereof, which does not conform to the Contract Documents. Agency's Representative will have the authority to stop Work on the Project, or any portion thereof. Whenever Agency's Representative considers it necessary, or advisable, for implementation of the intent of the Contract Documents, Agency's Representative will have the authority to require additional inspection or testing of the Work on the Project in accordance with the Contract Documents, whether or not such Work is fabricated, installed, or completed. However, no authority of Agency's Representative conferred by the Contract Documents nor any decision made in good faith either to exercise, or to not exercise such authority, will give rise to a duty or responsibility of Agency or Agency's Representative to the Design -Build Entity, or any person or entity claiming under, or through, the Design -Build Entity. F. Agency's Representative will have the authority to conduct inspections in connection with beneficial occupancy and to determine the dates of Completion; will receive for review and approval any records, written warranties, and related documents required by the Contract Documents and assembled by the Design -Build Entity; and will issue A2-23 a final Certificate for Payment upon the Design -Build Entity's compliance with the requirements of the Contract Documents. G. Agency's Representative will be, in the first instance, the interpreter of the requirements of the Contract Documents and the judge of performance thereunder by the Design -Build Entity. Should the Design -Build Entity discover any conflicts, omissions, or errors in the Construction Documents or the Contract Documents; have any questions about the interpretation or clarification of the Contract Documents; question whether Work is within the scope of the Contract Documents; then, before proceeding with the Work affected, the Design -Build Entity shall notify Agency's Representative in writing and request interpretation, or clarification. Agency's Representative's response to questions and requests for interpretations, clarifications, instructions, or decisions will be made with reasonable promptness. Should the Design -Build Entity proceed with the Work affected before receipt of a response from Agency's Representative, any portion of the Work on the Project which is not done in accordance with Agency's Representative's interpretations, clarifications, instructions, or decisions shall be removed or replaced and the Design - Build Entity shall be responsible for all resultant losses. H. Agency may at any time and from time to time, without prior notice to or approval of the Design -Build Entity, replace Agency's Representative with a new Agency Representative. Upon receipt of notice from Agency informing the Design -Build Entity of such replacement and identifying the new Agency's Representative, the Design -Build Entity shall recognize such person or firm as Agency's Representative for all purposes under the Contract Documents. ARTICLE 4 - AVAILABILITY AND OWNERSHIP OF LANDS AND MATERIALS; HAZARDOUS ENVIRONMENTAL CONDITIONS; REFERENCE POINTS 4.1 Availability of Lands. Agency shall furnish the Project site. Agency shall notify Design -Build Entity of any encumbrances or restrictions not of general application but specifically related to use of the Project site with which Design -Build Entity must comply in performing the Work. Agency will obtain in a timely manner and pay for easements for permanent structures or permanent changes in existing facilities. Design -Build Entity shall provide for all additional lands and access thereto that may be required for temporary construction facilities or storage of materials and equipment at no additional cost to Agency. 4.2 Ownership of Site Materials Found. The title to water, soil, rock, gravel, sand, minerals, timber and any other materials developed or obtained in the excavation or other operations of Design -Build Entity or any of its Subcontractors in the performance of the Contract, and the right to use said items in carrying out the Contract, or to dispose of same, is hereby expressly reserved by Agency. Neither Design -Build Entity nor any of its Subcontractors nor any of their representatives or employees shall have any right, title, or interest in said materials, nor shall they assert or make any claim thereto. Design -Build Entity will, as determined by Agency's Representative, be permitted to use in the Work without charge, any such materials which meet the requirements of the Contract Documents, provided Agency shall have the right to use or consume these materials without payment to a third party. A2-24 4.3 Hazardous Material at Site. A. The Design -Build Entity shall have no responsibility for detection, abatement, remediation, removal or disposal of any Hazardous Material, except Hazardous Materials introduced onto the Project Site by the Design -Build Entity, its employees, subcontractors, agents, or other parties acting on behalf of the Design -Build Entity. In the event that the Design -Build Entity becomes aware of the presence of, or exposure of persons to, any Hazardous Material at the Project Site, the Design -Build Entity shall inform Agency by notice immediately. Notwithstanding anything to the contrary herein, the Design -Build Entity shall not be responsible for, and the Agency shall bear full responsibility and remediation costs relating to any Hazardous Materials uncovered, removed or disturbed by the Design -Build Entity on the Project Site resulting from the Design -Build Entity's performance of the work hereunder, except Hazardous Materials introduced onto the Project Site by the Design -Build Entity, its employees, subcontractors, agents, or other parties acting on behalf of the Design -Build Entity. The Agency shall not be responsible for, and the Design -Build Entity shall bear full responsibility and remediation costs relating to any Hazardous Materials introduced onto the Project Site by the Design -Build Entity, its employees, subcontractors, agents, or other parties acting on behalf of the Design -Build Entity. B. The Design -Build Entity hereby specifically agrees to indemnify, defend and hold the Agency, its present and future directors, officers, employees, agents, representatives, successors and assigns harmless from and against any and all losses, liabilities, claims, demands, damages, causes of action, fines, penalties, costs and expenses (including, but not limited to, all reasonable consulting, engineering, attorneys' or other professional fees), that they may incur or suffer by reason of: (a) the existence, uncovering or unveiling, or any release by the Agency or Design -Build Entity of, a Hazardous Material introduced onto the Project Site by the Design -Build Entity, its employees, subcontractors, agents, or other parties acting on behalf of the Design -Build Entity; (b) any enforcement or compliance proceeding commenced by or in the name of any governmental authority because of the presence on the Project Site of Hazardous Materials introduced onto the Project Site by the Design -Build Entity, its employees, subcontractors, agents, or other parties acting on behalf of the Design -Build Entity; and (c) any action reasonably necessary to abate, remediate or prevent a violation or threatened violation of any Hazardous Material laws by the Design -Build Entity. 4.4 Protection and Restoration of Existing Improvements and Reference Points. Design -Build Entity shall be responsible for laying out the Work, shall protect and preserve the established reference points and property monuments, and shall make no changes or relocations without the prior written approval of Agency. Design -Build Entity shall report to Agency's Representative whenever any reference point or property monument is lost or destroyed or requires relocation because of necessary changes in grades or locations, and shall be responsible for the accurate replacement or relocation of such reference points or property monuments by professionally qualified personnel. ARTICLE 5 - BONDS AND INSURANCE 5.1 Time for Compliance. A2-25 Design -Build Entity shall not commence Work under this Contract until it has provided evidence to Agency that it has secured all insurance required under this Article. Design - Build Entity shall require and verify that all subconsultants and subcontractors maintain insurance meeting all the requirements stated herein. Design -Build Entity shall not allow any subconsultant or subcontractor to commence work on any subcontract until it has provided evidence to Agency that the subconsultant or subcontractor has secured all insurance required under this Article. 5.2 Minimum Reauirements. Design -Build Entity shall, at its expense, procure and maintain for the duration of the Contract insurance against claims for injuries to persons or damages to property which may arise out of or result from the performance of the Work and Design -Build Entity's other obligations under the Contract Documents whether by Design -Build Entity, its agents, representatives, employees or subcontractors. Design -Build Entity shall also require all of its subconsultants and subcontractors to procure and maintain the same insurance for the duration of the Contract and verify the subconsultants' and subcontractors' compliance. Design -Build Entity's and subconsultants' and subcontractors' insurance shall meet at least the minimum levels of coverage set forth in this Article: A. Minimum Scope of Insurance. Coverage shall be at least as broad as the latest version of the following: (1) General Liability: Insurance Services Office Commercial General Liability coverage (occurrence form CG 0001); (2) Automobile Liability: Insurance Services Office Business Auto Coverage form number CA 0001, code 1 (any auto) or if Design -Build Entity has no owned autos, non -owned, leased or hired autos Code 8 (hired) and Code 9 (non -owned); (3) Workers' Compensation and Employer's Liability: Workers' Compensation insurance as required by the State of California and Employer's Liability Insurance; (4) Installation Floater/Builder's Risk: "All Risk All Perils" form; and (5) Professional Liability/Errors and Omissions. The policies shall not contain any exclusion contrary to the Contract, including but not limited to endorsements or provisions limiting coverage for (1) contractual liability or (2) cross liability for claims or suits by one insured against another. B. Minimum Limits of Insurance. The Design -Build Entity shall maintain limits no less than: 1. For Commercial General Liability, Design -Build Entity shall have limits of at least the amount that corresponds to the Contract Price in the following table: Contract Price $ 0 $ 2 million $ 5 million $10 million - $ 2 million - $ 5 million - $ 10 million - $ 20 million A2-26 Amount of Liability Insurance (per occurrence) $ 2 million $ 3 million $ 5 million $10 million If Commercial General Liability Insurance or other form with general aggregate limit is used including, but not limited to, form CG 25 03, either the general aggregate limit shall apply separately to the Project or the general aggregate limit shall be twice the required occurrence limit. Should any of the Work involve aircraft (fixed wing or helicopter) owned or operated by Design -Build Entity, liability insurance with limits of not less than $5,000,000 per occurrence for bodily injury and property damage is required. Should any of the Work involve watercraft owned or operated by Design -Build Entity, liability insurance with limits of not less than $5,000,000 per occurrence for bodily injury and property damage is required. 2. Automobile Liability: $1 million per accident for bodily injury and property damage. 3. Workers' Compensation and Employer's Liability: a. Workers' Compensation: statutory limits. b. Employer's Liability limits of $1 million per accident for bodily injury or disease. c. Should any of the Work be upon or contiguous to navigable bodies of water, Design -Build Entity shall carry insurance covering its employees for benefits available under the Federal Longshoremen's and Harbor Worker's Act to the extent required by law; 4. Excess/Umbrella Liability Policy may be provided to insure the total limits required for Commercial General Liability and Automobile Liability and must apply to all primary coverage afforded, including but not limited to general liability, owned and non -owned automobiles, leased and hired cars. 5. Professional Liability/Errors and Omissions: $2,000,000 per claim. C. Notices; Cancellation or Reduction of Coverage. At least fifteen (15) Days prior to the expiration of any such policy, evidence showing that such insurance coverage has been renewed or extended shall be filed with Agency. If such coverage is cancelled or materially reduced, Design -Build Entity shall, within ten (10) Days after receipt of written notice of such cancellation or reduction of coverage, file with Agency evidence of insurance showing that the required insurance has been reinstated or has been provided through another insurance company or companies. In the event any policy of insurance required under this Contract does not comply with these specifications or is canceled and not replaced, Agency has the right but not the duty to obtain the insurance it deems necessary and any premium paid by Agency will be promptly reimbursed by Design - Build Entity or Agency may withhold amounts sufficient to pay premium from Design - Build Entity payments. In the alternative, Agency may suspend or terminate this Contract. 5.3 Insurance Endorsements. A2-27 The insurance policies shall contain the following provisions, or Design -Build Entity shall provide endorsements on forms approved by Agency to add the following provisions to the insurance policies: A. General Liability. The general liability policy shall include or be endorsed (amended) to state that: (1) using ISO CG forms 20 10 and 20 37 (including completed operations), or endorsements providing the exact same coverage, Agency, its officials, officers, employees, agents, and volunteers and any other additional insureds named in the Special Conditions shall be covered as additional insureds with respect to the Work or ongoing and completed operations performed by or on behalf of the Design -Build Entity, including materials, parts or equipment furnished in connection with such work; and (2) using ISO form 20 01, or endorsements providing the exact same coverage, the insurance coverage shall be primary insurance as respects Agency, its officials, officers, employees, agents, and volunteers and any other additional insureds named in the Special Conditions, or if excess, shall stand in an unbroken chain of coverage excess of the Design -Build Entity's scheduled underlying coverage. Any excess insurance shall contain a provision that such coverage shall also apply on a primary and noncontributory basis for the benefit of Agency, before Agency's own primary insurance or self-insurance shall be called upon to protect it as a named insured. Any insurance or self-insurance maintained by Agency, its officials, officers, employees, agents, and volunteers and any other additional insureds named in the Special Conditions shall be excess of the Design -Build Entity's insurance and shall not be called upon to contribute with it in any way. B. Automobile Liability. The automobile liability policy shall include or be endorsed (amended) to state that: (1) Agency, its officials, officers, employees, agents, and volunteers and any other additional insureds named in the Special Conditions shall be covered as additional insureds with respect to the ownership, operation, maintenance, use, loading or unloading of any auto owned, leased, hired or borrowed by the Design -Build Entity or for which the Design -Build Entity is responsible; and (2) the insurance coverage shall be primary insurance as respects Agency, its officials, officers, employees, agents, and volunteers and any other additional insureds named in the Special Conditions, or if excess, shall stand in an unbroken chain of coverage excess of the Design -Build Entity's scheduled underlying coverage. Any insurance or self-insurance maintained by Agency, its officials, officers, employees, agents, and volunteers and any other additional insureds named in the Special Conditions shall be excess of the Design - Build Entity's insurance and shall not be called upon to contribute with it in any way. C. Workers' Compensation and Employer's Liability Coverage. The insurer shall agree, using WC 00 03 13 or the exact equivalent, to waive all rights of subrogation against Agency, its officials, officers, employees, agents, and volunteers and any other additional insureds named in the Special Conditions for losses paid under the terms of the insurance policy. D. Professional Liability/Errors and Omissions. A2-28 Professional Liability Insurance insuring the A/E, its officers, directors, stockholders, employees, agents, or partner, and all other persons for whose acts the NE may be liable, against any and all liabilities arising out of or in connection with the negligent acts, errors or omissions of any of the foregoing in connection with the carrying out of their professional responsibilities described in this Contract. Professional Liability Insurance shall remain in full force and effect, and shall be so certified to Agency by the insurer, for a period of five (5) years after the completion of all of the Design - Build Entity's services hereunder and Agency's acceptance of the Project. All subconsultants shall have professional liability insurance with the same limits (additional requirements for Professional Liability/Errors and Omissions Insurance written on a "claims made" basis are set forth below). E. All Coverages. Each insurance policy required by this Agreement shall be endorsed to include the following provisions: 1. Coverage shall not be suspended, voided, reduced or canceled except after thirty (30) Days (10 Days for nonpayment of premium) prior written notice by mail has been given to Agency and all additional insureds. 2. Any failure to comply with reporting or other provisions of the policies, including breaches of warranties, shall not affect coverage provided to Agency and any other additional insureds. 3. Standard separation of insureds provisions. 4. No special limitations on the scope of protection afforded to Agency, its officials, officers, employees, agents, and volunteers and any other additional insureds named in the Special Conditions. 5. Waiver of any right of subrogation of the insurer against Agency, its officials, officers, employees, agents, and volunteers, or any other additional insureds, or shall specifically allow the Design -Build Entity or others providing insurance in compliance with these specifications to waive their right of recovery prior to a loss. By signing this agreement, the Design -Build Entity hereby waives its own right of recovery against Agency or any other additional insureds, and shall require similar written express waivers and insurance clauses from each of its subconsultants and subcontractors. 5.4 Builder's Risk f"All Risk"1. Reserved. 5.5 Pollution Liability Insurance. Pollution Liability Insurance is required should any of the Project involve pollutants. Liability coverage shall include coverage for the environmental risk associated with the project and expenses related to such, including bodily injury, property damage, on and offsite clean-up, transporting, carrying, or storing pollutants, coverage for non -owned disposal site in an amount not less than that set forth in the Special Conditions. A2-29 Pollutants include, but are not limited to, asbestos, mold, microbial matter, solid, liquid, gaseous or thermal irritants or contaminants, including smoke, vapor, soot, fumes, acids, alkalis, chemicals, and waste. Waste includes materials to be recycled, reconditioned, or reclaimed. 5.6 Receipt and Application of Insurance Proceeds. Any insured loss under the policies of insurance required herein will be adjusted with Agency and made payable to Agency as fiduciary for the loss payees, as their interests may appear, subject to the requirements of any applicable mortgage clause and of the provisions herein. Agency shall deposit in a separate account any money so received and shall distribute it in accordance with such agreement as the parties in interest may reach. If no other special agreement is reached, the damaged Work shall be repaired or replaced, the moneys so received applied on account thereof, and the Project and the cost thereof covered by an appropriate Change Order. Agency as fiduciary shall have power to adjust and settle any loss with the insurers unless one of the parties in interest shall object in writing to Agency's exercise of this power within fifteen (15) Days after the occurrence of loss. If such objection be made, Agency as fiduciary shall make settlement with the insurers in accordance with such agreement as the parties in interest may reach. If no such agreement among the parties in interest is reached, Agency as fiduciary shall adjust and settle the loss with the insurers and, if required in writing by any party in interest, Agency as fiduciary shall give bond for the proper performance of such duties. 5.7 Partial Utilization, Acknowledgement of Property Insurer. If Agency finds it necessary to occupy or use a portion or portions of the Project prior to Completion of all the Work, no such use or occupancy shall commence before the insurers providing the property insurance have acknowledged notice thereof and in writing effected any changes in coverage necessitated thereby. The insurers providing the property insurance shall consent by endorsement on the policy or policies, but the property insurance shall not be canceled or permitted to lapse on account of any such partial use or occupancy. 5.8 Deductibles and Self -Insurance Retentions. Any deductibles or self -insured retentions must be declared to and approved by Agency. Design -Build Entity shall guarantee that, at the option of Agency, either: (1) the insurer shall reduce or eliminate such deductibles or self -insured retentions as respects Agency, its officials, officers, employees, agents, and volunteers and any other additional insureds named in the Special Conditions; or (2) the Design -Build Entity shall procure a bond guaranteeing payment of losses and related investigation costs, claims, and administrative and defense expenses. 5.9 Claims Made Policies. Claims made policies are not acceptable other than for Professional Liability. In addition to the requirements above, for any claims made policy: The Retroactive Date must be shown and must be before the date of the Contract or the beginning of contract work; Insurance must be maintained and evidence of insurance must be provided for at least five (5) years after Agency's acceptance of the Work; and If coverage is canceled or A2-30 non -renewed, and not replaced with another claims -made policy form with a Retroactive Date prior to the contract effective date, the Design -Build Entity must purchase "extended reporting" coverage for a minimum of five (5) years after Agency's acceptance of the Work. 5.10 Subcontractor Insurance Requirements. Design -Build Entity shall not allow any Subcontractors to commence work on any subcontract relating to the Work until Design -Build Entity has verified that all Subcontractors maintain insurance meeting all requirements under this Section and has provided evidence to Agency of such insurance. For Commercial General Liability coverage Subcontractors shall provide coverage naming Agency, its officials, officers, employees, agents, and volunteers with a format at least as broad as CG 20 38 04 13. If requested by Design -Build Entity, Agency may approve different scopes or minimum limits of insurance for particular Subcontractors. Design -Build Entity shall confirm that Agency shall be named as additional insureds on all Subcontractors' policies of Commercial General Liability Insurance and Commercial Automobile Insurance. 5.10 Acceptability of Insurers. Insurance is to be placed with insurers with a current A.M. Best's rating no less than A:VIII, licensed to do business in California, and satisfactory to Agency. 5.11 Verification of Coverage. Design -Build Entity shall furnish Agency with original certificates of insurance and endorsements effecting coverage required by this Contract on forms satisfactory to Agency. The certificates and endorsements for each insurance policy shall be signed by a person authorized by that insurer to bind coverage on its behalf. All certificates and endorsements must be received and approved by Agency before work commences. Agency reserves the right to require complete, certified copies of all required insurance policies, at any time. 5.12 Reservation of Rights. Agency reserves the right to modify these requirements, including limits, based on the nature of the risk, prior experience, insurer, coverage, or other special circumstances. 5.13 Performance Bond and Payment Bond. A. The Design -Build Entity shall submit performance and payment bonds on the forms provided with the Contract Documents, duly executed by a responsible corporate surety admitted to transact surety business in the State of California, as defined in Code of Civil Procedure Section 995.120, and listed in the United States Department of the Treasury circular entitled "Companies Holding Certificates of Authority as Acceptable Sureties on Federal Bonds and as Acceptable Reinsuring Companies," authorized to do business in the State of California and acceptable to Agency conditioned upon the faithful performance by the Design -Build Entity of all requirements of the Contract Documents. Each of the bonds shall be in a sum no less than one hundred percent (100%) of the Contract Price. The Design -Build Entity shall furnish bonds covering the faithful performance of the Contract (Performance A2-31 Bond) and payment of obligations arising thereunder (Payment Bond) on the forms contained in the Contract. The obligations of the performance bond surety shall continue so long as any obligation of Design -Build Entity remains. Nothing herein shall limit the Agency's rights or the Design -Build Entity's or surety's obligations under the Contract, law or equity, including, but not limited to, California Code of Civil Procedure section 337.15. B. The Payment Bond and Performance Bond shall be in effect on the date the Contract is signed by Agency. The Design -Build Entity shall promptly furnish such additional security as may be required by Agency to protect its interests and those interests of persons or firms supplying labor or materials to the Project. The premiums for the Payment Bond and Performance Bond shall be paid by the Design -Build Entity. The Design -Build Entity maintains and agrees that it has executed Payment and Performance Bonds in the amounts and manner required by the Contract Documents. No payment will be made to the Design -Build Entity until the Design - Build Entity's Payment Bond and Performance Bond have been approved by Agency. C. Should, in Agency's sole opinion, any bond become insufficient or surety found to be unsatisfactory, the Design -Build Entity shall renew or replace the effected bond within 10 Days of receiving notice from Agency. In the event the surety or the Design -Build Entity intends to reduce or cancel any required bonds, at least thirty (30) Days prior written notice shall be given to Agency, and the Design -Build Entity shall post acceptable replacement bonds at least ten (10) Days prior to expiration of the original bonds. No further payments shall be deemed due or will be made under this Contract until any replacement bonds required by this Article are accepted by Agency. D. To the extent, if any, that the Contract Price is increased in accordance with the Contract, the Design -Build Entity shall, upon request of Agency, cause the amount of the bonds to be increased accordingly and shall promptly deliver satisfactory evidence of such increase to Agency. The bonds shall further provide that no change or alteration of the Contract (including, without limitation, an increase in the Contract Price, as referred to above), extensions of time, or modifications of the time, terms, or conditions of payment to the Design -Build Entity will release the surety. If the Design -Build Entity fails to furnish any required bond, Agency may terminate the Contract for cause. ARTICLE 6 - DESIGN -BUILD ENTITY'S RESPONSIBILITIES 6.1 Design -Build Entity Responsibility: Independent Contractor. The Design -Build Entity shall be responsible to Agency for acts and omissions of the Design -Build Entity's employees, Subcontractors, material and equipment suppliers, and their agents, employees, invitees, and other persons performing portions of Work on the Project under direct or indirect contract with the Design -Build Entity or any of its Subcontractors. Agency retains the Design -Build Entity on an independent contractor basis. Design -Build Entity retains the right to perform similar or different services for others during the term of this Contract. The Design -Build Entity is not an employee, agent or representative of Agency. The Design -Build Entity represents that it is fully experienced and properly qualified to perform the class of Work provided for in this A2-32 Contract and that it is properly licensed, equipped, organized, and financed to perform Work on the Project. Neither Agency, nor any of its officials, officers, directors, employees or agents shall have control over the conduct of Design -Build Entity or any of Design -Build Entity's officers, employees, or agents, except as set forth in this Contract. The Design -Build Entity shall maintain complete control over its employees and its Subcontractors and shall pay all wages, salaries and other amounts due such personnel in connection with their performance as required by law. The Design -Build Entity shall be responsible for all reports and obligations respecting such personnel, including but not limited to, social security taxes, income tax withholdings, unemployment insurance, and workers' compensation insurance. 6.2 Review of Contract Documents and Field Conditions by The Design -Build Entity; Single Point Responsibility of The Design -Build Entity. A. In addition to the examination and reviews performed, and obligations assumed, incident to making the representations set forth in the Contract, the Design -Build Entity shall carefully study and compare each of the Contract Documents provided by Agency with the others and with information furnished by Agency, and shall promptly report in writing to Agency's Representative any errors, inconsistencies, or omissions in the Contract Documents provided by Agency or inconsistencies with Applicable Law observed by the Design -Build Entity. The Design -Build Entity shall be solely responsible for any errors, inconsistencies or omissions in the Contract Documents if the Design -Build Entity fails to perform such review and examination or fails to report such errors, inconsistencies or omissions to Agency in writing. B. The Design -Build Entity is responsible for the design and construction of the Project and shall use the highest design and engineering standards of care applicable to projects, buildings or work of similar size, complexity, quality and scope in performing Work on the Project. The Design -Build Entity shall be solely responsible for any and all design errors including, but without limitation, errors, inconsistencies or omissions in the Construction Documents. The Design -Build Entity shall take field measurements, verify field conditions, and carefully compare with the Contract Documents such field measurements, conditions, and other information known to the Design -Build Entity before commencing Work on the Project. Errors, inconsistencies, or omissions discovered at any time shall be promptly reported in writing to Agency's Representative. C. If the Design -Build Entity performs any design and/or construction activity which it knows, or should know, involves an error, inconsistency, or omission referred to in this Article, without notifying and obtaining the written consent of Agency's Representative, the Design -Build Entity shall be responsible for the resultant losses, including, without limitation, the costs of correcting Defective Work. D. Agency does not assume any obligation to employ the Design -Build Entity's services or pay the Design -Build Entity royalties of any type as to future programs that may result from Work performed under this Contract. E. The Design -Build Entity shall be responsible for all plotting, printing, copying and distribution costs of any and all documents required in connection with Work on the Project. A2-33 F. The Design -Build Entity agrees that it has single point responsibility for the design and construction of this Project, and agrees to utilize the highest standard of excellent design, engineering and construction practices. The Design -Build Entity has the duty to act in Agency's best interests at all times throughout the course and performance of this Contract. 6.3. Design, Supervision and Construction Procedures. A. The Design -Build Entity shall supervise, coordinate, and direct all Work on the Project using the Design -Build Entity's best skill and attention and applying such skills and expertise as may be necessary to perform the Work in accordance with the Contract Documents. The Design -Build Entity shall be solely responsible for, and have control over, the entire design effort, construction means, methods, techniques, sequences, procedures, and the coordination of all portions of Work on the Project, including, but without limitation, landscape and site work, utilities, and building systems. B. The Design -Build Entity shall be responsible to Agency for acts and omissions of the Design -Build Entity, its agents, employees, and Subcontractors, and their respective agents and employees. C. The Design -Build Entity shall not be relieved of its obligation to perform all Work on the Project in accordance with the Contract Documents either by acts or omissions of Agency or Agency's Representative in the administration of the Contract, or by tests, inspections, or approvals required, or performed, by persons or firms other than the Design -Build Entity. D. The Design -Build Entity shall be responsible for inspection of all portions of Work on the Project to determine that such portions conform to the requirements of the Contract Documents and are ready to receive subsequent Work. E. To facilitate communications and the management of the design process, the Design -Build Entity shall maintain an office in the Agency's County for the duration of the design process. F. Unless otherwise provided in the Contract Documents, the Design -Build Entity shall provide and pay for all professional design/engineering services, services, labor, materials, equipment, tools, construction equipment and machinery, transportation, and other facilities and services necessary for proper execution and completion of the Work on the Project, whether temporary or permanent and whether or not incorporated or to be incorporated in Work on the Project. The Design -Build Entity shall furnish architectural and engineering services for the preparation of Construction Documents necessary to complete the Project in accordance with the requirements of the Contract Documents. From the Agency -approved Construction Documents, which are developed from the Agency -accepted Proposal, the Design - Build Entity shall furnish all labor, materials, equipment, services, and transportation necessary to complete construction of the Project, including, if applicable, site work, structures and utilities. G. The Design -Build Entity is required to deliver to Agency, if requested, any and all Design Materials including, but not limited to, calculations, preliminary drawings, A2-34 construction drawings, shop drawings, electronic media data, tenant improvement documents, sketches, illustrations, specifications, descriptions, models, mock ups, and other information developed, prepared, furnished, or delivered in the prosecution of the Design Work. H. The Design -Build Entity is responsible for preparation of the Construction Documents for the entire Project. The Design -Build Entity is responsible for construction of the entire Project as required by the Contract Documents. 6.4 Labor: Working Hours. A. The Design -Build Entity shall provide competent, suitably qualified personnel to survey and lay out the Work and perform construction as required by the Contract Documents. The Design -Build Entity shall at all times maintain good discipline and order at the Site. The Design -Build Entity will provide all labor needed to complete the Work within the Contract Times. B. Except as otherwise required for the safety or protection of persons or the Work or property at the Site or adjacent thereto, and except as otherwise stated in the Contract Documents, all Work at the Site shall be performed during regular working hours, which are defined as hours between 6:00 a.m. and 5:00 p.m. any day Monday through Friday of any week except on Holidays and/or during Schedule Constraints defined in the Contract Documents. The Design -Build Entity will not permit the performance of Work on a Saturday, Sunday, any Holiday or during identified Schedule Constraints without Agency's written consent given after prior written notice to Agency's Representative. The Design -Build Entity shall be responsible for, and shall reimburse Agency for, all inspection costs outside regular working hours, including overtime. 6.5 Progress Meetings. The Design -Build Entity shall schedule and hold regular on -site progress meetings at least weekly during construction and at other times as requested by the Agency or as required by progress of the Work. The Design -Build Entity, Agency's Representative, and all Subcontractors active on the Site shall attend each meeting. The Design -Build Entity may at its discretion request attendance by representatives of its Suppliers, manufacturers, and other Subcontractors. Agency's Representative will preside at the progress meetings and will arrange for keeping and distributing the minutes. The purpose of the meetings is to review the progress of the Work, maintain coordination of efforts, discuss changes in scheduling, and resolve other problems which may develop. During each meeting, the Design -Build Entity shall present any issues which may impact its progress with a view to resolve these issues expeditiously. 6.6 CPM Progress Schedule and Recovery Schedule. A. Design -Build Entity shall adhere to the Project Schedule, which shall be a CPM progress schedule established in accordance with the Contract Documents as it may be adjusted from time to time as provided below: 1. Design -Build Entity shall submit to Agency's Representative for acceptance proposed adjustments in the Project Schedule that will not result in changing the A2-35 Project Completion Date. Such adjustments will comply with any provisions of the General Requirements applicable thereto. 2. Proposed adjustments in the Project Schedule that will change the Project Completion Date shall be submitted in accordance with the requirements of the Contract Documents. Adjustments in the Project Completion Date may only be made by a Change Order. 3. Should any of the following conditions exist, Agency may require Design -Build Entity to prepare, at no extra cost to Agency, a plan of action and a recovery schedule for completing the Work and achieving all contractual milestones within the Project Completion Date: a. The Design -Build Entity's monthly progress report indicates delays that are, in the opinion of Agency, of sufficient magnitude that Agency questions the Design -Build Entity's ability to complete the Work; b. The Project Schedule shows the Design -Build Entity to be thirty (30) or more Days behind the critical path at any time during construction; c. The Design -Build Entity desires to make changes in the logic or the planned duration of future activities of the Project Schedule which, in the opinion of Agency, are major in nature. d. The recovery schedule shall include proposed revisions to the Project Schedule, demonstrating how Design -Build Entity intends to achieve all contractual milestones including contract completion within the Project Completion Date. The submittal shall include a narrative describing the actions planned by the Design -Build Entity to recover the schedule. e. Design -Build Entity shall submit the recovery schedule within seven (7) Days of Agency's request: i. If Design -Build Entity asserts that Agency is responsible for the delay, failure to submit the recovery schedule within seven (7) Days of Agency's request will be considered a concurrent delay event attributable to Design -Build Entity, and Design -Build Entity shall only be entitled to non- compensable adjustments to the Project Completion Date. ii. If Design -Build Entity is responsible for the delay, this provision will not limit or affect Design -Build Entity's liability and failure to submit the recovery schedule with seven (7) Days of Agency's request may result in Agency withholding progress payments or other amounts due under the Contract Documents. f. Design -Build Entity is responsible for all costs associated with the preparation and execution of the recovery schedule, including any necessary recovery actions, which may include, but are not limited to, assignment of additional labor, and/or equipment, shift or overtime work, expediting of submittals or deliveries, overlapping of activities or sequencing changes to increase activity concurrence. A2-36 g. Regardless of whether Agency directs Design -Build Entity to prepare a recovery schedule pursuant to this Article, Design -Build Entity shall promptly undertake appropriate action at no additional cost to Agency to recover the schedule whenever the current Project Schedule shows that the Design -Build Entity will not achieve a milestone and/or complete the Work within the Project Completion Date. B. Unless otherwise specified in the Contract Documents, Design -Build Entity shall provide and assume full responsibility for all services, materials, equipment, labor, transportation, construction equipment and machinery, tools, appliances, fuel, power, light, telephone, sanitary facilities, temporary facilities, and all other facilities and incidentals necessary for the performance, testing, start up, and completion of the Work within the Project Completion Date. C. Failure of Agency's Representative to discover errors or omissions in schedules that it has reviewed, or to inform the Design -Build Entity that the Design -Build Entity, Subcontractors, or others are behind schedule, or to direct or enforce procedures for complying with the Project Schedule shall not relieve the Design -Build Entity from its sole responsibility to perform and complete all Work on the Project within the Project Completion Date and shall not be a cause for an adjustment of the Project Completion Date or the Contract Price. D. The Design -Build Entity shall perform all Work on the Project in accordance with the current accepted Project Schedule. 6.7 Materials. A. All materials and equipment incorporated into the Work shall be as specified or, if not specified, shall be of good quality and new, except as otherwise provided in the Contract Documents. All materials furnished by the Design -Build Entity shall be of the most suitable grade for the purpose intended considering strength, ductility, durability, and best industry practice. B. All special warranties and guarantees required by the Contract Documents shall expressly run to the benefit of Agency. If required by Agency's Representative, Design -Build Entity shall furnish satisfactory evidence (including reports of required tests) as to the source, kind, and quality of materials and equipment. C. All materials and equipment shall be stored, applied, installed, connected, erected, protected, used, cleaned, and conditioned in accordance with instructions of the applicable supplier, except as otherwise may be provided in the Contract Documents. D. Materials shall be furnished in ample quantities and at such times as to ensure uninterrupted progress of the Work and shall be stored properly and protected as required by the Contract Documents. Design -Build Entity shall be entirely responsible for damage or loss by weather or other causes to materials or Work until Agency has accepted the Work. Materials shall be stored on the Project site in such manner so as not to interfere with any operations of Agency or any independent contractor. A2-37 E. No materials, supplies, or equipment for Work under this Contract shall be purchased subject to any chattel mortgage or under a conditional sale or other agreement by which an interest therein or in any part thereof is retained by the seller or supplier. Design -Build Entity warrants good title to all material, supplies, and equipment installed or incorporated in the work and agrees upon completion to deliver the Work to Agency free from any claims, liens, or encumbrances. F. Inspection of Materials. 1. Materials furnished by the Design -Build Entity which will become a part of the Project shall be subject to inspection at any one or more of the following locations, as determined by Agency's Representative: at the place of production or manufacture, at the shipping point, or at the site of the Work. To allow sufficient time to provide for inspection, the Design -Build Entity shall submit to Agency's Representative, at the time of issuance, copies of purchase orders or other written instrument confirming procurement of the materials, including drawings and other pertinent information, covering materials on which inspection will be made. 2. No later than fourteen (14) Days prior to manufacture of material, Design -Build Entity shall inform Agency's Representative, in writing, the date the material is to be manufactured. 3. The inspection of materials at any of the locations specified above or the waiving of the inspection thereof shall not impact whether the materials and equipment conform to the Contract Documents. Design -Build Entity will not be relieved from furnishing materials meeting the requirements of the Contract Documents due to Agency's inspection or lack of inspection of the equipment or materials. Acceptance of any materials will be made only after materials are installed in the Project. 6.8 Submittals. A. Industry Standard Submittals. Design -Build Entity will identify in the Construction Documents all industry standard submittals for all materials, systems, and equipment incorporated into the Work. B. Schedule of Submittals. 1. Design -Build Entity will prepare and deliver a Schedule of Submittals to Agency's Representative that has been fully integrated with the CPM Progress Schedule and identifies each Submittal required by the Construction Documents as well as the date on which Design -Build Entity will deliver each Submittal to Agency's Representative. Each Submittal must be delivered to Agency's Representative at least thirty (30) Days prior to the date the material or equipment is scheduled to be incorporated into the Work. The Design -Build Entity is responsible for any schedule delays resulting from the Submittal process. A2-38 2. Design -Build Entity must submit all submittals required by the Construction Documents in accordance with the Schedule of Submittals. If Design -Build Entity fails to submit the submittals in accordance with the Schedule of Submittals, Design -Build Entity will be solely liable for any delays or impacts caused by the delayed submittal, whether direct or indirect. Design -Build Entity will be liable for the time calculated from the date the submittal is due until the date a compliant submittal is made. A compliant submittal will be one that is complete and satisfies the requirements of the Contract Documents. 3. Where a Submittal, Shop Drawing or Sample is required by the Construction Documents, any related Work performed prior to Agency's Representative's review and approval of the pertinent Submittal will be at the sole expense and responsibility of the Design -Build Entity. C. Submittal Procedures. The Design -Build Entity will follow the following procedures for each Submittal, Shop Drawing and Sample required by the Contract Documents: 1. Transmit three (3) copies of each with a Submittal Transmittal. 2. Transmittals will be sequentially numbered. The Design -Build Entity to mark revised Submittals with original number and sequential alphabetic suffix. 3. Each Submittal will identify the Project, the Design -Build Entity, Subcontractor and supplier, pertinent Construction Document and detail number, and specification section number appropriate to the Submittal. 4. The Design -Build Entity must sign each Submittal, certifying that it has reviewed and approved the Submittal, verified products required, field dimensions, adjacent construction work, and that coordination of information is according to requirements of the Project and Contract Documents. 5. Identify variations in Contract Documents and product or system limitations that may differ and/or be detrimental to successful performance of completed Work. 6. When a Submittal is revised for resubmission, the Design -Build Entity shall promptly address Agency comments and resubmit. The Design -Build Entity shall identify changes made since previous submission. 7. Agency's review of Submittals shall not relieve the Design -Build Entity from responsibility for deviations from the Contract Documents unless the Design - Build Entity has, in writing, called Agency's attention to such deviations at time of submission and Agency's has taken no exception to the deviation. Agency's review of Submittals shall not relieve the Design -Build Entity from responsibility for errors in the Submittals. 8. Submittals not required by the Construction Documents or requested by Agency's Representative will not be acknowledged or processed. A2-39 9. Incomplete Submittals will not be reviewed by Agency's Representative. Delays resulting from incomplete submittals are not the responsibility of Agency's Representative. 10. The Design -Build Entity shall not be entitled to any extension of the Project Completion Date as a result of the Submittal process. 6.9 Shop Drawing and Sample Submittal Procedures. A. Before submitting each Shop Drawing or Sample, Design -Build Entity shall have: 1. Reviewed and coordinated each Shop Drawing or Sample with other Shop Drawings and Samples and with the requirements of the Work and the Contract Documents; 2. Determined and verified all field measurements, quantities, dimensions, specified performance and design criteria, installation requirements, materials, catalog numbers, and similar information with respect thereto; 3. Determined and verified the suitability of all materials offered with respect to the indicated application, fabrication, shipping, handling, storage, assembly, and installation pertaining to the performance of the Work; and 4. Determined and verified all information relative to the Design -Build Entity's responsibilities for means, methods, techniques, sequences, and procedures of construction, and safety precautions and programs incident thereto. B. With each Submittal, the Design -Build Entity shall give Agency's Representative specific written notice of any variations that the Shop Drawing or Sample may have from the requirements of the Contract Documents. This notice shall be both a written communication separate from the Shop Drawings or Sample submittal and, in addition, a specific notation made on each Shop Drawing or Sample submitted to Agency's Representative for review and approval of each such variation. C. Shop Drawings. Data shown on the Shop Drawings will be complete with respect to quantities, dimensions, specified performance and design criteria, materials, and similar data to show Agency's Representative the services, materials, and equipment Design -Build Entity proposes to provide and to enable Agency's Representative to review the information Representative for assessing conformance with information given and design concept expressed in Contract Documents. When required by individual Specification Sections, provide Shop Drawings signed and sealed by a professional engineer responsible for designing components shown on Shop Drawings. Shop Drawings must include signed and sealed calculations to support design in a form suitable for submission to and approval by authorities having jurisdiction. Design - Build Entity shall make revisions and provide additional information when required by authorities having jurisdiction. D. Samples. A2-40 Clearly identify each Sample as to material, Supplier, pertinent data such as catalog numbers, the use for which intended and other data as required to enable Agency's Representative to review the submittal for assessing conformance with information given and design concept expressed in Contract Documents. Samples should be of appropriate size and detail to assess functional, aesthetic, color, texture, patterns and finish selection. E. Agency's Representative's Review. 1. Agency's Representative will review Shop Drawings and Samples in accordance with the Schedule of Submittals. Agency's Representative's review and acceptance will be only to determine if the items covered by the Submittals will, after installation or incorporation in the Project, conform to the information given in the Contract Documents and be compatible with the design concept of the completed Project as a functioning whole as indicated by the Contract Documents. 2. Agency's Representative's review and approval will not extend to means, methods, techniques, sequences, or procedures of construction (except where a particular means, method, technique, sequence, or procedure of design or construction is specifically and expressly called for by the Contract Documents) or to safety precautions or programs incident thereto. The review and approval of a separate item as such will not indicate approval of the assembly in which the item functions. 3. Agency's Representative's review and acceptance shall not relieve the Design -Build Entity from responsibility for any variation from the requirements of the Contract Documents unless Agency's Representative has given written approval of each such variation by specific written notation thereof incorporated in or accompanying the Submittal. 4. The Design -Build Entity shall make corrections required by Agency's Representative and shall return three (3) corrected copies of Shop Drawings and Product Data, and submit, as required, new Samples for review and approval. The Design -Build Entity shall direct specific attention in writing to revisions other than the corrections called for by Agency's Representative on previous Submittals. Agency will review the first resubmittal of Shop Drawings at its cost. Agency reserves the right to reduce the Contract Price by Change Order for its cost for any subsequent reviews of Shop Drawing resubmittals. 6.10 Construction Documents. A. The NE shall design the building systems and prepare the Construction Documents. The Construction Documents shall provide information customarily necessary in documents for projects of similar size, complexity, and quality. The Construction Documents shall include all information required by the building trades to complete the construction of the Project, other than such details customarily developed by others during construction. Agency's review of the Construction Documents shall be conducted in accordance with the approved Project Schedule with procedures set forth in this Article. Such review shall not relieve the Design -Build Entity from its A2-41 responsibilities under the Contract. Such review shall not be deemed an approval or waiver by Agency of any deviation from, or of the Design -Build Entity's failure to comply with, any provision or requirement of the Contract Documents, unless such deviation or failure has been identified as such in writing in the Document submitted by the Design -Build Entity and approved by Agency. B. However, it is acknowledged by the parties hereto that inherent in a Design -Build concept, bridging or otherwise, the production and review of Construction Documents may be a continuing process with portions thereof completed at different times. The Design -Build Entity will submit the Construction Document packages to Agency for review and approval in accordance with the agreed upon schedule, unless otherwise approved in writing by Agency. The Project Schedule shall indicate the times for Agency to review the completion of each such portion of the Construction Documents and a reasonable time for review of same. C. The Design -Build Entity shall submit completed packages of the Construction Documents for review by Agency at the times indicated on the Project Schedule and as defined in the Scheduling Specification. Meetings between the Design -Build Entity and Agency to review the Construction Document packages, shall be scheduled at least every two weeks, or as otherwise agreed to by the parties, and held so as not to delay Work on the Project. The Design -Build Entity will conduct these design meetings with Agency in accordance with the schedule approved by Agency. The Design -Build Entity will be responsible for preparing and circulating for the parties review, design meeting minutes from all such meetings. 6.11 Field Engineering. Reserved. 6.12 Geotechnical and Survey. Reserved. 6.13 Dust Control. Design -Build Entity, at its expense, shall maintain all excavations, embankments, haul roads, permanent access roads, plant sites, waste disposal areas, borrow areas, and all other work areas free from dust. Industry accepted methods of dust control suitable for the area involved, such as sprinkling, chemical treatment, light bituminous treatment or similar methods, will be permitted. 6.14 Air Pollution. A. To the extent applicable, Design -Build Entity must fully comply with all applicable laws, rules and regulations in furnishing or using equipment and/or providing services, including, but not limited to, emissions limits and permitting requirements imposed by the South Coast Air Quality Management Agency (SCAQMD) and/or California Air Resources Board (CARB). Although the SCAQMD and CARB limits and requirements are more broad, Design -Build Entity shall specifically be aware of their application to "portable equipment", which definition is considered by SCAQMD and CARB to include any item of equipment with a fuel -powered engine. Design- A2-42 Build Entity shall indemnify Agency against any fines or penalties imposed by SCAQMD, CARB, or any other governmental or regulatory agency for violations of applicable laws, rules and/or regulations by Design -Build Entity, its sub -consultants, or others for whom Design -Build Entity is responsible under its indemnity obligations provided for in this Agreement. B. The Design -Build Entity shall comply with all air pollution control rules, regulations, ordinances and statutes. All containers of paint, thinner, curing compound, solvent or liquid asphalt shall be labeled to indicate that the contents fully comply with the applicable material requirements. Design -Build Entity shall not discharge into the atmosphere from any source whatever smoke, dust, or other air contaminants in violation of the laws, rules, and regulations of the governmental entities having jurisdiction. 6.15 Patent Fees and Royalties. A. Design -Build Entity shall pay all license fees and royalties and assume all costs incident to the use in the performance of the Work or the incorporation in the Work of any invention, design, process, product, or device which is the subject of patent rights or copyrights held by others. If a particular invention, design, process, product, or device is specified in the Contract Documents for use in the performance of the Work and if, to the actual knowledge of Agency or Agency's Representative, its use is subject to patent rights or copyrights calling for the payment of any license fee or royalty to others, the existence of such rights shall be disclosed by Agency in the Contract Documents. B. To the fullest extent permitted by Applicable Laws, Design -Build Entity shall indemnify, defend, and hold harmless Agency and Agency's Representative, and the officers, directors, members, partners, employees, agents, consultants and subcontractors of each and any of them, from and against all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to any infringement of patent rights or copyrights incident to the use in the performance of the Work or resulting from the incorporation in the Work of any invention, design, process, product, or device not specified in the Contract Documents or specified in the Contract Documents and identified as being subject to payment of any license fee or royalty to others required by patent rights or copyrights. 6.16 Permits and Licenses. A. Design -Build Entity shall obtain and pay for all other permits and licenses required for the Work, including excavation permit and permits for plumbing, mechanical and electrical work and for operations in or over public streets or right of way under jurisdiction of public agencies other than Agency. B. Reserved. C. Before acceptance of the Work, the Design -Build Entity shall submit all licenses, permits, certificates of inspection and required approvals to Agency. A2-43 6.17 Applicable Laws. Design -Build Entity shall give all notices required by and shall comply with all Applicable Laws applicable to the performance of the Work. Except where otherwise expressly required by Applicable Laws, neither Agency nor Agency's Representative shall be responsible for monitoring Design -Build Entity's compliance with any Applicable Laws. If Design -Build Entity performs any Work knowing or having reason to know that it is contrary to Applicable Laws, Design -Build Entity shall bear all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to such Work. 6.18 Labor Laws and Design -Build Entity's Obligations. A. Hours of Work. 1. The Design -Build Entity and Subcontractors shall furnish sufficient forces to ensure the prosecution of the Work on the Project in accordance with the Construction Schedule and in such a manner to allow for the full and adequate completion of the Project within the Project Completion Date. 2. Work on the Project shall be performed during regular working hours, except that in the event of an emergency or when required to complete the Work on the Project in accordance with job progress, Work may be performed outside of regular working hours with advance written notice to Agency. Permissible working hours shall be between 6:00 a.m. to 5:00 p.m. and shall not be changed except with consent of Agency. 3. Eight (8) hours of work shall constitute a legal day's work. The Design -Build Entity and each Subcontractor shall forfeit, as penalty to Agency, twenty-five dollars ($25) for each worker employed in the execution of Work on the Project by the Design -Build Entity or any Subcontractor for each day during which such worker is required or permitted to work more than eight (8) hours in any one day and forty (40) hours in any week in violation of the provisions of the Labor Code, and in particular, Section 1810 to Section 1815, except as provided in Labor Code Section 1815. 4. If the work done after hours is required by the Contract to be done outside the Design -Build Entity's regular working hours, the costs of any inspections, if required to be done outside normal working hours, shall be borne by Agency. If Agency allows the Design -Build Entity to do Work outside regular working hours for the Design -Build Entity's own convenience, the costs of any inspections required outside regular working hours shall be invoiced to the Design -Build Entity by Agency and deducted from the next progress payment. If the Design -Build Entity elects to perform Work outside the Inspector's regular working hours, costs of any inspections required outside regular working hours shall be invoiced to the Design -Build Entity by Agency and deducted from the next progress payment. If it is determined by the parties that Work outside of regular working hours is necessary to meet the A2-44 Agency's objectives, then the final construction schedule shall be adjusted accordingly, and the cost of inspection shall by the Agency. 5. No Work on the Project or other activities by or on behalf of the Design -Build Entity which presents a hazard or unreasonable disruption to Agency staff shall be allowed during normal working hours. The determination as to whether Work on the Project or some other activity presents a hazard or constitutes an unreasonable disruption to Agency staff shall be made by and pursuant to the sole discretion of a representative of Agency. All Work on the Project or other activities which could present a hazard or unreasonable disruption to Agency staff shall be performed before or after normal working hours, on weekends, or on an Agency recognized holiday. Neither the Design -Build Entity nor its Subcontractors or anyone working on behalf of the Design -Build Entity or Subcontractors shall be entitled to additional compensation or an extension of the Project Completion Date for having to arrange their Work schedule so as not to violate the provisions of this Article. The Design -Build Entity, Subcontractors and persons working on behalf of the Design -Build Entity shall be expected to arrange such Work and other activities in advance so as to avoid creating monetary or time impacts. B. Wage Rates, Travel, and Subsistence. 1. The Design -Build Entity is aware of the requirements of Labor Code Sections 1720 et seq. and 1770 et seq., as well as California Code of Regulations, Title 8, Section 16000 et seq. ("Prevailing Wage Laws"), which require the payment of prevailing wage rates and the performance of other requirements on certain "public works" and "maintenance" projects. Since the Work on the Project involves an applicable "public works" or "maintenance" project, as defined by the Prevailing Wage Laws, and since the total compensation is $1,000 or more, the Design -Build Entity agrees to fully comply with such Prevailing Wage Laws. Agency has obtained the prevailing wage rates from the Director of the Department of Industrial Relations, State of California. Copies of the prevailing wage rates are on file at Agency's office and shall be made available to any interested party on request. the Design -Build Entity shall make copies of the prevailing rates of per diem wages for each craft, classification or type of worker needed to perform the Project available to interested parties upon request, and shall post copies at the Design -Build Entity's principal place of business and at the Project site. The Design -Build Entity shall defend, indemnify and hold Agency, its elected officials, officers, employees and agents free and harmless from any claims, liabilities, costs, penalties or interest arising out of any failure or allege failure to comply with the Prevailing Wage Laws. 2. Pursuant to Labor Code Section 1775, the Design -Build Entity is hereby advised that in the event that the Design -Build Entity fails to pay prevailing wages, the Design -Build Entity will be held liable for penalties and for shortfalls in wages and such amounts may be withheld from progress payments. the Design -Build Entity and each Subcontractor shall forfeit as a penalty to Agency not more than two hundred dollars ($200) for each Day, or portion thereof, for each worker paid less than the stipulated prevailing wage rate for any work done by him, or by any subcontract under him, in violation A2-45 of the provisions of the Labor Code. The difference between such stipulated prevailing wage rate and the amount paid to each worker for each Day or portion thereof for which each worker was paid less than the stipulated prevailing wage rate shall be paid to each worker by the Design -Build Entity. 3. The Design -Build Entity shall post, at appropriate conspicuous points on the Project site, a schedule showing all determined general prevailing wage rates and all authorized deductions, if any, from unpaid wages actually earned. C. Labor Compliance/Pavroll Records. 1. The Design -Build Entity shall post, at appropriate conspicuous points on the Project site, a schedule showing all determined general prevailing wage rates and all authorized deductions, if any, from unpaid wages actually earned. 2. Pursuant to Labor Code Section 1776, the Design -Build Entity and each Subcontractor shall maintain weekly certified payroll records showing the name, address, social security number, work classification, straight time and overtime hours paid each day and week, and the actual per diem wages paid to each journeyman, apprentice, worker or other employee employed in connection with the Project. The Design -Build Entity shall certify under penalty of perjury that records maintained and submitted by the Design -Build Entity are true and accurate. The Design -Build Entity shall also require Subcontractor(s) to certify weekly payroll records under penalty of perjury. 3. In accordance with Labor Code section 1771.4, the Design -Build Entity and each Subcontractor shall furnish the certified payroll records directly to the Department of Industrial Relations ("DIR") on a weekly basis and in the format prescribed by the DIR. This may include electronic submission. Design -Build Entity shall ensure full compliance with all requirements and regulations from the DIR relating to labor compliance monitoring and enforcement and all other applicable labor law. 4. Any stop orders issued by the DIR against Design -Build Entity or any Subcontractor that affect Design -Build Entity's performance of Work, including any delay, shall be Design -Build Entity's sole responsibility. Any delay arising out of or resulting from such stop orders shall be considered Design -Build Entity caused delay subject to any applicable liquidated damages and shall not be compensable by the Agency. Design -Build Entity shall defend, indemnify and hold the Agency, its officials, officers, employees and agents free and harmless from any claim or liability arising out of stop orders issued by the DIR against Design -Build Entity or any Subcontractor. 5. The payroll records described herein shall be certified and submitted by the Design -Build Entity at a time designated by the Agency. The Design -Build Entity shall also provide the following: a. A certified copy of the employee's payroll records shall be made available for inspection or furnished to such employee or his or her authorized representative on request. A2-46 b. A certified copy of all payroll records described herein shall be made available for inspection or furnished upon request of the DIR. 6. Unless submitted electronically, the certified payroll records shall be on forms provided by the Division of Labor Standards Enforcement ("DLSE") of the DIR or shall contain the same information as the forms provided by the DLSE. 7. Any copy of records made available for inspection as copies and furnished upon request to the public or any public agency, the Agency, the Division of Apprenticeship Standards or the Division of Labor Standards Enforcement shall be marked or obliterated in such a manner as to prevent disclosure of an individual's name, address and social security number. The name and address of the Design -Build Entity awarded the Contract or performing the contract shall not be marked or obliterated. 8. In the event of noncompliance with the requirements of this Article, the Design -Build Entity shall have ten (10) Days in which to comply subsequent to receipt of written notice specifying any item or actions necessary to ensure compliance with this Article. Should noncompliance still be evident after such ten (10) day period, the Design -Build Entity shall, as a penalty to the Agency, forfeit One Hundred Dollars ($100.00) for each day, or portion thereof, for each worker until strict compliance is effectuated. Upon the request of DIR, such penalties shall be withheld from contract payments. 9. In submitting the Proposal on this Project, it shall be the Design -Build Entity's sole responsibility to evaluate and include the cost of complying with all labor compliance requirements under this Contract and Applicable Law in its Proposal. 10. The Design -Build Entity shall include provisions of this Article in all Subcontracts and require Subcontractors to comply with these provisions at no additional cost to Agency. D. Apprentices. The Design -Build Entity's attention is directed to the provisions of Sections 1777.5, 1777.6, and 1777.7 of the Labor Code concerning employment of apprentices by the Design -Build Entity or any Subcontractor. The Design -Build Entity shall obtain a certificate of apprenticeship before employing any apprentice pursuant to Sections 1777.5, 1777.6, and 1777.7 of the Labor Code. Information relative to apprenticeship standards, wage schedules, and other requirements may be obtained from DIR, the Administrator of Apprenticeships, San Francisco, California, or from the Division of Apprenticeship Standards and its branch offices. Knowing violations of Labor Code section 1777.5 will result in forfeiture not to exceed one hundred dollars ($100.00) for each calendar day of non-compliance pursuant to Labor Code section 1777.7. E. Nondiscrimination. Pursuant to Labor Code section 1735 and other applicable provisions of law, the Design -Build Entity and its Subcontractors shall not discriminate against any A2-47 employee or applicant for employment because of race, color, religion, sex, national origin, age, political affiliation, marital status, or handicap on this Work. The Design - Build Entity will take affirmative action to insure that employees are treated during employment or training without regard to their race, color, religion, sex, national origin, age, political affiliation, marital status, or handicap. F. Workers' Compensation. Pursuant to Labor Code section 1860, Design -Build Entity shall secure the payment of workers' compensation to its employees in accordance with the provisions of Labor Code section 3700. By its signature hereunder, Design -Build Entity certifies that he is aware of the provisions of Section 3700 of the California Labor Code which require every employer to be insured against liability for Worker's Compensation or to undertake self-insurance in accordance with the provisions of that Code, and agrees to comply with such provisions before commencing the performance of the Work. G. Public Works Registration. Pursuant to Labor Code sections 1725.5 and 1771.1, the Design -Build Entity and its Subcontractors must be registered with the Department of Industrial Relations prior to the execution of a contract to perform public works. By entering into this Contract, Design -Build Entity represents that it is aware of the registration requirement and is currently registered with the DIR. Design -Build Entity shall maintain a current registration for the duration of the Project. Design -Build Entity shall further include the requirements of Labor Code sections 1725.5 and 1771.1 in any Subcontract and ensure that all Subcontractors are registered at the time this Contract is entered into and maintain registration for the duration of the Project. 6.19 Debarment Contractors or subcontractors may not perform work on a public works project with a subcontractor who is ineligible to perform work on a public project pursuant to Labor Code section 1777.1 or 1777.7. Any contract on a public works project entered into between a contractor and a debarred subcontractor is void as a matter of law. A debarred subcontractor may not receive any public money for performing work as a subcontractor on a public works contract. Any public money that is paid, or may have been paid to a debarred subcontractor by a contractor on the project shall be returned to the Agency. The Design -Build Entity shall be responsible for the payment of wages to workers of a debarred subcontractor who has been allowed to work on the Project. 6.20 Taxes. The Design -Build Entity shall pay all sales, consumer, use, and other similar taxes required to be paid in accordance with the Applicable Law of the place of the Project which are applicable during the performance of the Project. In accordance with Revenue and Taxation Code Section 107.6, the Contract Documents may create a possessory interest subject to personal property taxation for which the Design -Build Entity will be responsible. A2-48 6.21 Use of Site and Other Areas. A. Limitation on Use of Site and Other Areas. The Design -Build Entity shall confine construction equipment, the storage of materials and equipment, and the operations of workers to the Site and other areas permitted by Applicable Laws, and shall not unreasonably encumber the Site and other areas with construction equipment or other materials or equipment. Design - Build Entity shall assume full responsibility for any damage to any such land or area, or to the Agency or occupant thereof, or of any adjacent land or areas resulting from the performance of the Work. Should any claim be made by any such Agency or occupant because of the performance of the Work, Design -Build Entity shall promptly settle with such other party by negotiation or otherwise resolve the claim by arbitration or other dispute resolution proceeding or at law. B. Removal of Debris. During the progress of the Work Design -Build Entity shall keep the Site and other areas free from accumulations of waste materials, rubbish, and other debris. Removal and disposal of such waste materials, rubbish, and other debris shall conform to Applicable Laws. C. Cleaning. Prior to Completion of the Work, Design -Build Entity shall clean the Site and the Work and make it ready for utilization by Agency. At the completion of the Work Design -Build Entity shall remove from the Site all tools, appliances, construction equipment and machinery, and surplus materials and shall restore to original condition all property not designated for alteration by the Contract Documents. D. Loading Structures. Design -Build Entity shall not load nor permit any part of any structure to be loaded in any manner that will endanger the structure, nor shall Design -Build Entity subject any part of the Work or adjacent property to stresses or pressures that will endanger it. 6.22 Utility Usage. All temporary utilities, including but not limited to electricity, water, gas, and telephone, used on the Work shall be furnished and paid for by the Agency. 6.23 Record Drawings. A. Design -Build Entity shall maintain in a safe place at the Site one record copy of the Contract Documents and written interpretations and clarifications in good order and annotated to show changes made during construction. On these, it shall mark all Project conditions, locations, configurations, and any other changes or deviations which may vary from the information represented in the original Contract Documents, including buried or concealed construction and utility features which are revealed during the course of construction. Said record drawings shall be supplemented by A2-49 any detailed sketches as necessary or directed to fully indicate the Work as actually constructed. These master record drawings of the as -built conditions, including all revisions made necessary by Addenda and Change Orders shall be maintained up- to-date during the progress of the Project. Red ink shall be used for alterations and notes. Notes shall identify relevant Change Orders by number and date. B. Record drawings shall be accessible to Agency's Representative at all times during the construction period. Upon Completion of the Project and as a condition of final acceptance, the Design -Build Entity shall finalize and deliver a complete set of record drawings to Agency's Representative. The information submitted by the Design -Build Entity will be assumed to be correct, and the Design -Build Entity shall be responsible for, and liable to Agency, for the accuracy of such information, and for any errors or omissions which may or may not appear on the record drawings. 6.24 Safety and Protection. A. Design -Build Entity shall be solely responsible for all safety precautions and programs in connection with the Work. Such responsibility does not relieve Subcontractors of their responsibility for the safety of persons or property in the performance of their work, nor for compliance with applicable safety laws. Design - Build Entity shall take all necessary precautions for the safety of, and shall provide the necessary protection to prevent damage, injury or loss to: 1. All persons on the Site or who may be affected by the Work; 2. All the Work and materials and equipment to be incorporated therein, whether in storage on or off the Site; and 3. Other property at the Site or adjacent thereto, including trees, shrubs, lawns, walks, pavements, roadways, structures, utilities, and Underground Facilities not designated for removal, relocation, or replacement in the course of construction. B. Design -Build Entity shall comply with all Applicable Laws relating to the safety of persons or property, or to the protection of persons or property from damage, injury, or loss; and shall erect and maintain all necessary safeguards for such safety and protection. Design -Build Entity shall notify owners of adjacent property and of Underground Facilities and other utility owners when prosecution of the Work may affect them, and shall cooperate with them in the protection, removal, relocation, and replacement of their property. Design -Build Entity shall comply with the applicable requirements of Agency's safety programs, if any. Design -Build Entity shall inform Agency and Agency's Representative of the specific requirements of Design -Build Entity's safety program with which Agency's and Agency's Representative's employees and representatives must comply while at the Site. C. All damage, injury, or loss to any property caused, directly or indirectly, in whole or in part, by Design -Build Entity, any Subcontractor, Supplier, or any other individual or entity directly or indirectly employed by any of them to perform any of the Work, or anyone for whose acts any of them may be liable, shall be remedied by Design -Build Entity. A2-50 6.25 Safety Representative. Design -Build Entity shall designate an OSHA -certified and experienced safety representative at the Project site whose duties and responsibilities shall be the prevention of accidents and the maintaining and supervising of safety precautions and programs. Design -Build Entity shall provide Agency's Representative the name and contract information of the safety representative in writing. Design -Build Entity shall provide Agency's Representative the name and contact information of the safety representative in writing. 6.26 Hazard Communication Programs. Design -Build Entity shall be responsible for coordinating any exchange of material safety data sheets or other hazard communication information required to be made available to or exchanged between or among employers at the Project site in accordance with Applicable Laws. 6.27 Emergencies. In an emergency affecting safety of life or of Work or of adjoining property, Design -Build Entity, without special instruction or authorization from Agency, shall act to prevent such threatened loss or injury; and Design -Build Entity shall so act, without appeal, if directed or instructed by Agency. Any compensation claimed by Design -Build Entity on account of emergency work shall be determined in accordance with the Contract Documents. 6.28 Guarantee. A. The Design -Build Entity unconditionally guarantees all Work on the Project will be completed in accordance with the requirements of the Contract Documents, and will remain free of defects in workmanship and materials for a period of one (1) year from the date of Project Completion, unless a longer guarantee period is specifically called for in the Contract Documents. However, a shorter guarantee period shall apply to landscape plants, trees, turf, etc. Trees or shrubs greater than one gallon in size at the time of planting shall be guaranteed for one (1) year, and all other plant material shall be guaranteed for six (6) months. The Design -Build Entity shall repair or replace any and all Work, together with any adjacent work that may have been damaged or displaced, which was not in accordance with the requirements of the Contract Documents, or that may be defective in its workmanship or material within the guarantee period specified in the Contract Documents, without any expense whatsoever to Agency; ordinary wear and tear and abuse excepted. B. The Design -Build Entity further agrees, within fourteen (14) Days, or as such shorter period as may be designated for emergency repairs, after being notified in writing by Agency, of any Work not in accordance with the requirements of the Contract Documents or any defects in the Work on the Project, that the Design -Build Entity shall commence and execute, with due diligence, all Work necessary to fulfill the terms of the guarantee. If Agency finds that the Design -Build Entity fails to perform any of the Work under the guarantee, Agency may elect to have the Work completed at the Design -Build Entity's expense and the Design -Build Entity will pay costs of the Work upon demand. Agency will be entitled to all costs, including reasonable A2-51 attorneys' fees and consultants' expenses necessarily incurred upon the Design - Build Entity's refusal to pay the above costs. C. Where Defective Work (or damage to other Work resulting therefrom) has been corrected or removed and replaced, the Warranty period hereunder with respect to such Work shall be extended for an additional period of one (1) year after such correction or removal and replacement has been satisfactorily completed. D. Design -Build Entity's obligations under this Article are in addition to any other obligation or warranty and do not limit Agency's rights and remedies pursuant to California Code of Civil Procedure sections 337.10 and 337.15. or any other Applicable Law. E. Notwithstanding the foregoing provisions, in the event of an emergency constituting an immediate hazard to health or safety of Agency employees, property, or licensees, Agency may undertake, at the Design -Build Entity's expense and without prior notice, all Work necessary to correct such condition(s) when it is caused by Work of the Design -Build Entity not being in accordance with the requirements of the Contract Documents. 6.29 Warranty. The Design -Build Entity warrants to Agency that any and all materials, equipment and furnishings incorporated in the Project will be of good quality and new unless otherwise required or permitted by the Contract Documents. Work not conforming to these requirements, including substitutions not properly approved and authorized, may be considered defective. The foregoing warranty excludes improper operation, or normal wear and tear under normal usage under the control of Agency. Such warranty shall exclude warranties relating to design, warranty of fitness, and any other express or implied warranties other than as set forth herein or in the Contract Documents; provided, however, that the foregoing shall not impair the rights of Agency to maintain an action for breach of contract against the Design -Build Entity. Nothing contained in these Contract Documents pertaining to warranty or guarantee shall be construed as limiting any other rights Agency may have at law, including rights for latent defects under Code of Civil Procedure Section 337.15. 6.30 Indemnification. A. To the fullest extent allowed by law (including without limitation Civil Code Sections 2782 and 2782.8), the Design -Build Entity shall defend (with counsel of Agency's choosing), indemnify and hold Agency, its officials, officers, agents, employees, and representatives free and harmless from and against any and all claims, demands, causes of action, costs, expenses, liabilities, losses, damages or injuries, in law or in equity, to property or persons, including wrongful death, regardless of whether the allegations are false, fraudulent, or groundless, arising out of, related to, or in connection with any acts, omissions or willful misconduct of Design -Build Entity, its officials, officers, employees, agents, consultants, contractors, and Subcontractors arising out of or in connection with the performance of the Work or this Contract, including claims made by Subcontractors for nonpayment, and including without limitation the payment of all attorney's fees and other related costs and expenses except to the extent caused by the sole or active negligence or willful misconduct of A2-52 the Agency. The Design -Build Entity shall defend, at the Design -Build Entity's own cost, expense and risk, with counsel of Agency's choosing, any and all such suits, actions or other legal proceedings of every kind that may be brought or instituted against Agency, its officials, officers, agents, employees and representatives. The Design -Build Entity shall pay and satisfy any judgment, award or decree that may be rendered against Agency, its officials, officers, agents, employees and representatives, in any such suit, action or other legal proceeding. The Design -Build Entity shall reimburse Agency, its officials, officers, agents, employees and representatives for any and all legal expenses and costs incurred by each of them in connection therewith or in enforcing the indemnity herein provided. The Design - Build Entity agrees to pay, or reimburse Agency and Agency's Representative, for regulatory agency or court imposed fees, fines, or penalties imposed on Agency and Agency's Representative arising from the Design -Build Entity's failure to complete the Project in a timely manner and/or in accordance with the Contract Documents and any applicable permits or Applicable Laws. The Design -Build Entity's responsibility and obligation to pay, or reimburse Agency and Agency's Representative, for these fees, fines, or penalties shall be in addition to the assessment of liquidated damages for late completion of the Project. This indemnity provision shall apply to all liability, as provided for above, regardless of whether any insurance policies are applicable. Insurance policy limits do not act as a limitation upon the amount of the indemnification to be provided by the Design -Build Entity. B. If the Design -Build Entity's obligation to defend, indemnify, and/or hold harmless arises out of the Design -Build Entity's performance as a "design professional" (as that term is defined under Civil Code Section 2782.8), then, and only to the extent required under Civil Code Section 2782.8, which is fully incorporated herein, the Design -Build Entity's indemnification obligation shall be limited to claims that arise out of, pertain to, or relate to the negligence, recklessness, or willful misconduct of the Design -Build Entity, and, upon Design -Build Entity obtaining a final adjudication by a court of competent jurisdiction, Design -Build Entity's liability for such claim, including the cost to defend, shall not exceed the Design -Build Entity's proportionate percentage of fault. C. In claims against any person or entity indemnified under this Article that are made by an employee of the Design -Build Entity or any Subcontractor, a person indirectly employed by the Design -Build Entity or any Subcontractor, or anyone for whose acts the Design -Build Entity or any Subcontractor may be liable, the indemnification obligation under this Article shall not be limited by any limitation on amount or type of damages, compensation, or benefits payable by or for Design -Build Entity or any Subcontractor under workers' compensation acts, disability benefit acts, or other employee benefit acts or any other insurance limitations. D. In the event the Design -Build Entity and one or more than one other party is connected with an accident or occurrence covered by this indemnification, then all such parties shall be jointly and severally responsible to each of the Indemnitees for indemnification, and the ultimate responsibility among such indemnifying parties for the loss and expense of any such indemnification shall be resolved without jeopardy to any indemnitee listed in this Article. A2-53 E. The provisions of this Article shall survive the termination of this Contract howsoever caused, and no payment, partial payment, or acceptance of occupancy in whole or part of the Work shall waive or release any of the provisions of this Article. 6.31 Superintendent. A. The Design -Build Entity shall employ a competent Superintendent satisfactory to Agency who shall be in attendance at the Project site at all times during the performance of the Construction Work. Superintendent shall represent the Design - Build Entity and communications given to, and received from, Superintendent shall be binding on the Design -Build Entity. Superintendent must be able to proficiently speak, read and write in English. Failure to maintain a Superintendent on the Project site at all times Work on the Project is in progress shall be considered a material breach of this Contract, entitling Agency to terminate the Contract or, alternatively, issue a Suspension Order until the Superintendent is on the Project site. If, by virtue of issuance of said Suspension Order, the Design -Build Entity fails to complete the Contract by the Project Completion Date, the Design -Build Entity will be assessed Liquidated Damages in accordance with the Contract. B. Any changes to the assignment of the Superintendent shall receive prior written approval from Agency. The Superintendent may not perform the work of any trade, or perform any work not directly related to the supervision and coordination of the Construction Work at the Project site when work is in progress. In addition, the Design -Build Entity will provide all key personnel identified in the Contract for the time periods stipulated. 6.32 Project Staffing. A. The Design -Build Entity and each Subcontractor shall: furnish a competent and adequate staff as necessary for the proper administration, coordination, supervision, and superintendence of its portion of the Work on the Project; organize the procurement of all materials and equipment so that the materials and equipment will be available at the time they are needed for the Work; and keep an adequate force of skilled and fit workers on the job to complete all Work on the Project in accordance with all requirements of the Contract. B. Agency shall have the right, but not the obligation, to require the removal from the Project of the Design -Build Entity's Representative, or any other superintendent, staff member, agent, or employee of any contractor, Subcontractor, material or equipment supplier, or any other entity working on the Project. Removal may be required for any reason designated by Agency, including but not limited to, failure or refusal to perform Work on the Project in a manner acceptable to Agency, uncooperative or incompetent performance on the Project, threatening the adequate or timely completion of the Project, or threatening the safety of persons or property. 6.33 Compliance With State Storm Water Permit for Construction. A. Storm, surface, ground, nuisance, or other waters may be encountered at various times during the Work. Design -Build Entity hereby acknowledges that it has investigated the risk arising from such waters, has prepared its Proposal accordingly, and assumes any and all risks and liabilities arising therefrom. A2-54 B. Design -Build Entity shall keep itself and all subcontractors, staff, and employees fully informed of and in compliance with all local, state and federal laws, rules and regulations that may impact, or be implicated by the performance of the Work including, without limitation, all applicable provisions of the Agency's ordinances regulating discharges of storm water; the Federal Water Pollution Control Act (33 U.S.C. § 1251 et seq.); the California Porter -Cologne Water Quality Control Act (Water Code § 13000 et seq.); and any and all regulations, policies, or permits issued pursuant to any such authority. These include, but are not limited to California Regional Water Quality Control Boards (Santa Ana and San Diego Regions) Order No. R8-2009-0030 (NPDES Permit No. CAS 618030), Order No. R9- 2009-0002, Order No. R8-2009-0045, Order No. R9-2013-0001 as amended by Order Nos. R9-2015-0001 and R9-2015-0100, and State Water Resources Control Board Order No. 2010-0014-DWQ, Order No. 2009-0009-DWQ, and Order No. 2012-0006-DWQ, and any amendment or renewal thereof. C. The Design -Build Entity shall be required to comply with all conditions of the State Water Resources Control Board National Pollutant Discharge Elimination System General Permit for Waste Discharge Requirements for Discharges of Stormwater Runoff Associated with Construction Activity ("Permit") for all construction activity which results in the disturbance of in excess of one acre of total land area or which is part of a larger common area of development or sale. The Design -Build Entity shall be responsible for filing the Notice of Intent and for obtaining the Permit. If applicable, the Design -Build Entity shall be solely responsible for preparing and implementing a Stormwater Pollution Prevention Plan ("SWPPP") prior to initiating work on the Project. It shall be the Design -Build Entity's responsibility to evaluate the cost of procuring the Permit and preparing the SWPPP as well as complying with the SWPPP and any necessary revision to the SWPPP to address storm water impacts. The Design -Build Entity shall comply with all requirements of the State Water Resources Control Board. The Design -Build Entity shall include all costs of compliance with specified requirements in the Price. For those Sites where construction activity results in the disturbance of less than one acre of total land area and/or do not need coverage under the Permit, the Design -Build Entity shall be responsible for preparing and implementing an Erosion and Sediment Control Plan in accordance with California Regional Water Quality Control Board Order No. R8- 2009-0030, Order No. R9-2013-0001 as amended by Order Nos. R9-2015-0001 and R9-2015-0100 and any amendment or renewal thereof. D. The Design -Build Entity shall be responsible for procuring, implementing and complying with the provisions of the Permit and the SWPPP, including the standard provisions, monitoring and reporting requirements as required by the Permit. The Design -Build Entity shall provide copies of all reports and monitoring information to the Agency's Representative. The Design -Build Entity shall comply with the lawful requirements of any applicable municipality, the County, drainage authority, and other local agencies regarding discharges of storm water to separate storm drain system or other watercourses under their jurisdiction, including applicable requirements in municipal storm water management programs. E. Failure to comply with laws, regulations, and ordinances listed in this Article is a violation of federal and state law. Notwithstanding any other indemnity contained in this Contract, Design -Build Entity agrees to indemnify and hold harmless the Agency, A2-55 its officials, officers, agents, employees and authorized volunteers from and against any and all claims, demands, losses or liabilities of any kind or nature which the Agency, its officials, officers, agents, employees and authorized volunteers may sustain or incur for noncompliance with the laws, regulations, and ordinances listed above, arising out of or in connection with the Project, except for liability resulting from the sole established negligence, willful misconduct or active negligence of the Agency, its officials, officers, agents, employees or authorized volunteers. Agency reserves the right to defend any enforcement action or civil action brought against the Agency for Design -Build Entity's failure to comply with any applicable water quality law, regulation, or policy. Design -Build Entity hereby agrees to be bound by, and to reimburse the Agency for the costs associated with, any enforcement action and/or settlement reached between the Agency and any relevant enforcement entity. 6.34 Weekly Report. The Design -Build Entity shall prepare and submit to Agency, during both the Construction Documents Phase and the Construction Phase, weekly reports on the Work accomplished during the prior weekly period. Such reports weekly report shall also set forth the Design -Build Entity's projected progress for the forthcoming three weeks. 6.35 Other Reports. The Design -Build Entity will cooperate with Agency in preparing, or causing to be prepared, all or part of, periodic project reports required by state or federal agencies. 6.36 Notice of Labor Dispute. A. If the Design -Build Entity has knowledge that any actual or potential labor dispute is delaying, or threatens to delay, the timely performance of Work on the Project, the Design -Build Entity shall immediately give written notice including all relevant information to Agency. B. The Design -Build Entity agrees to insert the substance of this Article in any subcontract to which a labor dispute may delay the timely performance of Work on the Project, except that each subcontract shall provide that in the event its timely performance is delayed or threatened by delay by any actual or potential labor dispute, the Subcontractor shall immediately notify the next higher tier Subcontractor or the Design -Build Entity, as the case may be, of all relevant information concerning the dispute. 6.37 Documents and Samples At Proiect Site. The Design -Build Entity shall maintain the following at the Project site: A. One current copy of the Contract Documents (including Construction Documents), in good order and marked to record current changes and selections made during construction. B. One copy of the prevailing wage rates applicable to the Project. A2-56 C. The current accepted Project Schedule. D. Shop Drawings, Product Data, and Samples. E. All other required submittals. 6.38 Cutting, Fitting, and Patching. The Design -Build Entity shall do all cutting, fitting, or patching work required to make all parts of the Project come together properly and to allow the Project to receive or be received by the work of Separate Contractors shown upon, or reasonably implied by, the Contract Documents. The Design -Build Entity shall not endanger the Project, or adjacent property by cutting, digging, or otherwise. The Design -Build Entity shall not cut or alter the work of any Separate Contractor without the prior written consent of Agency's Representative. 6.39 Access to Work. Agency, Agency's Representative, their consultants, and other persons authorized by Agency will at all times have access to the Work on the Project wherever it is in preparation or progress. The Design -Build Entity shall provide safe and proper facilities for such access and for inspection. 6.40 Concealed Or Unknown Conditions. A. Except and only to the extent provided otherwise in Articles 9 and 10, by signing the Contract, the Design -Build Entity agrees: 1. To bear the risk of concealed or unknown conditions, if any, which may be encountered in performing the Contract, as described in the Contract Documents, and/or can reasonably be inferred by the Design -Build Entity based on its experience and expertise; and 2. That the Design -Build Entity's Contract Price for the Contract was made with full knowledge of this risk. B. In agreeing to bear the risk of concealed or unknown conditions, the Design -Build Entity understands that, except and only to the extent provided otherwise in Articles 9 and 10, concealed and/or unknown conditions shall not excuse the Design -Build Entity from its obligation to achieve full completion of the Project within the Project Completion Date, and shall not entitle the Design -Build Entity to an adjustment of the Contract Price. C. If concealed or unknown conditions are encountered which require, in the opinion of Agency's Representative, design details which differ from those details shown in the Bridging Documents and Agency's Representative finds that such revised design details will cause an increase or decrease in the cost of, or the time required for performance of the Contract, and if Agency agrees with Agency's Representative's determinations, Agency will issue a Change Order modifying the Contract to provide for the change in design details and to provide for an adjustment in the Contract A2-57 Price and/or Project Completion Date pursuant to Articles 9 and 10 following receipt of a Change Order Request. D. If the Design -Build Entity encounters concealed or unknown conditions that differ materially from those anticipated or expected, the Design -Build Entity shall notify Agency's Representative within three (3) Days in writing of such conditions so that Agency's Representative can determine if such conditions require design details which differ from those design details shown in the Bridging Documents. Design - Build Entity shall be liable to Agency for any extra costs incurred as a result of the Design -Build Entity's failure to give such notice. Design -Build Entity's failure to give such notice shall constitute a waiver by Design -Build Entity of any additional compensation. 6.41 Liability for and Repair of Damaged Work. Unless otherwise covered by the City's Builder's Risk Policy, the Design -Build Entity shall be liable for any and all damages and losses to the Project (whether by fire, theft, vandalism, earthquake, flood or otherwise) prior to Agency's acceptance of the Project as fully completed. 6.42 Environmental Quality Protection A. Landscape and Vegetation Preservation The Design -Build Entity shall exercise care to preserve the natural landscape and vegetation, and shall conduct operations so as to prevent unnecessary destruction, scarring, or defacing of the natural surroundings in the vicinity of the Work. Movement of crews and equipment within the rights -of -way and over routes provided for access to the Work shall be performed in a manner to prevent damage to property. When no longer required, construction roads shall be restored to original contours. Upon completion of the Work, and following removal of construction facilities and required cleanup, land used for construction purposes and not required for the completed installation shall be scarified and regraded, as required, so that all surfaces are left in a condition that will facilitate natural revegetation, provide for proper drainage, and prevent erosion. B. Protected Species If, in the performance of the Work, evidence of the possible occurrence of any Federally listed threatened or endangered plant or animal is discovered, the Design - Build Entity shall notify the Agency Representative immediately, giving the location and nature of the findings. Written confirmation of the evidence, location and nature of the findings shall be forwarded to Agency within 2 Days. The Design -Build Entity shall immediately cease all construction activities in the immediate area of the discovery to the extent necessary to protect the endangered plant or animal. If directed by the Agency Representative, Design -Build Entity will refrain from working in the immediate area, suspend the Work in its entirety, or alter its performance to ensure full compliance with all applicable permits, laws and regulations. Any Agency directed changes to the Work as a result of a siting will be pursuant to the Contract Documents. Any costs or delays incurred by Agency or the Design -Build Entity due A2-58 to unreasonable or false notification of an endangered plant or animal will be borne by the Design -Build Entity. C. Preservation of Historical and Archeological Resources If, in the performance of the Work, Design -Build Entity should unearth cultural resources (for example, human remains, animal bones, stone tools, artifacts and/or midden deposits) through excavation, grading, watering or other means, the Design - Build Entity notify the Agency Representative immediately, giving the location and nature of the findings. The Design -Build Entity shall immediately cease all construction activities in the immediate area of the discovery to the extent necessary to protect the cultural resource. If directed by the Agency Representative, Design - Build Entity will refrain from working in the immediate area, suspend the Work in its entirety, or re -sequence and/or alter its performance to ensure full compliance with all applicable permits, laws and regulations. The Design -Build Entity shall provide such cooperation and assistance as may be necessary to preserve the cultural resources for removal or other disposition. Any Agency directed changes to the Work as a result of the cultural resource will be pursuant to the Contract Documents. Should Design -Build Entity, without permission, injure, destroy, excavate, appropriate, or remove any cultural resource on or adjacent to the Site, it will be subject to disciplinary action, arrest and penalty under applicable law. The Design - Build Entity shall be principally responsible for all costs of mitigation and/or restoration of cultural resources related to the unauthorized actions identified above. Design -Build Entity shall be required to pay for unauthorized damage and mitigation costs to cultural resources (historical and archeological resources) as a result of unauthorized activities that damage cultural resources and shall indemnify Agency pursuant to the Contract Documents. 6.43 Technical Manuals: Spare Parts. A. The Design -Build Entity shall submit technical operation and maintenance information for each item of mechanical, electrical and instrumentation equipment in an organized manner in the Technical Manual. It shall be written so that it can be used and understood by Agency's operation and maintenance staff. The Design - Build Entity shall furnish to Agency six (6) identical Technical Manuals. Each set shall consist of one or more volumes, each of which shall be bound in a standard binder. B. The Design -Build Entity shall furnish to Agency six (6) identical sets of spare parts information for all mechanical, electrical, and instrumentation equipment. The spare parts list shall include the current list price of each spare part. The spare parts list shall include those spare parts which each manufacturer recommends be maintained by Agency in inventory. Each manufacturer or supplier shall indicate the name, address, and telephone number of its nearest outlet of spare parts to assist Agency in ordering. The Design -Build Entity shall cross-reference all spare parts lists to the equipment numbers designated in the Contract Documents. The spare parts lists shall be bound in standard size, 3-ring binder. A2-59 ARTICLE 7 - OTHER WORK AT THE PROJECT SITE 7.1 Related Work At Proiect Site. A. Nothing contained in the Contract Documents shall be interpreted as granting to Design -Build Entity exclusive occupancy at the Project site. Agency reserves the right to award separate contracts for, or to perform with its own forces, construction or operations related to the Work or other construction or operations at or affecting the Project site, including portions of Work on the Project which have been deleted by Change Order. The Design -Build Entity shall cooperate with Agency's employees or through other direct contracts, or have other work performed by utility owners (collectively, "Other Contractors"). If such other work is not noted in the Contract Documents, then written notice thereof will be given to the Design -Build Entity prior to starting any such other work. The Design -Build Entity shall participate with Agency and Separate Contractors in joint review of construction schedules and Project requirements when directed to do so. The Design -Build Entity shall make necessary revisions to the Project Schedule after such joint review. B. Design -Build Entity shall be solely responsible for all costs associated with coordinating its Work with Separate Contractors. Design -Build Entity shall not be entitled to additional compensation from Agency for damages resulting from such simultaneous, collateral, and essential Work. If necessary to avoid or minimize such damage or delay, Design -Build Entity shall redeploy its work forces to other parts of the Work, or adjust its Work schedule including reasonable acceleration of the Work. If a portion of the Work on the Project is dependent upon the proper execution or results of other construction or operations by Agency or Separate Contractors, the Design -Build Entity shall inspect such other design or construction or operations before proceeding with that portion of the Work on the Project. The Design -Build Entity shall promptly report to Agency's Representative apparent discrepancies or defects which render the other design, construction or operations unsuitable to receive the Work on the Project. Unless otherwise directed by Agency's Representative, the Design -Build Entity shall not proceed with the portion of the Work on the Project affected until apparent discrepancies or defects have been corrected. Failure of the Design -Build Entity to so report within a reasonable time after discovering such discrepancies or defects shall constitute an acknowledgment that the other construction or operations by Agency or Separate Contractors is suitable to receive the Work on the Project, except as to defects not then reasonably discoverable. C. Design -Build Entity shall afford each Separate Contractor proper and safe access to the Project site, provide a reasonable opportunity for the introduction and storage of materials and equipment and the execution of such other work, and properly coordinate the Work with theirs. Design -Build Entity shall do all cutting, fitting, and patching of the Work that may be required to properly connect or otherwise make its several parts come together and properly integrate with such other work. Design - Build Entity shall not endanger any work of others by cutting, excavating, or otherwise altering such work; provided, however, that Design -Build Entity may cut or alter others' work with the written consent of Agency's Representative and the others whose work will be affected. A2-60 D. If the proper execution or results of any part of Design -Build Entity's Work depends upon work performed by Separate Contractors, Design -Build Entity shall inspect such other work and promptly report to Agency's Representative in writing any delays, defects, or deficiencies in such other work that render it unavailable or unsuitable for the proper execution and results of Design -Build Entity's Work. Design -Build Entity's failure to so report will constitute an acceptance of such other work as fit and proper for integration with Design -Build Entity's Work except for latent defects and deficiencies in such other work. E. If any claims are made by Separate Contractors arising out of Design -Build Entity's performance of the Work, Design -Build Entity shall be responsible to immediately resolve the dispute and indemnify Agency pursuant to the Contract Documents. F. Agency's Representative shall arrange meetings with Separate Contractors performing work to plan coordination of construction activities but will not be responsible to direct coordination efforts. Any difference or conflict arising between Design -Build Entity and any Separate Contractor shall be submitted to Agency's Representative for a decision in the matter. Design -Build Entity shall comply with direction from Agency's Representative whose decision on coordination matters will be final. 7.2 For Delays by Others. By entering into this Contract, Design -Build Entity acknowledges that there may be Separate Contractors on the Project site whose work will be coordinated with that of Design -Build Entity. Design -Build Entity expressly warrants and agrees that Design - Build Entity will cooperate with Separate Contractors and will do nothing to delay, hinder, or interfere with the work of Separate Contractors, Agency, or Agency's Representative. Design -Build Entity also expressly agrees that, in the event its Work is hindered, delayed, interfered with, or otherwise affected by a Separate Contractor, its sole remedy will be a direct action against the Separate Contractor. Design -Build Entity will have no remedy, and hereby expressly waives any remedy, against Agency or Agency's Representative on account of delay, hindrance, interference, or other event caused by Separate Contractor. 7.3 Design -Build Entity's Delay or Damage. Design -Build Entity shall be liable to Agency and any Separate Contractor for the direct delay and disruption costs or damages incurred by such Separate Contractor as a result of Design -Build Entity's wrongful action or inactions. ARTICLE 8 - SUBCONTRACTORS 8.1 Award of Subcontracts and Other Contracts for Portions of The Work. A. All Subcontractors shall be retained in accordance with the Subletting and Subcontracting Fair Practices Act (Public Contract Code Section 4100 et seq.). The Design -Build Entity shall not, without the consent of Agency: substitute any person or entity as a Subcontractor in place of the Subcontractor designated in the Proposal; or permit any such Subcontractor to be assigned or transferred, or allow it to be performed by any person or entity other than the original Subcontractor listed in the A2-61 Proposal. Any assignment or substitution made without the prior written consent of the awarding authority or not in compliance with the Subletting and Subcontracting Fair Practices Act shall be void, and the assignees shall acquire no rights in the Contract. Any consent, if given, shall not relieve the Design -Build Entity or its Subcontractors from their obligations under the terms of the Contract. All requests by the Design -Build Entity for substitution will be handled through Agency's Representative. B. The Design -Build Entity shall submit to Agency's Representative after selecting Subcontractors pursuant to an open and competitive process, an updated expanded list of Subcontractors, along with their respective addresses, telephone numbers, e- mail addresses and contractor's license numbers. The expanded list of Subcontractors shall be provided and/or updated no later than ten (10) Days after the date which the Design -Build Entity awards a contract for any portion of the Work to a Subcontractor not originally listed in the Design -Build Entity's Proposal. C. Agency has the right to request all documentation that supports the Design -Build Entity's selection of a Subcontractor. Agency shall have the right of final approval as to the qualifications of a Subcontractor to perform its designated scope of Work. Within Agency's discretion, any Subcontractor may be deemed not qualified to perform Work on the Project if Agency or Agency's Representative determines that the Subcontractor fails to meet the requirements of the Contract Documents, or for any other reason. D. Any increase in the cost of the Work on the Project resulting from the replacement or substitution of a Subcontractor pursuant to this Article or as required by Agency or Agency's Representative pursuant to this Article, shall be borne solely by the Design - Build Entity. The Design -Build Entity shall not be entitled to any increase in Contract Price or an extension of Project Completion Date due to such replacement or substitution. E. Any part of the Work on the Project performed for the Design -Build Entity by a Subcontractor shall be pursuant to a written subcontract. Each such subcontract shall require the Subcontractor, to the extent of the work to be performed by the Subcontractor, to be bound to the Design -Build Entity by the terms of the Contract Documents, to assume toward the Design -Build Entity all the obligations and responsibilities which the Design -Build Entity assumes towards the Agency by the Contract Documents, and to perform such portion of the work on the Project in accordance with the Contract Documents. Each such subcontract shall preserve and protect the rights of the Agency under the Contract Documents, with respect to the work to be performed by Subcontractor, so that subcontracting thereof will not prejudice such rights. The Design -Build Entity is responsible for reviewing and coordinating the Work of and among his Subcontractors and Design Professionals. This review and coordination includes, but is not limited to, resolution of any inconsistencies, errors or omissions. 8.2 Contingent Assignment of Subcontracts. The Design -Build Entity hereby assigns to Agency all its interest in first tier subcontracts now or hereafter entered into by the Design -Build Entity for performance of any part of the Work on the Project. The assignment will be effective upon acceptance by Agency A2-62 in writing and only as to those subcontracts which Agency designates in writing. Agency may accept said assignment at any time during the course of the Work on the Project and prior to Final Completion in the event of a suspension or termination of the Design - Build Entity's rights under the Contract Documents. Such assignment is part of the consideration to Agency for entering into the Contract with the Design -Build Entity and may not be withdrawn prior to Final Completion. ARTICLE 9 - CHANGE IN CONTRACT PRICE; CHANGE IN CONTRACT TIMES 9.1 Contract Change Orders. A. Agency, without invalidating the Contract, may order changes in the work consisting of additions, deletions or other revisions, and the Contract Price and/or Contract Time shall be adjusted accordingly. All such changes in the Work shall be authorized by written Change Order and shall be performed under the applicable conditions of the Contract Documents. A Change Order signed by the Design -Build Entity indicates the Design -Build Entity's agreement therewith, including any adjustment in the Contract Price and/or Contract Time, and the full and final settlement of all costs (direct, indirect and overhead) related to the work authorized by the Change Order. No changes in the Work covered by this Contract shall exonerate any surety or any bond given in connection with this Contract. No dispute, disagreement or failure of the Parties to reach agreement on the terms of a Change Order shall relieve the Design -Build Entity from the obligation to proceed with performance of the changed work promptly and expeditiously. Whenever any change is made as provided for herein, such change shall be considered and treated as though originally included in the Contract Documents, and shall be subject to all terms, conditions and provisions of the original Contract Documents. B. Design -Build Entity shall promptly execute changes in the Work as directed in writing by Agency even when the parties have not reached agreement on whether the change increases the scope of Work or affects the Contract Price or Contract Time, if any. All claims for additional compensation to the Design -Build Entity shall be presented in writing. No claim will be considered after the work in question has been done unless a written Change Order has been issued or a timely written notice of claim has been made by Design -Build Entity. Design -Build Entity shall not be entitled to claim or bring suit for damages, whether for loss of profits or otherwise, on account of any decrease or omission of any item or portion of Work to be done. 9.2 Contract Change Order Procedures. A. Agency Directive 1. The Agency may direct changes in the Work, including deletion of Work, by delivering a written work directive. To the extent the work directive results in a change to the Contract Price and/or Contract Time, Design -Build Entity must timely submit a Change Order Request and comply with all Change Order procedures in accordance with this Article. Notwithstanding issuance of a work directive, Design -Build Entity's failure to timely submit a Change Order Request shall constitute a waiver by Design -Build Entity of any adjustment to the Contract Price and/or Contract Time for work performed under the directive. A2-63 The Agency shall not be liable to Design -Build Entity for work performed or omitted by Design -Build Entity in reliance on verbal orders. 2. The Agency shall have the right to order changes in the Work by a unilateral Change Order setting forth the Agency's determination of the reasonable additions or savings in the Contract Price and/or Contract Time. B. Design -Build Entity Change Order Requests 1. The Design -Build Entity agrees that one of the purposes of the Contract is to minimize the risk for Change Orders and reduce the likelihood of Change Orders. Change Order Requests shall be kept to a minimum. 2. The Design -Build Entity may request changes to the Contract Price and/or Contract Time for Agency directed changes in the Work or for Additional Work caused by the acts, errors, or omissions of the Agency, or caused by unforeseen conditions if, and only if, the Design -Build Entity follows the procedures specified in this Article. Work that should or could have been included as part of the Construction Documents or work resulting from ambiguities in the Construction Documents shall not be considered Additional Work and the Agency will not issue a Change Order for said work. 3. If Design -Build Entity intends to initiate a Change Order Request, then Design - Build Entity shall provide the Agency with written notice of the underlying facts and circumstances that give rise to the proposed change. Design -Build Entity shall submit the notice of change/delay prior to performance of the work and no later than five (5) Days after the Agency's work directive or Design -Build Entity discovers the circumstances causing the need for the Change Order. To be considered valid and complete, the notice of change/delay shall include a general statement of the circumstances giving rise to the notice of change/delay and a reasonable order of magnitude estimate of the additional costs and/or time. If the circumstances give rise to both a cost adjustment and time extension, Design -Build Entity shall submit the notice of change and notice of delay concurrently. 4. A Change Order Request will only be deemed timely submitted if it is submitted prior to incurring any expense and within fourteen (14) Days from Design -Build Entity's notice of change/delay. 5. A Change Order Request must state that it is a Change Order Request, state and justify the reason for the request, and specify the amount of any requested adjustment to the Contract Price and/or Contract Time, if any. The Change Order Request shall include all of the following information (unless inapplicable to the change): A detailed description of the circumstances giving rise to the request; A complete itemized cost proposal, including itemized pricing for costs; Supporting documentation for all costs; A time impact analysis showing the impact of the delay to the critical path to completion; If any added costs or information cannot be determined at the time of the Change Order Request, the reason the costs or information cannot be determined at the time; and Certification to the accuracy of the Change Order Request under penalty of perjury. The time impact analysis shall be in the critical path method format and A2-64 shall show the sequencing of all critical and non -critical new activities and/or activity revisions affected by the delay, with logic ties to all affected existing activities noted on the schedule. The Agency may demand, and Design -Build Entity shall provide, any additional information supporting the Change Order Request, including but not limited to native electronic format version of schedules and time impact analyses. Design -Build Entity shall provide the requested additional information within five (5) Days of the request. 6. If the Agency denies the Change Order Request or disagrees with the proposal submitted by Design -Build Entity, it will notify the Design -Build Entity, and the Agency will provide its opinion of the appropriate change to the Contract Price and/or Contract Time. If no agreement can be reached, the Agency shall have the right to order the work by a unilateral Change Order setting forth the Agency's determination of the reasonable additions or savings in the Contract Price and/or Contract Time, if any. The Agency's determination shall become final and binding if the Design -Build Entity fails to submit a Claim in writing to the Agency within fourteen (14) Days of the issuance of the unilateral Change Order, disputing the terms of the unilateral Change Order and providing such supporting documentation for its position as the Agency may reasonably require. 9.3 Change Order Format A. A Change Order signed by the Contractor indicates the Contractor's agreement therewith, including any adjustment in compensation or extension of time, and the full and final settlement of all costs (direct, indirect and overhead) related to the Work authorized by the Change Order. B. The Agency may designate the forms to be used for notices, Change Order Requests, and Change Orders. If so designated, Design -Build Entity may only use such forms. Design -Build Entity shall not reserve a right to assert impact costs, extended job site costs, extended overhead, constructive acceleration and/or actual acceleration beyond what is stated in the Change Order. No Claims shall be allowed for impact, extended overhead costs, constructive acceleration and/or actual acceleration due to a multiplicity of changes and/or clarifications. The Design -Build Entity may not change or modify the Agency's Change Order form in an attempt to reserve additional rights. 9.4 Determining Adiustments to Compensation. A. Limitation on Costs. Design -Build Entity shall not be entitled to any compensation for Work subject to a Change Order except as expressly set forth in this Article. The mark-up added in instances of Additional Work shall constitute the entire amount of profit, any mark- ups, any field or home office overhead costs, including personnel, equipment or office space, any materials, or any costs of equipment idle time for such Work. B. Lump Sum Change Orders. Whenever possible, any changes affecting compensation shall be in a lump sum mutually agreed by the Design -Build Entity and the Agency. A2-65 C. Time and Materials Change Orders. The Agency may direct the Design -Build Entity to proceed with the Additional Work with payment to be made on the basis of actual cost of the labor and materials required to complete the Additional Work. If the Project is federally funded, a time and materials Change Order shall only be issued after a determination that no other Change Order is suitable and the Change Order shall include a ceiling price that the Design -Build Entity exceeds at its own risk. D. Federally Funded Proiects. For any change in price to the Contract, general and administrative expenses shall be negotiated and must conform to the cost principles set forth under at 2 C.F.R. Part 200, subpart E, and profit shall be negotiated as a separate element of the cost. To establish a fair and reasonable profit, consideration must be given to the complexity of the Additional Work to be performed, the risk borne by the Design - Build Entity, the Design -Build Entity's investment, the amount of subcontracting, the quality of its record of past performance, and industry profit rates in the surrounding geographical area for similar work. E. Allowed Costs. Estimates for lump sum quotations and accounting for time -and -material work shall be limited to direct expenditures necessitated specifically by the change and shall be segregated as follows: 1. Labor. The costs of labor will be the actual cost for wages prevailing locally for each craft or type of worker at the time the Additional Work is done, plus employer payments of payroll taxes and insurance, health and welfare, pension, vacation, apprenticeship funds, and other direct costs resulting from federal, state or local laws, as well as assessment or benefits required by lawful collective bargaining agreements. The use of a labor classification which would increase the Additional Work cost will not be permitted unless the Design -Build Entity establishes the necessity for such additional costs. Labor costs for equipment operators and helpers shall be reported only when such costs are not included in the invoice for equipment rental. 2. Materials. The cost of materials reported shall be at the lowest current price at which such materials are locally available in the quantities involved, plus sales tax, freight and delivery. Materials costs shall be based upon supplier or manufacturer's invoice. 3. Tool and Equipment Use. a. Regardless of ownership, the rates to be used in determining equipment use shall not exceed listed rates prevailing locally at equipment rental agencies, A2-66 or distributors, at the time the work is performed. The Design -Build Entity shall furnish cost data supporting the establishment of the rental rate. The rental rate to be applied for use of each items of equipment shall be the rate resulting in the least total cost to the Agency for the total period of use. The Agency shall the make the final determination as to an equitable rental rate for the equipment. No payment will be made for the use of small tools, which have a replacement value of $1,000 or less. b. The rental time to be paid for equipment shall be the time the equipment is in productive operation on the Additional Work being performed. Rental time will not be allowed while equipment is inoperative due to breakdowns. c. All equipment shall, in the opinion of the Agency, be in good working condition and suitable for the purpose for which the equipment is to be used. Equipment with no direct power unit shall be powered by a unit of at least the minimum rating recommended by the manufacturer. d. Before construction equipment is used on any Additional Work, the Design - Build Entity shall plainly stencil or stamp an identifying number thereon at a conspicuous location, and shall furnish to the Agency, in duplicate, a description of the equipment and its identifying number. e. When hourly rates are listed, any part of an hour less than 30 minutes of operation shall be considered to be 1/2-hour of operation, and any part of an hour greater than 30 minutes will be considered one hour of operation. When daily rates are listed, any part of a day less than 4 hours operation shall be considered to be 1/2-day of operation. 4. Allowed Mark-up. The allowed mark-up for any and all overhead (including supervision and home and field office costs) and profit on work added to the Contract shall be determined in accordance with the following provisions: a. "Net Cost" is defined as the actual costs of labor, materials and tools and equipment only, excluding overhead and profit. The costs of applicable insurance and bond premium will be reimbursed to the Design -Build Entity and Subcontractors at cost only, without mark-up. Design -Build Entity shall provide the Agency with documentation of the costs, including but not limited to payroll records, invoices, and such other information as the Agency may reasonably request. b. For Work performed by the Design -Build Entity's forces the allowed mark-up shall not exceed fifteen (15%) percent of labor costs, ten percent (10%) of material costs, and ten percent (10%) of the cost of tools and equipment use. c. For Work performed by a Subcontractor, the added cost for overhead and profit shall not exceed fifteen percent (15%) of the Subcontractor's Net Cost of the Work to which the Design -Build Entity may add up to five percent (5%) of the Subcontractor's Net Cost. A2-67 d. For Work performed by a sub -subcontractor, the added cost for overhead and profit shall not exceed fifteen percent (15%) of the sub -subcontractor's Net Cost for Work to which the Subcontractor and Design -Build Entity may each add up to an additional five percent (5%) of the Net Cost of the lower tier subcontractor. e. No additional mark-up will be allowed for lower tier subcontractors, and in no case shall the added cost for overhead and profit payable by the Agency exceed twenty-five percent (25%) of the Net Cost as defined herein, of the party that performs the Work. f. Calculation of the mark-up will be subject to the limitations above and to calculation as further detailed in (b)(B)(5) above. 5. Documentation of Time -and -Material Costs. a. T&M Daily Sheets. Design -Build Entity must submit timesheets, materials invoices, records of equipment hours, and records of rental equipment hours to the Agency's for an approval signature each day that Work is performed on a time -and - material basis. The Engineer's signature on time sheets only serves as verification that the Work was performed and is not indicative of the Agency's agreement to Design -Build Entity's entitlement to the cost. b. T&M Summary Sheet. Design -Build Entity shall submit a T&M Summary Sheet, which shall include total actual costs, within five (5) Days following completion of Additional Work on a time -and -material basis. Design -Build Entity's total actual cost shall be presented in a summary table in an electronic spreadsheet file by labor, material, equipment, and any other costs, along with documentation supporting the costs. Design -Build Entity's failure to submit the T&M Summary Sheet within five (5) Days of completion of the Additional Work will result in Design -Build Entity's waiver for any reimbursement of any costs associated with the Additional Work. 6. Excluded Costs. The following costs or any other home or field office overhead costs, all of which are to be considered administrative costs covered by the Design -Build Entity's mark-up, shall not be allowed costs and shall not be included in any lump sum proposals or time -and -materials invoices: a. Overhead Cost. Payroll costs and other compensation of Design -Build Entity's officers, executives, principals, general managers, engineers, architects, estimators, attorneys, auditors, accountants, purchasing and contracting agents, timekeepers, clerks, and other personnel employed by Design -Build Entity A2-68 whether at the Site or in Design -Build Entity's principal office or any branch office, material yard, or shop for general administration of the Work; b. Office Expenses. Expenses of Design -Build Entity's principal and branch offices; c. Capital Expenses. Any part of Design -Build Entity's capital expenses, including interest on Design -Build Entity's capital employed for the Additional Work and charges against Design -Build Entity for delinquent payments; d. Negligence. Costs due to the negligence of Design -Build Entity or any Subcontractor or Supplier, or anyone directly or indirectly employed by any of them or for whose acts any of them may be liable, including without limitation the correction of Defective Work, disposal of materials or equipment wrongly supplied, and making good any damage to property; i. Small Tools. Cost of small tools valued at less than $1,000 and that remain the property of Design -Build Entity; ii. Administrative Costs. Costs associated with the preparation of Change Orders (whether or not ultimately authorized), cost estimates, or the preparation or filing of Claims; iii. Anticipated Lost Profits. Expenses of Design -Build Entity associated with anticipated lost profits or lost revenues, lost income or earnings, lost interest on earnings, or unpaid retention; iv. Home Office Overhead. Costs derived from the computation of a "home office overhead" rate by application of the Eichleay, Allegheny, burden fluctuation, or other similar methods; v. Special Consultants and Attorneys. Costs of special consultants or attorneys, whether or not in the direct employ of Design -Build Entity, employed for services specifically related to the resolution of a Claim, dispute, or other matter arising out of or relating to the performance of the Additional Work. vi. Other. A2-69 Other overhead or general expense costs of any kind and the cost of any item not specifically and expressly included in the Contract Documents; including but not limited to: submittals, drawings, field drawings, shop drawings, including submissions of drawings; field inspection; general superintendence; computer services; reproduction services; salaries of project engineer, superintendent, timekeeper, storekeeper, and secretaries; janitorial services; small tools, incidentals and consumables; temporary on - site facilities (offices, telephones, high speed internet access, plumbing, electrical power, lighting; platforms, fencing, water); surveying; estimating; protection of work; handling and disposal fees; final cleanup; other incidental work; related warranties; insurance and bond premiums. vii. Compliance with Federal Cost Principles. If the Project is federally funded, any costs that are not allowable, reasonable and allocable to the Project, under generally accepted accounting principles and the applicable federal requirements. 9.5 Design -Build Entity's Wavier of Further Relief. A. DESIGN -BUILD ENTITY'S FAILURE TO PROVIDE A COMPLETE AND TIMELY NOTICE OF A CHANGE ORDER REQUEST OR TO COMPLY WITH ANY OTHER REQUIREMENT OF THIS ARTICLE, SHALL CONSTITUTE A WAIVER BY DESIGN -BUILD ENTITY OF THE RIGHT TO AN ADJUSTMENT OF THE CONTRACT PRICE AND/OR PROJECT COMPLETION DATE ON ACCOUNT OF SUCH CIRCUMSTANCES AND A WAIVER OF ANY RIGHT TO FURTHER RECOURSE OR RECOVERY BY REASON OF OR RELATED TO SUCH CHANGE BY MEANS OF THE CLAIMS DISPUTE RESOLUTION PROCESS OR BY ANY OTHER LEGAL PROCESS OTHERWISE PROVIDED FOR UNDER APPLICABLE LAWS. B. Design -Build Entity recognizes and acknowledges that timely submission of a formal written notice of change/delay and Change Order Request, whether or not the circumstances of the change may be known to the Agency or available to the Agency through other means, is not a mere formality but is of crucial importance to the ability of the Agency to promptly identify, prioritize, evaluate and mitigate the potential effects of changes. Any form of informal notice, whether verbal or written (including, without limitation, statements in requests for information, statements in Submittals, statements at any job meeting or entries on monthly reports, daily logs or job meeting minutes), that does not strictly comply with the formal requirements of this Article, shall accordingly be insufficient. 9.6 Aaencv Reservation of Rights. By signing the Contract, the parties agree that Agency has the right to do any or all of the following, which are reasonable and within the contemplation of the parties: A. To order changes in the Work, including without limitation: Changes to correct errors or omissions caused by Agency, if any, in the Contract Documents; Changes A2-70 resulting from Agency's decision to change the Work subsequent to execution of the Contract; and Changes due to unforeseen conditions. B. To suspend Work on the Project or any part thereof. C. To delay Work on the Project, including without limitation, delays resulting from the failure of Agency or Agency's Representative to timely perform any Contract obligation and delays for Agency's convenience which may be subject to adjustment to the Contract Time and/or Contract Price. ARTICLE 10 -TIME FOR COMPLETION; LIQUIDATED DAMAGES 10.1 Progress and Completion. The Design -Build Entity shall proceed expeditiously with adequate forces and shall achieve full completion of the Work by the Project Completion Date. If Agency's Representative determines and notifies the Design -Build Entity that the Design -Build Entity's progress is such that the Design -Build Entity will not achieve full completion of the Work by the Project Completion Date, the Design -Build Entity shall immediately and at no additional cost to Agency, take all measures necessary, including working such overtime, additional shifts, Sundays, or holidays as may be required to ensure that the entire Project is completed within the Project Completion Date. Upon receipt of such notice from Agency's representative, the Design -Build Entity shall immediately notify Agency's Representative of all measures to be taken to ensure full completion of the Work within the Project Completion Date. The Design -Build Entity shall reimburse Agency for any extra costs or expenses (including the reasonable value of any services provided by Agency's employees) incurred by Agency as the result of such measures. 10.2 Time for Completion. The time for completion set forth in Contract shall commence: (1) on the date stated in the Notice to Proceed, or (2) if the Notice to Proceed does not specify a commencement date, then on the date of the Notice to Proceed and shall be completed by Design -Build Entity in the time specified in the Contract Documents. The Agency is under no obligation to consider early completion of the Project; and the Project Completion Date shall not be amended by the Agency's receipt or acceptance of the Design -Build Entity's proposed earlier completion date. Any difference in time between the Design -Build Entity's early completion and the Project Completion Date shall be considered a part of the Project float. Design -Build Entity shall not be entitled to compensation, and the Agency will not compensate Design -Build Entity, for delays which impact early completion. Design -Build Entity shall not, under any circumstances, receive additional compensation from the Agency (including but not limited to indirect, general, administrative or other forms of overhead costs) for the period between the time of earlier completion proposed by the Design -Build Entity and the Project Completion Date. 10.3 Liauidated Damages. If the Work is not completed as stated in the Contract Documents, it is understood that the Agency will suffer damage. In accordance with Government Code section 53069.85, being impractical and infeasible to determine the amount of actual damage, it is agreed that Design -Build Entity shall pay to the Agency as fixed and liquidated damages, and A2-71 not as a penalty, the sum stipulated in the Contract for each calendar day of delay until the Work is fully completed. Design -Build Entity and its surety shall be liable for any liquidated damages. Any money due or to become due the Design -Build Entity may be retained to cover liquidated damages. 10.4 Inclement Weather. Design -Build Entity shall abide by the Agency's determination of what constitutes inclement weather. Time extensions for inclement weather shall only be granted when the Work stopped during inclement weather is on the critical path of the Project schedule. Design -Build Entity shall not be entitled to reverse liquidated damages for time extensions resulting from inclement weather. 10.5 Extension of Time. Design -Build Entity's entitlement to an extension of the Contract Time is limited to a City - caused extension of the critical path, reduced by the Design -Build Entity's concurrent delays, and established by a proper time impact analysis. Design -Build Entity shall not be charged liquidated damages because of any delays in completion of the Work due to unforeseeable causes beyond the control and without the fault or negligence of Design - Build Entity (or its Subcontractors or Suppliers). The Agency shall ascertain the facts and extent of delay and grant extension of time for completing the Work when, in its judgment, the facts justify such an extension. Design -Build Entity shall not be entitled to an adjustment in the Contract Times for delays within the control of Design -Build Entity. Delays attributable to and within the control of a Subcontractor or Supplier shall be deemed to be delays within the control of Design -Build Entity. 10.6 Force Maieure. In accordance with Sections 10.5 above, the Design -Build Entity shall not be charged liquidated damages, and the Agency shall not be responsible, for any delays resulting from a Force Majeure Event. If a delay to the critical path results from a Force Majeure Event, the Design -Build Entity will be entitled to a time extension but will not receive an adjustment to the Contract Price or any other compensation. Such a non-compensable adjustment shall be Design -Build Entity's sole and exclusive remedy for such delays. 10.7 No Damaaes for Reasonable Delay. The Agency's liability to Design -Build Entity for delays for which the Agency is responsible shall be limited to only an extension of time unless such delays were unreasonable under the circumstances. In no case shall the Agency be liable for any costs which are borne by the Design -Build Entity in the regular course of business, including, but not limited to, home office overhead and other ongoing costs. Damages caused by unreasonable Agency delay shall be based on actual costs only, no proportions or formulas shall be used to calculate any delay damages. 10.8 Procedure for Time Extensions and Delav Damages. Design -Build Entity shall not be entitled to any extension of time or any reverse liquidated damages unless Design -Build Entity properly notices the delay and adjustment to compensation and requests a Change Order in accordance with the A2-72 Contract Documents. Design -Build Entity's failure to timely and fully comply with the Change Order procedures in the Contract Documents shall constitute a waiver of Design -Build Entity's right to a time extension or reverse liquidated damages. ARTICLE 11 - TEST AND INSPECTIONS; CORRECTION, REMOVAL, OR ACCEPTANCE OF DEFECTIVE WORK; NOTICE OF DEFECTS 11.1 Notice of Defective Work. Prompt notice of all Defective Work of which Agency or Agency's Representative has actual knowledge will be given to Design -Build Entity. Defective Work may be rejected, corrected, or accepted as provided in the Contract Documents. 11.2 Access to Work. Agency, Agency's Representative, their consultants and other representatives and personnel, independent testing laboratories, and governmental agencies with jurisdictional interests will have access to the Project site and the Work at reasonable times for their observation, inspection, and testing. Design -Build Entity shall provide them proper and safe conditions for such access and advise them of Design -Build Entity's safety procedures and programs. 11.3 Tests and Inspections. A. Design -Build Entity shall give Agency's Representative timely notice of readiness of the Work for all required inspections, tests, or approvals and shall cooperate with inspection and testing personnel to facilitate required inspections or tests. B. Except as provided by the Contract Documents, Agency shall employ and pay for the services of an independent testing laboratory to perform all inspections, tests, or approvals required by the Contract Documents. C. If Applicable Laws of any public body having jurisdiction require any Work (or part thereof) specifically to be inspected, tested, or approved by an employee or other representative of such public body, Design -Build Entity shall assume full responsibility for arranging and obtaining such inspections, tests, or approvals, pay all costs in connection therewith, and furnish Agency's Representative the required certificates of inspection or approval. D. Design -Build Entity shall be responsible for arranging and obtaining and shall pay all costs in connection with any inspections, tests, or approvals required for Agency and Agency's Representative's acceptance of materials or equipment to be incorporated in the Work; or acceptance of materials, mix designs, or equipment submitted for approval prior to Design -Build Entity's purchase thereof for incorporation in the Work. Such inspections, tests, or approvals shall be performed by organizations acceptable to Agency. E. Agency will provide inspection during normal working hours from 8:00 a.m. to 5:00 p.m. Monday through Friday. Inspection before or after this time will be charged to the contractor as reimbursable inspection time. Inspections on weekends requires A2-73 two days' notice for review and approval. Upon written request and approval the 8.5 hour working day may be changed to other limits subject to Agency ordinance. 11.4 Uncovering Work. A. If any Work (or the work of others) that is to be inspected, tested, or approved is covered by Design -Build Entity without written concurrence of Agency's Representative, Design -Build Entity shall, if requested by Agency's Representative, uncover such Work for observation. B. Uncovering Work shall be at Design -Build Entity's expense unless Design -Build Entity has given Agency's Representative timely notice of Design -Build Entity's intention to cover the same and Agency's Representative has not acted with reasonable promptness in response to such notice. C. If Design -Build Entity has given Agency's Representative timely notice of Design - Build Entity's intention to cover the work and Agency's Representative has not acted with reasonable promptness in response to such notice, and Agency's Representative later considers it necessary or advisable that covered Work be observed by Agency's Representative or inspected or tested by others, Design -Build Entity, at Agency's Representative's request, shall uncover, expose, or otherwise make available for observation, inspection, or testing as Agency's Representative may require, that portion of the Work in question, furnishing all necessary labor, material, and equipment. 1. If it is found that the uncovered Work is defective, Design -Build Entity shall pay all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to such uncovering, exposure, observation, inspection, and testing, and of satisfactory replacement or reconstruction (including but not limited to all costs of repair or replacement of work of others); and Agency shall be entitled to an appropriate decrease in the Contract Price. 2. If the uncovered Work is not found to be defective, Design -Build Entity shall be allowed an increase in the Contract Price and/or an extension of the Contract Time, directly attributable to such uncovering, exposure, observation, inspection, testing, replacement, and reconstruction. 11.5 Agency Mav Stop The Work. If the Work is defective, Agency may in its sole discretion order Design -Build Entity to stop the Work, or any portion thereof, until the cause for such order has been eliminated. All delays associated with the stop Work order will be the responsibility of the Design - Build Entity. 11.6 Correction of Defective Work. A. Promptly after receipt of written notice, the Design -Build Entity shall (1) correct Defective Work that becomes apparent during the progress of the Work on the Project and (2) replace, repair, or restore to Agency's satisfaction any other parts of A2-74 the Work on the Project and any other real or personal property which is damaged or destroyed as a result of Defective Work or the correction of Defective Work. The Design -Build Entity shall promptly commence such correction, replacement, repair, or restoration upon notice from Agency's Representative or Agency, but in no case later than fourteen (14) Days after receipt of such notice; and the Design -Build Entity shall diligently and continuously prosecute such correction to completion. The Design -Build Entity shall bear all costs of such correction, replacement, repair, or restoration, and all losses resulting from such Defective Work, including additional testing, inspection, and compensation for Agency's Representative's services and expenses. The Design -Build Entity shall perform corrective Work on the Project at such times that are acceptable to Agency and in such a manner as to avoid, to the extent practicable, disruption to Agency's activities. When correcting Defective Work, Design -Build Entity shall take no action that would void or otherwise impair Agency's special warranty and guarantee, if any, on said Work. B. If immediate correction of Defective Work is required for life safety or the protection of property and is performed by Agency or Separate Contractors, the Design -Build Entity shall pay to Agency all reasonable costs of correcting such Defective Work. The Design -Build Entity shall replace, repair, or restore to Agency's satisfaction any other parts of the Construction Work and any other real or personal property which is damaged or destroyed as a result of such Defective Work or the correction of such Defective Work. C. The Design -Build Entity shall remove from the Project site portions of the Construction Work and materials which are not in accordance with the Contract Documents and which are neither corrected by the Design -Build Entity nor accepted by Agency. D. Enforcement of the Design -Build Entity's express warranties and guarantees to repair contained in the Contract Documents shall be in addition to and not in limitation of any other rights or remedies Agency may have under the Contract Documents or at law or in equity for Defective Work. Nothing contained in this Article shall be construed to establish a period of limitation with respect to other obligations of the Design -Build Entity under the Contract Documents. 11.7 Acceptance of Defective Work. A. If, instead of requiring correction or removal and replacement of Defective Work, Agency prefers to accept it, Agency may do so. Design -Build Entity shall pay all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) attributable to Agency's evaluation of and determination to accept such Defective Work and for the diminished value of the Work. B. If any acceptance of Defective Work occurs prior to release of the Project retention, a Change Order will be issued incorporating the necessary revisions in the Contract Documents with respect to the Work, and Agency shall be entitled to an appropriate decrease in the Contract Price, reflecting the diminished value of Work and all costs incurred by Agency. A2-75 C. If the Project retention is held in an escrow account as permitted by the Contract Documents, Design -Build Entity will promptly alert the escrow holder, in writing, of the amount of retention to be paid to Agency. D. If the acceptance of defective Work occurs after release of the Project retention, an appropriate amount will be paid by Design -Build Entity to Agency. 11.8 Agency Mav Correct Defective Work. A. If Design -Build Entity fails within a reasonable time after written notice from Agency's Representative to correct Defective Work, or to remove and replace rejected Work as required by Agency, or if Design -Build Entity fails to perform the Work in accordance with the Contract Documents, or if Design -Build Entity fails to comply with any other provision of the Contract Documents, Agency may, after seven (7) Days written notice to Design -Build Entity, correct, or remedy any such deficiency. B. In connection with such corrective or remedial action, Agency may exclude Design - Build Entity from all or part of the Site, take possession of all or part of the Work and suspend Design -Build Entity's services related thereto, take possession of Design - Build Entity's tools, appliances, construction equipment and machinery at the Site, and incorporate in the Work all materials and equipment stored at the Site or for which Agency has paid Design -Build Entity but which are stored elsewhere. Design - Build Entity shall allow Agency and Agency's Representative, and the agents, employees, other contractors, and consultants of each of them, access to the Site to enable Agency to exercise the rights and remedies to correct the defective work. C. All claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) incurred or sustained by Agency correcting the defective work will be charged against Design -Build Entity, and a Change Order will be issued incorporating the necessary revisions in the Contract Documents with respect to the Work; and Agency shall be entitled to an appropriate decrease in the Contract Price. Such claims, costs, losses and damages will include but not be limited to all costs of repair, or replacement of work of others destroyed or damaged by correction, removal, or replacement of Defective Work. D. If the Change Order is executed after all payments under the Contract have been paid by Agency and the Project Retention is held in an escrow account as permitted by the Contract Documents, Design -Build Entity will promptly alert the escrow holder, in writing, of the amount of Retention to be paid to Agency. E. If the Change Order is executed after release of the Project Retention, an appropriate amount will be paid by Design -Build Entity to Agency. F. Design -Build Entity shall not be allowed an extension of the Contract Time because of any delay in the performance of the Work attributable to Agency correcting defective work. A2-76 ARTICLE 12 - PAYMENTS TO DESIGN -BUILD ENTITY AND COMPLETION 12.1 Schedule of Values. The Design -Build Entity shall submit a schedule of values to the Agency before the first Application for Payment, allocating the entire Contract Price to the various portions of the Work. The schedule of values shall be prepared in the form, and supported by the data to substantiate its accuracy, required by the Agency. This schedule, unless objected to by the Agency, shall be used as a basis for reviewing the Design -Build Entity's Applications for Payment. Any changes to the schedule of values shall be submitted to the Agency and supported by such data to substantiate its accuracy as the Agency may require, and unless objected to by the Agency, shall be used as a basis for reviewing the Design -Build Entity's subsequent Applications for Payment. 12.2 Applications for Payments. A. By the twenty-fifth (25th) day of each month Design -Build Entity shall submit to Agency's Representative for review an Application for Payment filled out and signed by Design -Build Entity covering the Work completed as of the date of the Application for Payment and accompanied by such supporting documentation as is required by the Contract Documents. If payment is requested on the basis of materials and equipment not incorporated in the Work but delivered and suitably stored at the Site or at another location agreed to in writing, the Application for Payment shall also be accompanied by a bill of sale, invoice, or other documentation warranting that Agency has received the materials and equipment free and clear of all Liens and evidence that the materials and equipment are covered by appropriate property insurance or other arrangements to protect Agency's interest therein, all of which must be satisfactory to Agency. B. Beginning with the second Application for Payment, each Application shall include an affidavit executed by the Design -Build Entity stating that it has paid all amounts due on account of the Work paid by Agency in the prior Applications for Payment. 12.3 Review of Applications. A. Agency's Representative will either indicate in writing a recommendation of payment to Agency or return the Application for Payment to Design -Build Entity indicating in writing Agency's Representative's reasons for refusing to recommend payment. In the latter case, Design -Build Entity may make the necessary corrections and resubmit the Application for Payment. B. In taking action on the Design -Build Entity's Applications for Payment, the Agency shall be entitled to rely on the accuracy and completeness of the information furnished by the Design -Build Entity and shall not be deemed to represent that the Agency has made a detailed examination, audit or arithmetic verification of the documentation submitted in support of the Application for Payment or other supporting data; that the Agency has made exhaustive or continuous on -site inspections; or that the Agency has made examinations to ascertain how or for what purposes the Design -Build Entity has used amounts previously paid on account of the Contract. Such examinations, audits and verifications, if required by the Agency, will be performed by the Agency's auditors acting in the sole interest of the Agency. A2-77 C. By recommending any such payment Agency's Representative will not thereby be deemed to have represented that: 1. Inspections made to check the quality or the quantity of the Work as it has been performed have been exhaustive, extended to every aspect of the Work in progress, or involved detailed inspections of the Work beyond the responsibilities specifically assigned to Agency's Representative in the Contract Documents; or 2. There may not be other matters or issues between the parties that might entitle Design -Build Entity to be paid additionally by Agency or entitle Agency to withhold payment to Design -Build Entity. D. Neither Agency's Representative's review of Design -Build Entity's Work for the purposes of recommending payments nor Agency's Representative's recommendation of any payment, including final payment, will impose responsibility on Agency's Representative: 1. To supervise, direct, or control the Work; 2. For the means, methods, techniques, sequences, or procedures of construction, or the safety precautions and programs incident thereto; 3. For Design -Build Entity's failure to comply with Applicable Laws applicable to Design -Build Entity's performance of the Work; 4. To make any examination to ascertain how or for what purposes Design -Build Entity has used the moneys paid on account of the Contract Price; or 5. To determine that title to any of the Work, materials, or equipment has passed to Agency free and clear of any Liens. E. Agency's Representative may refuse to recommend the whole or any part of any payment due to subsequently discovered evidence or the results of subsequent inspections or tests. Agency retains the right to revise or revoke any such payment recommendation previously made, to such extent as may be necessary in Agency's opinion to protect Agency from loss. 12.4 Payment Becomes Due. Thirty (30) Days after presentation of an undisputed and properly submitted Application for Payment to Agency's Representative, and subject to Agency's Representative's recommendation, subject to the modifications above, the amount recommended will become due, and when due will be paid by Agency to Design -Build Entity. 12.5 Retention and Securities in Lieu of Retention. A. Unless Project has been deemed substantially complex as noted in the Contract Documents, Agency will retain five percent (5%) of the amount invoiced in accordance with Applicable Laws. A2-78 B. Pursuant to Public Contract Code section 22300, Design -Build Entity may substitute securities for any moneys withheld as a retention by Agency to ensure performance under the Contract. At the request and expense of Design -Build Entity, securities equivalent to the amount withheld shall be deposited with Agency, or with a state or federally chartered bank in this state as the escrow agent, who shall then pay those moneys to Design -Build Entity. Upon satisfactory completion of the Contract, the securities shall be returned to Design -Build Entity. 1. Alternatively, Design -Build Entity may request, and Agency shall make payment of retentions earned directly to the escrow agent selected by the Design -Build Entity. At the expense of Design -Build Entity, Design -Build Entity may direct the investment of the payments into securities and Design -Build Entity shall receive the interest earned on the investments upon the same terms provided for in Public Contract Code section 22300 for securities deposited by Design -Build Entity. Upon satisfactory completion of the Contract, Design -Build Entity shall receive from the escrow agent all securities, interest, and payments received by the escrow agent when Agency authorizes the escrow agent to release these funds to the Design -Build Entity, pursuant to the terms of Public Contract Code section 22300. C. Securities eligible for investment shall include those listed in Government Code section 16430, bank or savings and loan certificates of deposit, interest -bearing demand deposit accounts, standby letters of credit, or any other security mutually agreed to by Design -Build Entity and Agency. D. Design -Build Entity shall be the beneficial Agency of any securities substituted for moneys withheld and shall receive any interest thereon. E. The escrow agreement shall be in the form of the Escrow Agreement provided as part of the Contract Documents. 12.6 Agency's Reduction in Recommended Payment. A. In addition to reductions recommended by Agency's Representative, Agency may refuse to make payment of the full amount recommended by Agency's Representative because: 1. Claims have been made against Agency on account of Design -Build Entity's performance or furnishing of the Work. 2. Stop Payment Notices or Liens have been filed in connection with the Work. 3. Defective Work not remedied. 4. Failure of Design -Build Entity to make proper payments to its subcontractors or suppliers. 5. Completion of the Contract if there exists a reasonable doubt that the Work can be completed for the unpaid Contract balance. A2-79 6. Damage to another contractor or third party. 7. Amounts which may be due the Agency for claims against Design -Build Entity. 8. Failure of Design -Build Entity to keep the record (as -built") drawings up to date. 9. Failure to provide updates on the construction schedule. 10. Site cleanup. 11. Failure of the Design -Build Entity to comply with requirements of the Contract Documents. 12. Liquidated Damages. B. Upon completion of the Contract, Agency will reduce the final Contract Price to reflect costs charged to the Design -Build Entity, back charges or payments withheld pursuant to the Contract Documents. 12.7 Design -Build Entity's Warranty of Title. Design -Build Entity warrants and guarantees that title to all Work, materials, and equipment covered by any Application for Payment, whether incorporated in the Project or not, will pass to Agency no later than the time of payment free and clear of all Liens. 12.8 Partial Utilization. Agency reserves the right to occupy or utilize any portion of the Work at any time before completion, and such occupancy or use shall not constitute acceptance of any part of Work covered by this Contract. This use shall not relieve the Design -Build Entity of its responsibilities under the Contract. 12.9 Final Inspection. Upon written notice from Design -Build Entity that the entire Work is complete, Agency's Representative will promptly make a final inspection with Agency and Design -Build Entity and will notify Design -Build Entity in writing of all particulars in which this inspection reveals that the Work is incomplete or defective. Design -Build Entity shall immediately take such measures as are necessary to complete such Work or remedy such deficiencies. 12.10 Final Acceptance. After Design -Build Entity has, in the opinion of Agency's Representative, satisfactorily completed all corrections identified during the final inspection and has delivered, in accordance with the Contract Documents, all maintenance and operating instructions, schedules, guarantees, bonds, certificates or other evidence of insurance, certificates of inspection, marked -up record documents, and other documents required by the Contract Documents, Agency shall execute and file with the County in which the Project is located a Notice of Completion, constituting final acceptance and completion of the Project, except as may be expressly noted. A2-80 12.11 Final Payment. A. Application for Payment. 1. Upon execution of the Notice of Completion, Design -Build Entity may submit a final accounting for the cost of the Work and a final Application for Payment. Final payment, constituting the entire unpaid balance of the Contract Price. 2. Prior to Final Payment, the Agency may conduct an audit of the Work or notify the Design -Build Entity that it will not conduct an audit and issue a final Certificate for Payment. If the Agency conducts an audit of the Work, the Agency will either issue to the Design -Build Entity a final Certificate for Payment, or notify the Design -Build Entity in writing of the Agency's reasons for withholding a certificate. If the Agency's auditors report the cost of the Work as substantiated by the Design -Build Entity's final accounting to be less than claimed by the Design -Build Entity, the Design -Build Entity shall be entitled to make a claim. Pending a final resolution of the disputed amount, the Agency shall pay the Design -Build Entity the amount certified in the Agency's final Certificate for Payment. 3. The final Application for Payment shall be accompanied (except as previously delivered) by: a. All documentation called for in the Contract Documents, including but not limited to the evidence of insurance; b. Consent of the surety to final payment; c. A fully completed Conditional Waiver and Release on Final Payment. B. Agency's Representative's Review of Application and Acceptance. If, on the basis of Agency's Representative's observation of the Work during construction and final inspection, and Agency's Representative's review of the final Application for Payment and accompanying documentation as required by the Contract Documents, Agency's Representative is satisfied that the Work has been completed and Design -Build Entity has satisfied all other requirements for final payment, Agency's Representative will indicate in writing Agency's Representative's recommendation of payment and present the Application for Payment to Agency for payment. Otherwise, Agency's Representative will return the Application for Payment to Design -Build Entity, indicating in writing the reasons for refusing to recommend final payment, in which case Design -Build Entity shall make the necessary corrections and resubmit the Application for Payment. C. Payment Becomes Due. Within sixty (60) Days after the presentation to Agency's Representative of the proper and complete final Application for Payment and accompanying documentation, the amount recommended by Agency's Representative, less any sum Agency is entitled to set off pursuant to the Contract Documents, will become due and will be paid by Agency to Design -Build Entity. A2-81 D. Waiver of Claims. The making and acceptance of final payment will constitute a waiver of all Claims by Design -Build Entity against Agency other than those previously made in accordance with the requirements herein and expressly acknowledged by Agency in writing as still unsettled. ARTICLE 13 -SUSPENSION OF WORK AND COMPLETION 13.1 Agency Mav Suspend Work. A. Agency may, at its sole option, decide to suspend at any time the performance of all or any portion of the Work by notice in writing to Design -Build Entity. Such notice of suspension of Work will designate the amount and type of plant, labor, and equipment to be committed to the Project during the period of suspension. Design - Build Entity shall use its best efforts to utilize its plant, labor, and equipment in such a manner as to minimize costs associated with suspension. B. Upon receipt of any such notice, Design -Build Entity shall, unless the notice requires otherwise: 1. Immediately discontinue Work on the date and to the extent specified in the notice; 2. Place no further orders or subcontracts for material, services, or facilities with respect to suspended Work other than to the extent required in the notice; 3. Promptly make every reasonable effort to obtain suspension upon terms satisfactory to Agency's Representative of all orders, subcontracts, and rental agreements to the extent they relate to performance of Work suspended; and 4. Continue to protect and maintain the Work including those portions on which Work has been suspended. C. Except as provided by this article, as full and complete compensation for such suspension, Design -Build Entity shall be granted an adjustment in the Contract Price based on a negotiated daily rate that reflects the Design -Build Entity's actual costs associated with the demobilized condition of the Site (and as a result will be less than the Daily Rate contained in the Special Conditions) and an extension of the Contract Times equal to the number of days performance of Work is suspended; provided, however, that no adjustment of Contract Price or extension of Contract Times shall be granted if the suspension results from Design -Build Entity's non- compliance with the requirements of the Contract. 13.2 Aaencv Mav Terminate for Cause. A. Agency may, without prejudice to any other right or remedy, serve written notice upon Design -Build Entity of its intention to terminate this Contract in whole or in part if the Design -Build Entity: (i) refuses or fails to prosecute the Work or any part thereof with such diligence as will ensure its completion within the Project Completion Date; A2-82 (ii) fails to complete the Work within the required time; (iii) files a bankruptcy petition or is adjudged a bankruptcy; (iv) makes a general assignment for the benefit of its creditors; (v) has a receiver appointed; (vi) refuses or fails to supply enough properly skilled workers or proper materials to complete the Work; (vii) fails to make prompt payment to subcontractors or for material or labor; (viii) disregards Applicable Laws, other requirements or instructions of Agency; or (ix) violates any of the provisions of the Contract Documents. B. The Notice of Default and Intent to Terminate shall state the reasons for termination. Unless within five (5) Days after the service of such notice, Design -Build Entity resolves the circumstances giving rise to the Notice of Default to Agency's satisfaction, or makes arrangements acceptable to Agency for the required corrective action, Agency may terminate this Contract. In such case, Design -Build Entity shall not be entitled to receive any further payment until the Work has been finished. Agency may take over and complete the Work by any method it may deem appropriate, including enforcement of the Project Performance Bond. Design -Build Entity and its surety shall be liable to Agency for any excess costs or other damages incurred by Agency to complete the Work. If Agency takes over the Work, Agency may, without liability for so doing, take possession of and utilize in completing the Work such materials, appliances, plant, and other property belonging to the Design - Build Entity as may be on the Site. 13.3 Aaencv Mav Terminate for Convenience. A. In addition to its right to terminate this Contract for default, Agency may terminate the Contract, in whole or in part, at any time upon seven (7) Days written notice to Design -Build Entity. The Notice of Termination shall specify that the termination is for the convenience of Agency, the extent of termination, and the effective date of such termination ("Effective Date of Termination"). B. After receipt of Notice of Termination, and except as directed by Agency, the Design - Build Entity shall, regardless of any delay in determining or adjusting any amounts due under this Termination for Convenience clause, immediately proceed with the following obligations: 1. Stop Work as specified in the Notice. 2. Complete any Work specified in the Notice of Termination in a least cost/shortest time manner while still maintaining the quality called for under the Contract Documents. 3. Leave the Site and any other property upon which the Design -Build Entity was working in a safe and sanitary manner such that it does not pose any threat to the public health or safety. 4. Terminate all subcontracts and purchase orders to the extent that they relate to the portions of the Work terminated. 5. Place no further subcontracts or orders, except as necessary to complete the remaining portion of the Work. A2-83 6. Submit to Agency, within fifteen (15) Days from the Notice of Termination, all of the documentation called for by the Contract Documents to substantiate all costs incurred by the Design -Build Entity for labor, materials and equipment through the Notice of Termination. Any documentation substantiating costs incurred by the Design -Build Entity solely as a result of Agency's exercise of its right to terminate this Contract pursuant to this clause, which costs the Design -Build Entity is authorized under the Contract Documents to incur, shall: (i) be submitted to and received by Agency no later than thirty (30) Days after the Effective Date of the Notice of Termination; (ii) describe the costs incurred with particularity; and (iii) be conspicuously identified as "Termination Costs Occasioned by Agency's Termination for Convenience." C. Agency's total liability to Design -Build Entity by reason of the termination shall be limited to the total (without duplication of any items) of: 1. The reasonable cost to the Design -Build Entity for all Work performed prior to the Effective Date of Termination, including the Work done to secure the Project for termination. Reasonable cost may not exceed the applicable percentage completion values derived from the progress schedule and the schedule of values. Deductions shall be made for cost of materials to be retained by the Design -Build Entity, cost of Work defectively performed, amounts realized by sale of materials, and for other appropriate credits or offsets against cost of Work as allowed by the Contract Documents. 2. When, in Agency's opinion, the cost of any item of Work is excessively high due to costs incurred to remedy or replace defective or rejected Work, reasonable cost to be allowed will be the estimated reasonable cost of performing the Work in compliance with requirements of the Contract Documents and excessive actual cost shall be disallowed. 3. Any Work required by the Termination for Convenience that is not included in Contract Documents will be negotiated pursuant to the Contract Change Order provisions. 4. Reasonable costs to the Design -Build Entity of handling material returned to vendors, delivered to Agency or otherwise disposed of as directed by Agency. 5. A reasonable allowance for the Design -Build Entity's internal administrative costs in preparing termination claim. 6. Reasonable demobilization costs, and reasonable payments made to Subcontractors or suppliers on account of termination. D. In no event shall Agency be liable for unreasonable costs incurred by the Design - Build Entity or subcontractors after receipt of a Notice of Termination. Such non- recoverable costs include, but are not limited to, the cost of or anticipated profits on Work not performed as of the date of termination, post -termination employee salaries, unreasonable post -termination administrative expenses, post -termination overhead or unabsorbed overhead, surety costs of any type, attorney fees of any type, and all other costs relating to prosecution of a claim or lawsuit. A2-84 E. Agency shall have no obligation to pay the Design -Build Entity under this Article unless and until the Design -Build Entity provides Agency with updated and acceptable as-builts and Record Documents for Work completed prior to termination as required by the Contract Documents. F. In arriving at the amount due the Design -Build Entity under this clause there shall be deducted in whole, or in the appropriate part(s) if the termination is partial: 1. All unliquidated advances or other payments on account previously made to the Design -Build Entity, including without limitation all payments which are applicable to the terminated portion of the Contract Documents, 2. Any claim Agency may have against the Design -Build Entity in connection with the Work or any amounts that may be withheld in accordance with the Contract Documents, and 3. The agreed price for, or proceeds of sale of, any materials, supplies, or other things kept by the Design -Build Entity and not otherwise recovered by or credited to Agency. G. Design -Build Entity shall not be paid on account of loss of anticipated profits or revenue or other economic loss or consequential damages arising out of or resulting from such termination. H Notwithstanding any other provision of this Article, when immediate action is necessary to protect life and safety or to reduce significant exposure or liability, Agency may immediately order Design -Build Entity to cease Work until such safety or liability issues are addressed to the satisfaction of Agency or the Contract is terminated. I. If Agency terminates Design -Build Entity for cause, and if it is later determined that the termination was wrongful, such default termination shall automatically be converted to and treated as a termination for convenience. In such event, Design - Build Entity shall be entitled to receive only the amounts payable under this section, and Design -Build Entity specifically waives any claim for any other amounts or damages, including, but not limited to, any claim for consequential damages or lost profits. ARTICLE 14 - CLAIMS, DISPUTE AVOIDANCE AND RESOLUTION 14.1 Procedure for Resolving Claims A. Design -Build Entity shall timely comply with any and all requirement of the Contract Documents pertaining to notices and requests for changes to the Contract Price and/or the Project Completion Date, including but not limited to all requirements of Article 9 and Article 14.1, as a prerequisite to filing any Claim governed by this Article. The failure to timely submit a notice of delay or notice of change, or to timely submit a Chang Order Request, or to timely provide any other notice or request required herein shall constitute a waiver of the right to further pursue the Claim under the Contract or at law. A2-85 B. Intent. Effective January 1, 1991, Section 20104 et seq., of the California Public Contract Code prescribes a process utilizing informal conferences, non -binding judicial supervised mediation, and judicial arbitration to resolve disputes on construction claims of $375,000 or less. Effective January 1, 2017, Section 9204 of the Public Contract Code prescribes a process for negotiation and mediation to resolve disputes on construction claims. The intent of this Article is to implement Sections 20104 et seq. and Section 9204 of the California Public Contract Code. This Article shall be construed to be consistent with all applicable law, including but not limited to these statutes. C. Claims. For purposes of this Article, "Claim" means a separate demand by the Design -Build Entity for (1) a time extension, including without limitation relief from damages or penalties for delay assessed by Agency, (2) payment of money or damages arising from Work done by or on behalf of the Design -Build Entity and payment of which is not otherwise expressly provided for or the Design -Build Entity is not otherwise entitled, or (3) payment of an amount which is disputed by Agency. A "Claim" does not include any demand for payment for which the Design -Build Entity has failed to provide notice, submit a Change Order Request, or otherwise failed to follow any procedures contained in the Contract Documents. D. Filinq Claims. Claims governed by this Article may not be filed unless and until the Design -Build Entity completes any and all requirements of the Contract Documents pertaining to notices and requests for changes to the Contract Price and/or the Project Completion Date, and Design -Build Entity's request for a change has been denied in whole or in part. Claims governed by this Article must be filed no later than thirty (30) Days after a request for change has been denied in whole or in part or after any other event giving rise to the Claim. The Claim shall be submitted in writing to the Agency and shall include on its first page the following words in 16 point capital font: "THIS IS A CLAIM." The Claim shall include the all information and documents necessary to substantiate the Claim, including but not limited to those identified below. Nothing in this Article is intended to extend the time limit or supersede notice requirements otherwise provided by Contract Documents. Failure to follow such contractual requirements shall bar any Claims or subsequent proceedings for compensation or payment thereon. E. Documentation. The Design -Build Entity will submit the claim justification in the following format: 1. Summary description of Claim including basis of entitlement, merit and amount of time or money requested, with specific reference to the Contract Document provisions pursuant to which the Claim is made; 2. List of documents relating to the Claim; A2-86 a. Specifications; b. Drawings; c. Clarifications (Requests for Information); d. Schedules; and e. Other. 3. Chronology of events and correspondence; 4. Narrative analysis of Claim merit; 5. Analysis of Claim cost, including calculations and supporting documents; 6. Time impact analysis in the form required by the Contract Documents or, if the Contract Documents do not require a particular format, CPM format, if an adjustment of the Contract Time is requested; and 7. Cover letter and certification of validity of the Claim. F. Agency Response to Claim. Upon receipt of a Claim pursuant to this Article, Agency shall conduct a reasonable review of the Claim and, within a period not to exceed 45 days of receipt of the Claim, or as extended by mutual agreement, shall provide a written statement identifying what portion of the Claim is disputed and what portion is undisputed. Any payment due on an undisputed portion of the Claim will be processed and made within 60 days after Agency issues its written response. 1. If Agency needs approval from its governing body to provide Design -Build Entity a written statement as set forth above, and the governing body does not meet within the 45 days or within the mutually agreed to extension of time following receipt of a Claim, Agency shall have up to three (3) days following the next publicly noticed meeting of the governing body after the 45-day period, or extension, expires to provide Design -Build Entity a written statement identifying the disputed portion and the undisputed portion of the Claim. 2. Agency may request, in writing, within 30 days of receipt of the claim, any additional documentation supporting the Claim or relating to defenses or Claims Agency may have. If additional information is needed thereafter, it shall be provided upon mutual agreement of the Agency and the Design -Build Entity. Agency's written response shall be submitted 30 days (15 days if the Claim is less than $50,000) after receiving the additional documentation, or within the same period of time taken by the Design -Build Entity to produce the additional information, whichever is greater. G. Meet and Confer Conference. A2-87 If the Design -Build Entity disputes Agency's response, or if Agency fails to respond within the statutory time period(s), the Design -Build Entity may so notify Agency, in writing, within 15 days of the receipt of the response or the failure to respond, and demand an informal conference to meet and confer for settlement of those portions of the Claim that remain in dispute. Upon such demand, Agency shall schedule a meet and confer conference within 30 Days. H. Mediation. Within 10 business days following the conclusion of the meet and confer conference, if the Claim or any portion of the Claim remains in dispute, the Agency shall provide the Design -Build Entity a written statement identifying the portion of the Claim that remains in dispute and the portion that is undisputed. Any payment due on an undisputed portion of the Claim shall be processed and made within 60 Days after the Agency issues its written statement. Any disputed portion of the Claim, as identified by the Design -Build Entity in writing, shall be submitted to nonbinding mediation, with the Agency and the Design -Build Entity sharing the associated costs equally. The public entity and Design -Build Entity shall mutually agree to a mediator within 10 business days after the disputed portion of the Claim has been identified in writing, unless the parties agree to select a mediator at a later time. 1. If the parties cannot agree upon a mediator, each party shall select a mediator and those mediators shall select a qualified neutral third party to mediate with regard to the disputed portion of the Claim. Each party shall bear the fees and costs charged by its respective mediator in connection with the selection of the neutral mediator. 2. For purposes of this Article, mediation includes any nonbinding process, including, but not limited to, neutral evaluation or a dispute review board, in which an independent third party or board assists the parties in dispute resolution through negotiation or by issuance of an evaluation. Any mediation utilized shall conform to the timeframes in this Article. 3. Unless otherwise agreed to by the Agency and the Design -Build Entity in writing, the mediation conducted pursuant to this section shall excuse any further obligation under Section 20104.4 to mediate after litigation has been commenced. 4. The mediation shall be held no earlier than the date the Design -Build Entity completes the Work or the date that the Design -Build Entity last performs Work, whichever is earlier. All unresolved Claims shall be considered jointly in a single mediation, unless a new unrelated Claim arises after mediation is completed. I. Procedures After Mediation. If following the mediation, the Claim or any portion remains in dispute, the Design - Build Entity must file a Claim pursuant to Chapter 1 (commencing with Section 900) and Chapter 2 (commencing with Section 910) of Part 3 of Division 3.6 of Title 1 of the Government Code prior to initiating litigation. For purposes of those provisions, the running of the period of time within which a Claim must be filed shall be tolled from the time the Design -Build Entity submits his or her written Claim pursuant to A2-88 subdivision (a) until the time the Claim is denied, including any period of time utilized by the meet and confer conference. J. Civil Actions. The following procedures are established for all civil actions filed to resolve Claims of $375,000 or less: 1. Within 60 Days, but no earlier than 30 Days, following the filing or responsive pleadings, the court shall submit the matter to non -binding mediation unless waived by mutual stipulation of both parties or unless mediation was held prior to commencement of the action in accordance with Public Contract Code section 9204 and the terms of this Contract. The mediation process shall provide for the selection within 15 Days by both parties of a disinterested third person as mediator, shall be commenced within 30 Days of the submittal, and shall be concluded within 15 Days from the commencement of the mediation unless a time requirement is extended upon a good cause showing to the court. 2. If the matter remains in dispute, the case shall be submitted to judicial arbitration pursuant to Chapter 2.5 (commencing with Section 1141.10) of Title 3 of Part 3 of the Code of Civil Procedure, notwithstanding Section 1114.11 of that code. The Civil Discovery Act of 1986 (Article 3 (commencing with Section 2016) of Chapter 3 of Title 3 of Part 4 of the Code of Civil Procedure) shall apply to any proceeding brought under this subdivision consistent with the rules pertaining to judicial arbitration. In addition to Chapter 2.5 (commencing with Section 1141.10) of Title 3 of Part 3 of the Code of Civil Procedure, (A) arbitrators shall, when possible, be experienced in construction law, and (B) any party appealing an arbitration award who does not obtain a more favorable judgment shall, in addition to payment of costs and fees under that chapter, also pay the attorney's fees on appeal of the other party. K. Government Code Claim Procedures. 1. This Article does not apply to tort claims and nothing in this Article is intended nor shall be construed to change the time periods for filing tort claims or actions specified by Chapter 1 (commending with Section 900) and Chapter 2 (commencing with Section 910) of Part 3 of Division 3.5 of Title 1 of the Government Code. 2. In addition to any and all requirements of the Contract Documents pertaining to notices of and requests for adjustment to the Contract Time, Contract Price, or compensation or payment for Additional Work, disputed Work, construction claims and/or changed conditions, the Design -Build Entity must comply with the claim procedures set forth in Government Code Section 900, et seq. prior to filing any lawsuit against the Agency. 3. Such Government Code claims and any subsequent lawsuit based upon the Government Code claims shall be limited to those matters that remain unresolved after all procedures pertaining to adjustment of the Contract Time or Contract Price for Additional Work, disputed Work, construction claims, and/or changed conditions have been followed by Design -Build Entity. If Design -Build A2-89 Entity does not comply with the Government Code claim procedure or the prerequisite contractual requirements, Design -Build Entity may not file any action against the Agency. 4. A Government Code claim must be filed no earlier than the date the Work is completed or the date the Design -Build Entity last performs Work on the Project, whichever occurs first. A Government Code claim shall be inclusive of all unresolved Claims known to Design -Build Entity or that should reasonably by known to Design -Build Entity excepting only new unrelated Claims that arise after the Government Code claim is submitted. L. Non -Waiver. The Agency's failure to respond to a Claim from the Design -Build Entity within the time periods described in this Article or to otherwise meet the time requirements of this Article shall result in the Claim being deemed rejected in its entirety, and shall not constitute a waiver of any rights under this Article. 14.2 Litigation. Any claims, disputes, or controversies between the parties arising out of or related to the Contract, which have not been resolved in accordance with the procedures set forth herein shall be resolved in a court of competent jurisdiction. 14.3 Duty to Continue Performance. Unless provided to the contrary in the Contract Documents, Design -Build Entity shall continue to perform the Work and Agency shall continue to satisfy its payment obligations to Design -Build Entity, pending the final resolution of any dispute or disagreement between Design -Build Entity and Agency. ARTICLE 15 - MISCELLANEOUS PROVISIONS 15.1 Limitations On Aaencv's Responsibilities. Agency shall not supervise, direct, or have control or authority over, nor be responsible for, the Design -Build Entity's means, methods, techniques, sequences, or procedures of design or construction, or the safety precautions and programs incident thereto, or for any failure of the Design -Build Entity to comply with Applicable Laws applicable to the performance of the Work. Agency will not be responsible for the Design -Build Entity's failure to perform the Project in accordance with the Contract Documents. 15.2 Successors The parties do for themselves, their heirs, executors, administrators, successors, and assigns agree to the full performance of all of the provisions contained in this Contract. The Design -Build Entity may not either voluntarily or by action of law, assign any obligation assumed by the Design -Build Entity hereunder without the prior written consent of the Agency. A2-90 15.3 Cumulative Remedies. The duties and obligations imposed by these General Conditions and the rights and remedies available hereunder to the parties hereto are in addition to, and are not to be construed in any way as a limitation of, any rights and remedies available to any or all of them which are otherwise imposed or available by Applicable Laws, by special warranty or guarantee, or by other provisions of the Contract Documents. The provisions of this Article will be as effective as if repeated specifically in the Contract Documents in connection with each particular duty, obligation, right, and remedy to which they apply. 15.4 Survival of Obligations. All representations, indemnifications, warranties, and guarantees made in, required by, or given in accordance with the Contract Documents, as well as all continuing obligations indicated in the Contract Documents, will survive final payment, completion, and acceptance of the Project or termination or completion of the Contract or termination of the services of the Design -Build Entity. 15.5 Controlling Law. Notwithstanding any subcontract or other contract with any Subcontractor, Supplier, or other person or organization performing any part of the Project, this Contract shall be governed by the law of the State of California excluding any choice of law provisions. 15.6 Jurisdiction: Venue. The Design -Build Entity and any Subcontractor, supplier, or other person or organization performing any part of the Project agree that any action or suits at law or in equity arising out of or related to the proposal process, award, or performance of the Project shall be maintained in the Superior Court of Riverside County, California, and expressly consent to the jurisdiction of said court, regardless of residence or domicile, and agree that said court shall be a proper venue for any such action. 15.7 Headings. Article and paragraph headings are inserted for convenience only and do not constitute parts of these General Conditions. 15.8 Agency's Right to Audit. A. The Design -Build Entity shall make available to Agency for auditing, all relevant accounting records and documents, and other financial data, and upon request, shall submit true copies of requested records to Agency. If the Design -Build Entity submits a Change Order Request or a Claim to Agency, Agency shall have the right to audit the Design -Build Entity's books, records, documents, and other evidence to the extent they are relevant. B. The right to audit shall include the right to examine books, records, documents, and other evidence and accounting procedures and practices, sufficient to discover and verify all direct and indirect costs of whatever nature claimed to have been incurred or anticipated to be incurred and for which the claim has been submitted, including A2-91 but not limited to job cost reports, estimates, proposals, bids, proposal papers, documents of other work administered by the Design -Build Entity's home office, and any and all other documentation relied upon by the Design -Build Entity to obtain this Contract. Agency shall have the right to make and take copies of any records examined. C. The right to audit shall include the right to inspect the Design -Build Entity's plans, or such parts thereof, as may be or have been engaged in the performance of the Project. The Design -Build Entity further agrees that the right to audit encompasses all subcontracts and is binding upon Subcontractors. The right to audit provided herein shall be exercisable through such representatives as Agency deems desirable during the Design -Build Entity's normal business hours at the Design -Build Entity's office. D. In accordance with Government Code Section 8546.7, records of both Agency and the Design -Build Entity shall be subject to examination and audit by the State Auditor General for a period of three (3) years after final payment. The Design -Build Entity shall make available to Agency any of the Design -Build Entity's other documents related to the Project immediately upon request of Agency. In addition to the State Auditor's rights described above, Agency shall have the right to examine and audit all books, estimates, records, contracts, documents, Proposals, subcontracts, and other data of the Design -Build Entity (including electronic records, computations and projections) related to negotiating, pricing, or performing the Project in order to evaluate the accuracy and completeness of the cost or pricing data, for a period of four (4) years after final payment. 15.9 Assignment. A. Design -Build Entity shall not assign, transfer, convey, sublet, or otherwise dispose of this Contract or any part thereof including any claims, without prior written consent of Agency. Any assignment without the written consent of Agency shall be void. Any assignment of money due or to become due under this Contract shall be subject to a prior lien for services rendered or Material supplied for performance of Work called for under the Contract Documents in favor of all persons, firms, or corporations rendering such services or supplying such Materials to the extent that claims are filed pursuant to the Civil Code, the Code of Civil Procedure or the Government Code. B. As set forth in Public Contract Code section 7103.5, in entering into a public works contract or a subcontract to supply goods, services, or materials pursuant to a public works contract, the contractor or subcontractor offers and agrees to assign to the awarding body all rights, title, and interest in and to all causes of action it may have under Section 4 of the Clayton Act (15 U.S.C. § 15) or under the Cartwright Act (Chapter 2 (commencing with Section 16700) of Part 2 of Division 7 of the Business and Professions Code), arising from purchases of goods, services, or materials pursuant to the public works contract or the subcontract. This assignment shall be made and become effective at the time the awarding body tenders final payment to the contractor, without further acknowledgment by the parties. 15.10 All Legal Provisions Included. A2-92 A. Design -Build Entity shall give all notices and comply with all federal, state and local laws, ordinances, rules and regulations bearing on conduct of work as indicated and specified by their terms. References to specific laws, rules or regulations in this Contract are for reference purposes only, and shall not limit or affect the applicability of provisions not specifically mentioned. If Design -Build Entity observes that drawings and specifications are at variance therewith, he shall promptly notify Agency in writing and any necessary changes shall be adjusted as provided for in this Contract for changes in Work. If Design -Build Entity performs any Work knowing it to be contrary to such laws, ordinances, rules and regulations, and without such notice to Agency, he shall bear all costs arising therefrom. B. Design -Build Entity shall be responsible for familiarity with the Americans with Disabilities Act ("ADA") (42 U.S.C. § 12101 et seq.). The Work will be performed in compliance with ADA laws, rules and regulations. Design -Build Entity shall comply with the Historic Building Code, including, but not limited to, as it relates to the ADA, whenever applicable. C. Design -Build Entity acknowledges and understands that, pursuant to Public Contract Code section 20676, sellers of "mined material" must be on an approved list of sellers published pursuant to Public Resources Code section 2717(b) in order to supply mined material for this Contract. D. No Agency official or representative who is authorized in such capacity and on behalf of Agency to negotiate, supervise, make, accept, or approve, or to take part in negotiating, supervising, making, accepting or approving any engineering, inspection, construction or material supply contract or any subcontract in connection with construction of the Work, shall be or become directly or indirectly interested financially in the Contract. E. All provisions of law required to be inserted in the Contract or Contract Documents pursuant to any Applicable Laws shall be and are inserted herein. If through mistake, neglect, oversight, or otherwise, any such provision is not herein inserted or inserted in improper form, upon the application of either party, the Contract or Contract Documents shall be changed by Agency, at no increase in the Contract Price or Contract Time, so as to strictly comply with the Applicable Laws and without prejudice to the rights of either party hereunder. 15.11 State License Board Notice. Contractors are required by law to be licensed and regulated by the Design -Build Entity's State License Board which has jurisdiction to investigate complaints against contractors if a complaint regarding a patent act or omission is filed within four (4) years of the date of the alleged violation. A complaint regarding a latent act or omission pertaining to structural defects must be filed within ten (10) years of the date of the alleged violation. Any questions concerning a contractor may be referred to the Registrar, the Contractors' State License Board, P.O. Box 26000, Sacramento, California 95826. 15.12 Noise. A2-93 A. The Design -Build Entity shall use only such equipment on the Project and in such state of repair so that the emission of sound therefrom is within the noise tolerance level of that equipment as established by CAL -OSHA. B. The Design -Build Entity shall comply with the most restrictive of the following: (1) local sound control and noise level rules, regulations and ordinances and (2) the requirements contained in these Contract Documents, including hours of operation requirements. No internal combustion engine shall be operated on the Project without a muffler of the type recommended by the manufacturer. Should any muffler or other control device sustain damage or be determined to be ineffective or defective, the Design -Build Entity shall promptly remove the equipment and shall not return that equipment to the Project site until the device is repaired or replaced. Noise and vibration level requirements shall apply to all equipment on the jobsite or related to the Project, including but not limited to, trucks, transit mixers or transit equipment that may or may not be owned by the Design -Build Entity. 15.13 Change In Name Or Nature of Design -Build Entity's Legal Entity. Should a change be contemplated in the name or nature of the Design -Build Entity's legal entity, the Design -Build Entity shall first notify Agency in order that proper steps may be taken to have the change reflected in the Contract Documents and all related documents. No change of the Design -Build Entity's name or nature will affect Agency's rights under the Contract Documents, including but not limited to the bonds and insurance. 15.14 Complete Contract. The Contract Documents constitute the full and complete understanding of the parties and supersede any previous agreements or understandings, oral or written, with respect to the subject matter hereof. The Contract may be modified only by a written instrument signed by both parties or as otherwise provided in the Contract Documents. 15.15 Notice of Third Party Claims. Pursuant to Public Contract Code section 9201, Agency shall provide Design -Build Entity with timely notification of the receipt of any third -party claim relating to the Contract. 15.16 Severabilitv of Provisions. If any one or more of the provisions contained in the Contract Documents should be invalid, illegal, or unenforceable in any respect, the validity, legality, and enforceability of the remaining provisions contained herein shall not in any way be affected or impaired thereby. 15.17 Correction of Errors and Omissions. The Design -Build Entity agrees to correct any error or omission in the Construction Documents or Contract Documents at no additional cost to Agency. A2-94 15.18 Severabilitv of Provisions. If any one or more of the provisions contained in the Contract Documents should be invalid, illegal, or unenforceable in any respect, the validity, legality, and enforceability of the remaining provisions contained herein shall not in any way be affected or impaired thereby. 15.19 Correction of Errors and Omissions. The Contract Documents shall not be construed in favor of or against any party, but shall be construed as if all parties prepared the Contract Documents. END OF GENERAL CONDITIONS A2-95 ATTACHMENT 3 SPECIAL CONDITIONS ARTICLE 1 - MODIFICATIONS TO THE GENERAL CONDITIONS Reserved. ATTACHMENT 4 PERFORMANCE BOND KNOW ALL PERSONS BY THESE PRESENTS: THAT WHEREAS, THE CITY OF PALM DESERT ("Agency") has awarded to TILDEN- COIL CONSRUCTORS, INC. ("DBE") an agreement for DEVELOPMENT SERVICES LOBBY RENOVATION (hereinafter referred to as the "Project"). WHEREAS, the work to be performed by the DBE is more particularly set forth in the Contract Documents for the Project dated , (hereinafter referred to as "Contract Documents"), the terms and conditions of which are expressly incorporated herein by reference; and WHEREAS, the DBE is required by said Contract Documents to perform the terms thereof and to furnish a bond for the faithful performance of said Contract Documents. NOW, THEREFORE, we, , the undersigned DBE and as Surety, a corporation organized and duly authorized to transact business under the laws of the State of California, are held and firmly bound unto the Agency in the sum of dollars, ($ ), said sum being not less than one hundred percent (100%) of the total amount of the Contract, for which amount well and truly to be made, we bind ourselves, our heirs, executors and administrators, successors and assigns, jointly and severally, firmly by these presents. THE CONDITION OF THIS OBLIGATION IS SUCH, that, if the DBE, his or its heirs, executors, administrators, successors or assigns, shall in all things stand to and abide by, and well and truly keep and perform the covenants, conditions and agreements in the Contract Documents and any alteration thereof made as therein provided, on its part, to be kept and performed at the time and in the manner therein specified, and in all respects according to their intent and meaning; and shall faithfully fulfill all obligations including the one (1) year guarantee of all materials and workmanship; and shall indemnify and save harmless the Agency, its officers and agents, as stipulated in said Contract Documents, then this obligation shall become null and void; otherwise it shall be and remain in full force and effect. As a part of the obligation secured hereby and in addition to the face amount specified therefore, there shall be included costs and reasonable expenses and fees including reasonable attorney's fees, incurred by Agency in enforcing such obligation. The obligations of Surety hereunder shall continue so long as any obligation of DBE remains. Nothing herein shall limit the Agency's rights or the DBE or Surety's obligations under the Contract, law or equity, including, but not limited to, California Code of Civil Procedure section 337.15. A4-97 Whenever DBE shall be, and is declared by the Agency to be, in default under the Contract Documents, the Surety shall remedy the default pursuant to the Contract Documents, or shall promptly, at the Agency's option: (1) Take over and complete the Project in accordance with all terms and conditions in the Contract Documents; or (2) Obtain a Bid or Bids for completing the Project in accordance with all terms and conditions in the Contract Documents and upon determination by Surety of the lowest responsive and responsible Bidder, arrange for a Contract between such Bidder, the Surety and the Agency, and make available as work progresses sufficient funds to pay the cost of completion of the Project, Tess the balance of the Contract price, including other costs and damages for which Surety may be liable. The term "balance of the Contract price" as used in this paragraph shall mean the total amount payable to DBE by the Agency under the Contract and any modification thereto, less any amount previously paid by the Agency to the DBE and any other set offs pursuant to the Contract Documents. (3) Permit the Agency to complete the Project in any manner consistent with California law and make available as work progresses sufficient funds to pay the cost of completion of the Project, less the balance of the Contract price, including other costs and damages for which Surety may be liable. The term "balance of the Contract price" as used in this paragraph shall mean the total amount payable to DBE by the Agency under the Contract and any modification thereto, less any amount previously paid by the Agency to the DBE and any other set offs pursuant to the Contract Documents. Surety expressly agrees that the Agency may reject any contractor or subcontractor which may be proposed by Surety in fulfillment of its obligations in the event of default by the DBE. Surety shall not utilize DBE in completing the Project nor shall Surety accept a Bid from DBE for completion of the Project if the Agency, when declaring the DBE in default, notifies Surety of the Agency's objection to DBE's further participation in the completion of the Project. The Surety, for value received, hereby stipulates and agrees that no change, extension of time, alteration or addition to the terms of the Contract Documents or to the Project to be performed thereunder shall in any way affect its obligations on this bond, and it does hereby waive notice of any such change, extension of time, alteration or addition to the terms of the Contract Documents or to the Project. A4-98 IN WITNESS WHEREOF, we have hereunto set our hands and seals this day of , 20 . Design -Build Entity By: President Surety By: Attorney -in -Fact The rate of premium on this bond is per thousand. The total amount of premium charges, $ (The above must be filled in by corporate attorney.) THIS IS A REQUIRED FORM Any claims under this bond may be addressed to: (Name and Address of Surety) (Name and Address of Agent or Representative for service of process in California, if different from above) (Telephone number of Surety and Agent or Representative for service of process in California) NOTE: A copy of the Power -of -Attorney to local representatives of the bonding company must be attached hereto. A4-99 Notary Acknowledgment A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. STATE OF CALIFORNIA COUNTY OF On , 20, before me, , Notary Public, personally appeared , who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. Signature of Notary Public WITNESS my hand and official seal. OPTIONAL Though the information below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent removal and reattachment of this form to another document. CAPACITY CLAIMED BY SIGNER DESCRIPTION OF ATTACHED DOCUMENT ❑ Individual ❑ Corporate Officer Partner(s) Title(s) ❑ Limited ❑ General ❑ Attorney -In -Fact ❑ Trustee(s) ❑ Guardian/Conservator ❑ Other: Signer is representing: Name Of Person(s) Or Entity(ies) A4-100 Title or Type of Document Number of Pages Date of Document Signer(s) Other Than Named Above ATTACHMENT 5 PAYMENT BOND (LABOR AND MATERIALS) KNOW ALL MEN BY THESE PRESENTS: THAT WHEREAS, the CITY OF PALM DESERT ("Agency"), by action taken or a resolution passed November 18, 2021, has awarded to TILDEN-COIL CONSTRUCTORS, INC., hereinafter designated as the "Principal," a contract ("Contract") for the work described as follows: ("Project"); and WHEREAS, said Principal is required to furnish a bond in connection with said Contract; providing that if said Principal or any of its Subcontractors shall fail to pay for any materials, provisions, provender, equipment, or other supplies used in, upon, for or about the performance of the work contracted to be done, or for any work or labor done thereon of any kind, or for amounts due under the Unemployment Insurance Code or for any amounts required to be deducted, withheld, and paid over to the Employment Development Department from the wages of employees of said Principal and its Subcontractors with respect to such work or labor the Surety on this bond will pay for the same to the extent hereinafter set forth. NOW THEREFORE, we, the Principal and as Surety, are held and firmly bound unto the Agency in the penal sum of dollars ($ ) lawful money of the United States of America, for the payment of which sum well and truly to be made, we bind ourselves, our heirs, executors, administrators, successors and assigns, jointly and severally, firmly by these presents. THE CONDITION OF THIS OBLIGATION IS SUCH that if said Principal, his or its subcontractors, heirs, executors, administrators, successors or assigns, shall fail to pay any of the persons named in Section 9100 of the Civil Code, fail to pay for any materials, provisions or other supplies, used in, upon, for or about the performance of the Work contracted to be done, or for any work or labor thereon of any kind, or amounts due under the Unemployment Insurance Code with respect to work or labor performed under the Contract, or for any amounts required to be deducted, withheld, and paid over to the Employment Development Department or Franchise Tax Board from the wages of employees of the DBE and his subcontractors pursuant to Section 18663 of the Revenue and Taxation Code, with respect to such Work and labor the Surety or Sureties will pay for the same, in an amount not exceeding the sum herein above specified, and also, in case suit is brought upon this bond, all litigation expenses incurred by the Agency in such suit, including reasonable attorneys' fees, court costs, expert witness fees and investigation expenses. This bond shall inure to the benefit of any of the persons named in Section 9100 of the Civil Code so as to give a right of action to such persons or their assigns in any suit brought upon this bond. It is further stipulated and agreed that the Surety on this bond shall not be exonerated or released from the obligation of this bond by any change, extension of time for performance, addition, alteration or modification in, to, or of any contract, plans, specifications, or agreement pertaining or relating to any scheme or work of improvement herein above described, or pertaining or relating to the furnishing of labor, materials, or equipment therefore, nor by any change or modification of any terms of payment or extension of the time for any payment pertaining or relating to any scheme or work of improvement herein above described, nor by any A5-101 rescission or attempted rescission or attempted rescission of the contract, agreement or bond, nor by any conditions precedent or subsequent in the bond attempting to limit the right of recovery of claimants otherwise entitled to recover under any such Contract or agreement or under the bond, nor by any fraud practiced by any person other than the claimant seeking to recover on the bond and that this bond be construed most strongly against the Surety and in favor of all persons for whose benefit such bond is given, and under no circumstances shall Surety be released from liability to those for whose benefit such bond has been given, by reason of any breach of Contract between the owner or Agency and original DBE or on the part of any obligee named in such bond, but the sole conditions of recovery shall be that claimant is a person described in Section 9100 of the Civil Code, and has not been paid the full amount of his claim and that Surety does hereby waive notice of any such change, extension of time, addition, alteration or modification herein mentioned and the provisions of Sections 2819 and 2845 of the California Civil Code. IN WITNESS WHEREOF, two (2) identical counterparts of this instrument, each of which shall for all purposes be deemed an original thereof, have been duly executed by the Principal and Surety above named, on the day of 20 the name and corporate seal of each corporate party being hereto affixed and these presents duly signed by its undersigned representative pursuant to authority of its governing body. (Corporate Seal of Principal, if corporation) (Seal of Surety) Design -Build Entity By: President Surety By: Attorney -in -Fact (Attached Attorney -In -Fact Certificate and Required Acknowledgements) NOTE: A copy of the Power -of -Attorney to local representatives of the bonding company must be attached hereto. A5-102 Notary Acknowledgment A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. STATE OF CALIFORNIA COUNTY OF On , 20, before me, , Notary Public, personally appeared , who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. Signature of Notary Public WITNESS my hand and official seal. OPTIONAL Though the information below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent removal and reattachment of this form to another document. CAPACITY CLAIMED BY SIGNER DESCRIPTION OF ATTACHED DOCUMENT ❑ Individual ❑ Corporate Officer Partner(s) Title(s) ❑ Limited ❑ General ❑ Attorney -In -Fact ❑ Trustee(s) ❑ Guardian/Conservator ❑ Other: Signer is representing: Name Of Person(s) Or Entity(ies) A5-103 Title or Type of Document Number of Pages Date of Document Signer(s) Other Than Named Above ATTACHMENT 6 HOURLY RATE SCHEDULE FOR EXTRA WORK A6-104 ATTACHMENT 7 WORKERS' COMPENSATION CERTIFICATION Labor Code section 3700 in relevant part provides: Every employer except the State shall secure the payment of compensation in one or more of the following ways: a. By being insured against liability to pay compensation by one or more insurers duly authorized to write compensation insurance in this state. b. By securing from the Director of Industrial Relations a certificate of consent to self -insure, which may be given upon furnishing proof satisfactory to the Director of Industrial Relations of ability to self -insure and to pay any compensation that may become due to his employees. I am aware of the provisions of section 3700 of the Labor Code which require every employer to be insured against liability for workers' compensation or to undertake self-insurance in accordance with the provisions of that code, and I will comply with such provisions before commencing the performance of the Work of this Contract. Date: Name of Design -Build Entity: Signature: Print Name: Title: (In accordance with Article 5 - commencing at section 1860, chapter 1, part 7, division 2 of the Labor Code, the above certificate must be signed and filed with the awarding body prior to performing any Work under this Contract.) A7-105