Loading...
HomeMy WebLinkAboutC22750 C-18, Inc. - Citywide Striping 564-04CITY OF PALM DESERT PUBLIC WORKS DEPARTMENT STAFF REPORT REQUEST: Authorize Award of C22750 for the Citywide Striping to C-18, Inc., in the amount $89,331.00 (Project No. 564-04) SUBMITTED BY: Mark Greenwood, P.E. APPLICANT: C-18, Inc. P.O. Box 3360 Beaumont, Califomia 92223 DATE: June 10, 2004 CONTENTS: Contract Vicinity Map Recommendation: By Minute Motion: 1. Authorize Award of Contract No. C22750 for Citywide Striping Program to C-18, Inc., of Beaumont, California, in the amount of $ 89,331.00. 2. Set aside a 10% contingency. Discussion: Citywide Striping is an annual program conducted within the City of Palm Desert. Staff advertised and called for bids for this program. On June 2, 2004, at 10:00 A.M. bids were opened and read aloud. The results are as follows; C-18 Sudhakar Company International $ 89,331.00 $109,511.00 Funds are available for this project in Account No. 110-4315-433-3320. Staff Report Award Contract C22750 for the Citywide Striping Program (Project 564-04) Page2of2 June 10, 2004 Therefore, staff recommends that City Council by minute motion authorize the award of Contract No. C22750 for the Citywide Striping Program to C-18, Inc., of Beaumont, California, in the amount of $89,331.00 and set aside a 10% contingency. Submitted By: Mark Gree ood, P. City Engineer Approval: CM for Deent Services City Manager Icls Department Head: Michael Errante, P.E. Director of Public Works Finance Director G:\PubWorks\Staff Reports120041June 101STAFF REPORT -Award to C-18.dot CONTRACT NO.C22750 AGREEMENT THIS AGREEMENT is made and entered into this 10 day of June 2004, by and between the City of Palm Desert, California, hereafter called "OWNER", and C-18, Inc., hereinafter called "Contractor". RECITALS: WITNESSETH 1. Contractor has submitted to OWNER its Contractor's Proposal for the construction of OWNER'S Project Citywide Striping Program, PROJECT NO. 564-04, in strict accordance with the Contract Documents identified below and OWNER has accepted said Proposal. 2. Contractor states that it has re-examined its Contractor's Proposal and found it to be correct, has ascertained that its subcontractors are properly licensed and possess the requisite skill and forces, has examined the site and Contract in accordance with the Contract Documents for the money set forth in its Proposal to be paid as provided in the Contract Documents. AGREEMENT: IT IS AGREED BY THE PARTIES AS FOLLOWS: 1. Contract Documents: The entire contract consists of the following: (a) The Agreement; (b) The Notice Inviting Bids; (c) The Instruction to Bidders; (d) The Contractor's Proposal; (e) The Bidder's Bond; (f) The Performance Bond; (g) The Payment Bond; (h) The General Conditions; (i) The Special Provisions; j) The Standard Specifications as modified in other portions of the Contract Documents; (k) The Plans; (I) Addenda Nos.1; (m) The Determination of Prevailing Wage Rates for Public Work; (n) Any Change Orders issued; (o) Any additional or supplemental specifications, notices, instructions and drawings issued in accordance with the provisions of the Contract Documents. All of said Documents presently in existence are by this reference incorporated herein as if here set forth in full and upon the proper issuance of their documents they shall likewise be deemed incorporated. 2. Contractor shall commence the work within ten calendar days after the date of the Notice to Proceed and will do all things necessary to construct the work generally described in Recital No. I in accordance with the Contract Documents and will complete said work within 90 (Ninety) calendar days from the Notice to Proceed date to the satisfaction of the City Engineer. G:\PubWorks\PROJECTS1564-041ContracttCONTRACT AGREEMENT.doc CONTRACT NO.C22750 3. That the Contractor agrees to indemnify, defend, and hold harmless the OWNER, its officers, agents and employees, and the Engineer, from any and all claims and losses accruing or resulting to any and all contractors, subcontractors, materialmen, laborers, and any other person, firm or corporation furnishing or supplying work, services, materials or supplies in connection with the performance of this Agreement. 4. Attention is directed to Section 6-9, "Liquidated Damages" of the Standard Specifications and is hereby amended to the substitute the City of Palm Desert in place of the State of Califomia. Liquidated damages shall be $100.00 per calendar day of delay. 5. Should any litigation or arbitration be commenced between the parties concerning the works of improvements as referenced herein, the prevailing party in any such litigation, being the OWNER or the Contractor, should be entitled to a reasonable sum for attorney's fees incurred in any such litigation relating to this Contract. 6. This Agreement shall be binding upon all parties hereto and their respective heirs, executors, administrators, successors, and assigns. 7. Contractor shall be paid in the manner set forth in the Contract Documents the amount of its Proposal as accepted by OWNER, subject to such additions and deductions as may be made pursuant to the Contact Documents and applicable law. 8. Execution of the Agreement by the parties constitutes their agreement to abide by all applicable provisions of the California Labor Code; constitutes CONTRACTOR'S certification that he is aware of the provisions of said Code and will comply with them; and further constitutes CONTRACTOR'S certification as follows: "I am aware of the provisions of Section 3700 of the Califomia Labor Code which requires every employer to be insured against liability for worker's compensation or to undertake self insurance in accordance with the provisions of that Code, and I will comply with such provisions before commencing the performance of the work of this contract. " G:1PubWorks\PROJECTS1564-041Contract\CONTRACT AGREEMENT.doc CONTRACT NO.C22750 IN WITNESS WHEREOF the parties hereto have executed or caused to be executed by their duly authorized officials, this Agreement which shall be deemed an original on the date first above written. CONTRACTOR: C-18, Inc. By: Attest By: Signature to be notarized Title: Title: OWNER: CITY OF PALM DESERT By: Title: Mayor of Palm Desert, California APPROVED AS TO CONTENT: Homer Croy ACM for Development Services Attest By: Title: City Clerk of Palm Desert David J. Erwin City Attorney G:1PubWorks\PROJECTS1564-041Contract\CONTRACT AGREEMENT.doc CONTRACT NO.C22750 PERFORMANCE BOND KNOW ALL MEN BY THESE PRESENTS: That whereas the City of Palm Desert has awarded to C-18, Inc. hereinafter designated as the "Principal", a contract for: PROJECT NO. 564-04 Citywide Striping Program WHEREAS, said Principal is required under the terms of said contract to furnish a good and sufficient bond for the performance of said contract: NOW THEREFORE, WE, C-18, Inc. the Principal, and as Surety, are held and firmly bound unto the City of Palm Desert hereinafter called the OWNER, in the penal sum of Eighty -Nine Thousand and Three Hundred Thirty -One dollars and no/100 Dollars ($89,331.00), being 100% of the contract amount in lawful money of the United States of America for the payment of which sum well and truly to be made, we hereby bind ourselves, our heirs, executors, administrators, and successors, jointly and severally, firmly by these presents. THE CONDITION OF THIS OBLIGATION IS SUCH that if the above bounded Principal, his executors, heirs, administrators, and successors, or assigns, shall in all things stand to and abide by, and well and truly keep and perform the covenants and agreements in the said contract and any alterations thereof made as therein provided, on his or their part, to be kept and performed at the time and in the manner therein specified, and in all respects according to their true intent and meaning, and shall indemnify and save harmless the OWNER, its officers and agents, as therein stipulated, then this obligation shall become null and void; otherwise, it shall be and remain in full force and virtue. And the said Surety, for value received, hereby stipulates and agrees that no change, extension of time, alteration or addition to terms of the contract or to the work to be performed thereunder or the specifications accompanying the same shall in any wise affect its obligations on this bond, and it does hereby waive notice of any such change, extension of time, alterations or additions to the terms of the contract or to the work or the specifications. Should it become necessary for the OWNER to institute a lawsuit or any other legal proceeding to enforce the terms and conditions of this bond, then all costs of said proceeding, including attorneys' fees, shall be awarded to the prevailing party. G:1PubWorks\PROJECTS1564-04\Contract\CONTRACT AGREEMENT.doc CONTRACT NO.C22750 IN WITNESS WHEREOF, identical counterparts of this instrument, each of which shall for all purposes be deemed an original thereof, have been duly executed by the Principal and Surety above named, on this day of 20 SURETY PRINCIPAL BY: BY: INSURANCE COMPANY and/or AGENT: ADDRESS: TELEPHONE NUMBER: G:\PubWorks\PROJECTS1564-041Contract\CONTRACT AGREEMENT.doc CONTRACT NO.C22750 CITY OF PALM DESERT PAYMENT BOND KNOW ALL MEN BY THESE PRESENTS: THAT WHEREAS, the City of Palm Desert (sometimes referred to hereinafter as "Obligee") has awarded to C-18, Inc. (hereinafter designated as the "Contractor"), an agreement dated June 10, 2004 described as follows: Citywide Striping Program, Project No. 564-04 (hereinafter referred to as the "Contract"); and WHEREAS, said Contractor is required to furnish a bond in connection with said Contract, and pursuant to Section 3247 of the California Civil Code; NOW, THEREFORE, we, C-18, Inc. the undersigned Contractor, as Principal, and a corporation organized and existing under the laws of the State of and duly authorized to transact business under the laws of the State of California, as Surety, are held and firmly bound unto the City of Palm Desert and to any and all persons, companies or corporations entitled to file stop notices under Section 3181 of the California Civil Code, in the sum of Eighty - Nine Thousand Three Hundred Thirty -One Dollars and no/00 Dollars ($89,331.00), said sum being not less than one hundred percent (100%) of the total amount payable by the said Obligee under the terms of the said Contract, for which payment well and truly to be made, we bind ourselves, our heirs, executors and administrators, successors and assigns, jointly and severally, firmly by these presents. THE CONDITION OF THIS OBLIGATION IS SUCH, that, if said Contractor, his or its heirs, executors, administrators, successors or assigns, or Subcontractors, shall fail to pay for any materials, provisions or other supplies, implements, machinery or power used in, upon, for or about the performance of the Public Work contracted to be done, or to pay any person for any work or labor of any kind, or for bestowing skills or other necessary services thereon, or for amounts due under the Unemployment Insurance Code with respect to such work or labor, or for any amounts required to be deducted, withheld, and paid over to the Employment Development Department from the wages of employees of said Contractor and his or its Subcontractors pursuant to Section 13020 of the Unemployment Insurance Code with respect to such work and labor as required by the provisions of Section 3247 through 3252 of the Civil Code, or for any amounts required to be deducted, withheld, and paid over to the Franchise Tax Board or Internal Revenue Service from the wages of employees of the Contractor or his or its Subcontractors, the Surety or Sureties hereon will pay for the same in an amount not exceeding the sum specified in this bond, otherwise the above obligation shall be void. In addition to the provisions hereinabove, it is agreed that this bond will inure to the benefit of any and all persons, companies and corporations entitled to serve stop notices under Section 3181 of the Civil Code, so as to give a right of action to them or their assigns in any suit brought upon this bond. G:1PubWorks\PROJECTS1564-041Contract\CONTRACT AGREEMENT.doc CONTRACT NO.C22750 The Surety, for value received, hereby stipulates and agrees that no change, extension of time, alteration or addition to the terms of the said Contract or to the work to be performed thereunder or the Specifications accompanying the same shall in any way affect its obligations on this bond, and it does hereby waive notice of any such change, extension of time, alteration or addition to the terms of the Contract or to the Specifications. No final settlement between the Obligee and the Contractor hereunder shall abridge the right of any beneficiary hereunder, whose claim may be unsatisfied. Contractor and Surety agree that if the Obligee is required to engage the services of an attorney in connection with the enforcement of the bond, each shall pay Obligee's reasonable attorney's fees incurred, with or without suit, in addition to the above sum. IN WITNESS WHEREOF, we have hereunto set our hands and seals this day of , 20 PRINCIPAL/CONTRACTOR: SURETY: (Typed Name of Contractor) (Typed Name of Surety) By: By: (Signature) (Signature of Attorney -in -Fact) (Typed Name and Title) (Typed Name of Attorney -in -Fact) The rate of premium on this bond is per thousand. The total amount of premium charged: $ (the above must be filled in by corporate surety). IMPORTANT: Surety companies executing bonds must possess a certificate of authority from the California Insurance Commissioner authorizing them to write surety insurance defined in Section 105 of the California Insurance Code, and if the work or project is financed, in whole or in part, with federal, grant or loan funds, it must also appear on the Treasury Department's most current list (Circular 570 as amended). THIS IS A REQUIRED FORM. G:\PubWorks\PROJECTS\564-04\Contract\CONTRACT AGREEMENT.doc CONTRACT NO.C22750 Any claims under this bond may be addressed to: (Name, Address and Telephone No. of Surety) (Name, Address and Telephone No. of agent or representative for service of process in California if different from above) G:1PubWorks\PROJECTS1564-041Contract\CONTRACT AGREEMENT.doc er) 6 0 OffA ir ctfoo G�� Q, TAMARISK ROW DRIVE - 0 '