HomeMy WebLinkAboutC29610 - 2010 Citywide Slurry Seal CONTRACT NO. C29610
CITY OF PALM DESERT
PUBLIC WORKS DEPARTMENT
STAFF REPORT
REQUEST: AWARD CONTRACT NO. C29610 FOR CONSTRUCTION OF
THE 2010 CITYWIDE SLURRY SEAL PROJECT TO ROY ALLAN
SLURRY SEAL, INC., OF SANTA FE SPRINGS, CALIFORNIA, IN
THE AMOUNT OF $130,357 (PROJECT NO. 751-10)
SUBMITTED BY: Mark Greenwood, P.E., Director of Public Works
CONTRACTOR: Roy Allan Slurry Seal, Inc.
11922 Bloomfield Avenue
Santa Fe Springs, CA 90670
DATE: March 25, 2010
CONTENTS: Agreement
Contractor's Proposal
List of Locations
Location Map
Recommendation
By Minute Motion:
1. Waive irregularities in the contract documents;
2. Accept Tire Rubber Modified Slurry Seal (TRMSS) as an equal to
Rubberized Emulsion Aggregate Slurry (REAS);
3. Award Contract No. C29610 for construction of the 2010 Citywide
Slurry Seal Project to Roy Allan Slurry Seal, Inc., of Santa Fe
Springs, California, in the amount of $130,357 (Project No. 751=10);
and
4. Authorize the Mayor to execute the Agreement.
Funding is available for this project in General Fund Account No. 110-4311-433-3320,
Street Maintenance.
Staff Report
Award Contract C29610 to Roy Allan Slurry Seal, Inc. (Project 751-10)
March 25, 2010
Page 2 of 3
Backqround
The 2010 Citywide Slurry Seal Program will use rubberized slurry seal to coat various
streets within Palm Desert. The rubberized slurry has an elastic quality that prolongs
street life longer than conventional slurry. The neighborhoods to be slurried this year
were selected based upon their need and the pavement condition index ranking. The
area to be slurried is in the southeast section of Palm Desert, south of Highway 111 and
east of Portola Avenue (see the location map).
The projec# was advertised and contractors were encouraged to submit bids. At the
March 9, 2010, bid opening, three contractors submitted bids. The breakdown is below:
Contractor Location Bid Amount
Roy Allan Slurry Seal, Inc. Santa Fe Springs, CA $130,357
Valley Slurry Seal West Sacramento, CA $139,682
Pavement Coatings Co. Mira Loma, CA $140,745
Roy Allan Slurry Seal, Inc., submitted the lowest responsive bid in the amount of
$130,357. The bid was approximately 26 percent lower than the engineer's estimate.
Roy Allan Slurry Seal, Inc., submitted a substitution of the slurry seal material specified
for the project. The specification identifies REAS as the material to be used, and Roy
Allan Slurry Seal, Inc., has submitted their bid based on using TRMSS. Staff has
reviewed both products and, while there are differences, the products perform the same
function. In 2008 the City applied TRMSS to Summit View Drive as a test area to
observe how the material wears. At the same time, the City awarded a contract to apply
REAS to streets in the same area. The streets were compared after about one and
one-half years, and both slurry seals appear to have perFormed equally. Therefore, staff
recommends that Council accept TRMSS as an equal to REAS.
The bid submitted by Roy Allan Slurry Seal, Inc., contains an irregularity in the
Contractor's Proposal form. On page C-2, the total bid price is written in figures. On
page C-3, the bidder did not write out the total bid in figures and in words in the blanks
provided on the form. The City Attorney has advised staff that this oversight is
something that Council can waive as an irregularity. Therefore, staff recommends that
Council waive the irregularity and award Contract No. C29610 for construction of the
2010 Citywide Slurry Seal Project to Roy Allan Slurry Seal, Inc., of Santa Fe Springs,
California, in the amount of$130,357 (Project No. 751-10).
G:IPubWorkslStaff Reports120101Maich 25L4ward C296f 0 2010 Citywide Slurry Seal to Roy Allay Sluny Sea/1SR Award Contract C29610 to Roy Allan Slurry Seal.doc
Staff Report
Award Contract C29610 to Roy Allan Slurry Seal, Inc. (Project 751-10)
March 25, 2010
Page 3 of 3
Fiscal Analvsis
This is an on-going maintenance activity with no fiscal impact beyond the contract
amount.
Prepared By: Departme t e :
� � y'
Ry Gayl r roject A inistrator Mark Green ood, P.E.
Director of Public Works
Paul S. Gibson, Director of Finance .
CITY COUNCIL�'I'ION
APPROVED DFNiED
Approval: RECEIVED OTHER
MEETI G DA -
AYES. ') �r�
Jo n M. Wohlmuth, City Manager NOES:
ABSENT:
ABSTAtN:
VCRIFIED BY:
Original on File with City rk's Office
AGREEMENT
THIS AGREEMENT is made and entered into this 25th day of March, 2010, by
and between City of Palm Desert, California, hereafter called "CITY" and Rov Allan
Slurry Seal. Inc. hereinafter called "CONTRACTOR".
WITNESSETH
RECITALS:
CONTRACTOR has submitted to CITY its Contractor's Proposal for the construction of
CITY Project,
1. 2010 CITYWIDE SLURRY SEAL PROJECT, PROJECT NO. 751-10,
CONTRACT NO. C29610, in strict accordance with the Contract Documents
identified below, CITY has accepted said Proposal.
2. CONTRACTOR states that it has re-examined its CONTRACTOR'S Proposal
and found it to be correct, has ascertained that its Subcontractors are properly
licensed and possess the requisite skill and forces, has examined the site and
Contract in accordance with the Contract Documents for the money set forth in
its Proposal to be paid as provided in the Contract Documents.
AGREEMENT:
IT IS AGREED BY THE PARTIES AS FOLLOWS:
1. Contract Documents: The entire contract consists of the following: (a) The
Agreement; (b) The Notice Inviting Bids; (c) The Instruction to Bidders; (d) The
Contractor's Proposal; (e) The Bidder's Bond; (f) The Performance Bond; (g)
The Payment Bond; (h) The General Specifications; (i) The Special Provisions;
(j) The Standard Specifications as modified in other portions of the Contract
Documents; (k) The Plans; (I) Addenda Nos. N/A; (m) The Determination of
Prevailing Wage Rates for Public Work; (n) Any Change Orders issued; (o) Any
additional or supplemental specifications, notices, instructions and drawings
issued in accordance with the provisions of the Contract Documents. All of said
Documents presently in existence are by this reference incorporated herein as if
here set forth in full and upon the proper issuance of their documents they shall
likewise be deemed incorporated.
2. Contractor shall commence the work within ten calendar days after the date of
the Notice to Proceed and will do all things necessary to construct the work
generally described in Recital No. 1 in accordance with the Contract Documents
and will complete said work within 30Calendar Days from the Notice to Proceed
date to the satisfaction of the Engineer.
3. Contractor agrees to indemnify, defend and save CITY and its officers, agents
and employees, and the Engineer harmless from:
a. Any and all liability, claims, damages, losses or injuries to any person or
other entity, including injury to Contractor's employees, and all claims
which arise from or are connected with the negligent performance of or
failure to perform the work or other obligations of this Agreement, or which
are caused or which are claimed to be caused by the negligent or
intentional acts or omissions of Contractor, its subcontractors, its agents
or employees, and, all expenses of investigating and defending against
same,
b. Any and all liability, claims, damages, losses or injuries to any and all
contractors, subcontractors, material-men, laborers, or any other person,
firm or corporation furnishing or supplying work, services, materials or
supplies in connection with the performance of the Agreement.
c. Attention is directed to the General Specifications - Claims, Liability, and
Indemnity Agreement/Hold Harmless sections, which specifications are
made part of this Agreement as set forth in Agreement paragraph 1,
above.
d. Attention is directed to Section 6-9, "Liquidated Damages" of the Standard
Specifications and is hereby amended to substitute the "City of Palm
Desert" in place of "Agency." Liquidated damages shall be $1,000.00
dollars per calendar day of delay.
4. Should any litigation or arbitration be commenced between the parties
concerning the works of improvements as referenced herein, the prevailing party
in any such litigation, being the CITY or the Contractor, should be entitled to a
reasonable sum for attorney's fees incurred in any such litigation relating to this
Contract.
5. This Agreement shall be binding upon all parties hereto and their respective
heirs, executors, administrators, successors, and assigns.
6. Contractor shall be paid in the manner set forth in the Contract Documents the
amount of its Proposal as accepted by CITY, subject to such additions and
deductions as may be made pursuant to the Contact Documents and applicable
law.
Satisfactory Performance: The prime Contractor agrees to pay each
Subcontractor under this prime contract for satisfactory performance of its
contract no later than 10 days from the receipt of each payment the prime
Contractor receives from City of Palm Desert. Any delay or postponement of
payment from the above referenced time frame may occur only for good cause
following written approval of the City of Palm Desert.
Release of Retention: The prime Contractor agrees further to release retention
payments to each Subcontractor within 30 days after the Subcontractor's work is
satisfactorily completed. Any delay or postponement of payment from the above
referenced time frame may occur only for good cause following written approval
of the City of Palm Desert.
7. Execution of the Agreement by the parties constitutes their agreement to abide
by all applicable provisions of the California Labor Code; constitutes contractor's
certification that he is aware of the provisions of said Code and will comply with
them; and further constitutes Contractor's certification as follows:
"I am aware of the provisions of Section 3700 of the California Labor Code which
requires every employer to be insured against liability for worker's compensation
or to undertake self insurance in accordance with the provisions of that Code,
and I will comply with such provisions before commencing the performance of the
work of this contract."
IN WITNESS WHEREOF the parties hereto have executed or caused to be
executed by their duly authorized officials, this Agreement which shall be deemed an
original on the date first above written.
(Remainder of this page has intentionally been /eft b/ank.
Signature blocks are contained on the next page]
CONTRACTOR:
BY� ATTEST BY:
Signature to be notarized
TITLE: TITLE:
CITY:
BY� ATTEST BY:
Signature to be notarized
TITLE: Mavor of Palm Desert CA TITLE: Citv Clerk of Palm Desert CA
APPROVED AS TO CONTENT: APPROVED AS TO FORM:
MARK GREENWOOD, P.E. DAVID J. ERWIN
DIRECTOR OF PUBLIC WORKS CITY ATTORNEY
State of California )
)
County of )
On before me,
personally appeared
, who proved to me on the basis of
satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within
instrument and acknowledged to me that he/she/they executed the same in his/her/their
authorized capacity(ies), and that by his/her/their signature(s) on the instrument the
person(s), or the entity upon behalf of which the person(s) acted, executed the
instrument.
I certify under PENALTY OF PERJURY under the laws of the State of California that the
foregoing paragraph is true and correct.
WITNESS my hand and official seal.
Signature (Seal)
PERFORMANCE BOND
KNOW ALL MEN BY THESE PRESENTS: That whereas the City of Palm Desert has
awarded to Rov Allan Slurry Seal Inc
hereinafter designated as the "Principal", a contract for:
2010 CITYWIDE SLURRY SEAL PROJECT
PROJECT NO. 751-10
CONTRACT NO. C29610
WHEREAS, said Principal is required under the terms of said contract to furnish
a good and sufficient bond for the performance of said contract:
NOW THEREFORE, WE, Rov Allan Slurry Seal Inc
the Principat, and as Surety, are held and
firmly bound unto the City of Palm Desert hereinafter called the City, in the penal sum of
One-hundred Thirtv Thousand Three-hundred Fiftv-seven and no cents Dollars
($130,357.00), being 100% of the contract amount in lawful money of the United States
of America for the payment of which sum well and truly to be made, we hereby bind
ourselves, our heirs, executors, administrators, and successors, jointly and severally,
firmly by these presents.
THE CONDITION OF THIS OBLIGATION IS SUCH that if the above bounded
Principal, his executors, heirs, administrators, and successors, or assigns, shall in all
things stand to and abide by, and well and truly keep and perform the covenants and
agreements in the said contract and any alterations thereof made as therein provided,
on his or their part, to be kept and performed at the time and in the manner therein
specified, and in all respects according to their true intent and meaning, and shall �
indemnify and save harmless the City, its officers and agents, as therein stipulated, then
this obligation shall become null and void; otherwise, it shall be and remain in full force
and virtue.
And the said Surety, for value received, hereby stipulates and agrees that no
change, extension of time, alteration or addition to terms of the contract or to the work to
be performed thereunder or the specifications accompanying the same shall in any wise
affect its obligations on this bond, and it does hereby waive notice of any such change,
extension of time, alterations or additions to the terms of the contract or to the work or
the specifications.
Should it become necessary for the City to institute a lawsuit or any other legal
proceeding to enforce the terms and conditions of this bond, then all costs of said
proceeding, including attorneys' fees, shall be awarded to the prevailing party.
IN WITNESS WHEREOF, identical counterparts of this instrument, each of which
shall for all purposes be deemed an original thereof, have been duly executed by the
Principal and Surety above named, on this day of , 20 .
SURETY PRINCIPAL
BY: BY:
INSURANCE COMPANY and/or AGENT
ADDRESS
TELEPHONE NUMBER
State of Cafifornia )
)
County of )
On before me,
,
personally appeared
, who proved to me on the basis of
satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within
instrument and acknowledged to me that he/she/they executed the same in his/her/their
authorized capacity(ies), and that by his/her/their signature(s) on the instrument the
person(s), or the entity upon behalf of which the person(s) acted, executed the
instrument.
I certify under PENALTY OF PERJURY under the laws of the State of California that the
foregoing paragraph is true and correct.
WITNESS my hand and official seal.
Signature (Seal)
PAYMENT BOND
KNOW ALL MEN BY THESE PRESENTS:
THAT WHEREAS, the City of Palm Desert (sometimes referred to hereinafter as
"Obligee") has awarded to Rov Allan Slurry Seal Inc. (hereinafter designated as the
"CONTRACTOR"), an agreement dated March 25. 2010 described as follows: 2010
CITYWIDE SLURRY SEAL PROJECT, PROJECT NO. 751-10, CONTRACT NO.
C29610, (hereinafter referred to as the "Contract"); and
WHEREAS, said CONTRACTOR is required to furnish a bond in connection with said
Contract, and pursuant to Section 3247 of the California Civil Code;
NOW, THEREFORE, we, Rov Allan Slurry Seal Inc. , the undersigned
CONTRACTOR, as Principal, and a corporation
organized and existing under the laws of the State of , and
duly authorized to transact business under the laws of the State of California, as Surety,
are held and firmly bound unto the City of Palm Desert and to any and all persons,
companies or corporations entitled to file stop notices under Section 3181 of the
California Civil Code, in the sum of One-hundred Thirtv Thousand Three-hundred FiftLr-
seven and no cents Dollars ($130,357.00), said sum being not less than one hundred
percent (100%) of the total amount payable by the said Obligee under the terms of the
said Contract, for which payment well and truly to be made, we bind ourselves, our
heirs, executors and administrators, successors and assigns, jointly and severally, firmly
by these presents.
THE CONDITION OF THIS OBLIGATION IS SUCH, that, if said CONTRACTOR, his or
its heirs, executors, administrators, successors or assigns, or Subcontractors, shall fail
to pay for any materials, provisions or other supplies, implements, machinery or power
used in, upon, for or about the performance of the Public Work contracted to be done,
or to pay any person for any work or labor of any kind, or for bestowing skills or other
necessary services thereon, or for amounts due under the Unemployment Insurance
Code with respect to such work or labor, or for any amounts required to be deducted,
withheld, and paid over to the Employment Development Department from the wages of
employees of said CONTRACTOR and his or its Subcontractors pursuant to Section
13020 of the Unemployment Insurance Code with respect to such work and labor as
required by the provisions of Section 3247 through 3252 of the Civil Code, or for any
amounts required to be deducted, withheld, and paid over to the Franchise Tax Board
or Internal Revenue Service from the wages of employees of the CONTRACTOR or his
or its Subcontractors, the Surety or Sureties hereon will pay for the same in an amount
not exceeding the sum specified in this bond, otherwise the above obligation shall be
void. In addition to the provisions herein above, it is agreed that this bond will inure to
the benefit of any and all persons, companies and corporations entitled to serve stop
notices under Section 3181 of the Civil Code, so as to give a right of action to them or
their assigns in any suit brought upon this bond.
The Surety, for value received, hereby stipulates and agrees that no change, extension
of time, alteration or addition to the terms of the said Contract or to the work to be
performed thereunder or the Specifications accompanying the same shall in any way
affect its obligations on this bond, and it does hereby waive notice of any such change,
extension of time, alteration or addition to the terms of the Contract or to the
Specifications.
No final settlement between the Obligee and the CONTRACTOR hereunder shall
abridge the right of any beneficiary hereunder, whose claim may be unsatisfied.
CONTRACTOR and Surety agree that if the Obligee is required to engage the services
of an attorney in connection with the enforcement of the bond, each shall pay Obligee's
reasonable attorney's fees incurred, with or without suit, in addition to the above sum.
IN WITNESS WHEREOF, we have hereunto set our hands and seals this
day of , 20
PRINCIPAL/CONTRACTOR: SURETY:
(Typed Name of CONTRACTOR) (Typed Name of Surety)
By: gy.
(Signature) (Signature of Attorney-in-Fact)
(Typed Name and Title) (Typed Name of Attorney-in-Fact)
The rate of premium on this bond is $ per thousand.
The total amount of premium charged: $
(the above must be filled in by corporate surety).
IMPORTANT: Surety companies executing bonds must possess a certificate of
authority from the California lnsurance Commissioner authorizing them to write surety
insurance defined in Section 105 of the California lnsurance Code, and if the work or
project is financed, in whole or in part, with federal, grant or loan funds, it must also
appear on the Treasury Department's most current list (Circular 570 as amended).
THIS IS A REQUIRED FORM.
Any claims under this bond may be addressed to:
(Name, Address and Telephone No. of Surety)
(Name, Address and Telephone No. of agent or representative for service of process in
California if different from above)
��:� ..
��
C - CONTRACTOR'S PROPOSAL
�� �
2010 CITYWIpE SLURRY SEAL PROJECT
PROJECT NO. 751-10
� CONTRACT NO. C29610
TO: CITY OF PALM DESERT, "CITY"
�� DATE: '��7_ I�
(.
��:; BIDDER: �j t� 11 �
��:� � �`r�" � � � "CONTRACTOR°
The UNDERSIGNED, "CONTRACTOR", having carefully examined the '
Q Contract Documents for the construction of, 2010 CITYW�pE SL�site and the
PROJECT, PROJECT NO. 751-10, CONTRACT NO. C29610 RRY SEAL
construct the work in accordance with the Contract Documents,h ncludin Add
y propases to
�� No(s), g enda
stated in this Pro'osal. for the amount
,� By submitting this Proposal, CONTRACTOR agrees with CITY:
�m �• That unless withdrawn in person by CONTRACTOR or so
� in writing by CONTRACTOR — not by telephone or telegram pebefore the tZed
specified in the Notice Inviting Bids for the pubiic opening of bids, this Pro o al
constitutes an irrevocabte offer fo r 6 0 c a l e n d a r d a y s a fter t ha t date. p
� 2• The CITY has the right to reject an or ail
irregularities or informalities contained in a Proposalroposals and to waive any
� 3• That the contract shall be awarded only b the
contract shall only be deemed awarded after the CONTRACTOR'SI com etd
� submission of all contract documents, bonds, insurance documentation, and the
CITY shall obtain all necessary signatures of the governing body, at which time
the contract shall be deemed awarded.
� 4• To submit to CITY such information as CITY
Bidder's financial standing experience and to pertorm the Work to determine the
� 5• That the accompanying certified or cashier's check
' or Bid Bond constitutes a
guarantee that if awarded the contract, CONTRACTOR will execute the
� Agreement and deliver the required bonds and certificates of insurance within 1
days after notice of award. )f CONTRACTOR fails to execute and deliver said
documents, the check or bond is to be charged with the costs of the resultant
� damages to CITY, including but not limited to publication costs, the difference i
J money befinreen the amount bid and the amount in excess of the bid which c n
CITY to do or cause to be done the work involved, lease and rental c sts
additional salaries and overhead, increased interest and costs of fundin the
project, attorney expense, additional engineering and architectural expense and
Page C-1
f , . ,
__.__
�i�
cost of maintaining or construction alternate facilities occasioned by the failure to
execute and deliver said documents.
��
�� It is understood that the quantities shown hereon, exce t for
"Lump Sum", are estimates and the final payment will be based�up nuthe'actuala ork
�-: pertormed, subject to such adjustment and alterations as elsewhere provided herein.
��
,..
i'�
���
'���M T
'� � ` -�. '.�f
i Y. '' , �c��� �`���.��,�.j� x,�'` :.�,.�r: ''�� � �. :;t��.�'��~ �"�°'� Y�� i � � �
,.�,
,;� � �Mobilization �S � � - = ,��° -� - - �
2 . �J ZC�C��(�(� �� ' ..C7�
�. Traffic Control �S � $ $ �
3 I �j 2.�`y.C� � �Z(1
REAS Slurry Seal (or approved equal) SF 669,000 �
� •►�?� l� ?�3?•
� 4 Signing and Striping LS 1
TOTAL BID PRICE
� �75�°� �7Sc�.vv
� $ 13C� ��?� C�
:�
�
�
�
�
�
�
�
�
ri
:�
:�
j Page C-2
�
i,� � , � �� ..
t".
�.�
The costs of any work shown or required in the Plans and Specifications, but not
specifically identified as a Pay Item are included in the related Pay Item(s), and no
�� additional compensation shall be due CONTRACTOR by virtue of C
compliance with the Plans and Specifications. ONTRACTOR'S
�
� TOTAL AMOUNT BASE BID IN FIGURES $
�;
TOTAL AMOUNT BASE BID IN WORDS
�..�
i6� IN WITNESS WHEREOF CONTRACTOR executed this proposal as of date set fo
Page C-1: rth on
� BY' � �__._____.—
Signature
� Title: ��� �`�i`�.���Q,. "�
CONTRACTOR
Y� State of California �
County of �
..,, )
� Subscribed and sworn to (or affirmed) before me on this
month , day of
� ) (year), by
� , proved to me on tt�e basis of satisfactory evidence to be the person(s
who appeared before me. )
�
� Signature of Notary
(Seal of Notary)
� ��e a-�ac��
��;��
�
�
.,
�
�
�
�
:�
�
.
:� Page G3
f
State of California
County of Oranqe
Subscribed and sworn to (or affirmed) before me on this -l� day
of MUrc,h , 20 t O , by ��r�,,�� ��
proved to me on the basis of satisfactory evidence to be the person(s) who
appeared before me.
ANN-MARIE ALLAN
N CoMM.# 1155275 r^
NOTARY PUBLIGCAUFORNU y'
� , ORANGE COUNIY
MY COMM.EXP.JULY 3�2��) L
•.T.'�'` Signature �
(Seal) �� C��.1�
:� � ' _ . _ .
�
D — INFORMATION REQUIRED OF BIDDER
�� The bidder is required to supply the following information. Additional sheets may be
attached if necessary.
:� (1) Address �q2Z �t � rv� ' � � � � r
�,. ;� t� �. �(�,?(�
(2) Telephqne No. � '�1 �(�Ci-���`�
�� 3 T e of F'
O yp irm (Individual, Partnership or Corporation) C-C,tir�p�,.�•�`7j �
;� (4) Corporation organized under the laws of the State of _ �`�Y��
(5) Contractor's License No._�7 Z��� Exp. Date __ L�'�3--� �
� Contractor hereby swears under penalty of perjury that this information provided is true
and correct.
` '�� t -
� By� w.�l��,,.-��— Title:_ v t C.�- S�tJ�.t,ti-�---
Signature Contractor
`� (6) List the names and addresses of all owners of the firm or names and titles of all
officers of the corporation:
��.,► 1�\\c�.�. — � �z�1�,.�„ �-
� (�
�.�� ,.�y"`F��. Y���C:� ^ �Q� 'Y-Y`e� '� •—�--
�
� (7) Number of years' experience as a Contractor in construction work _�
(8) List at least three similar projects completed recently:
,� Contract Amount Class of Work Date Completed Name, Address &
Tele hone No. of Owner
� �� $i�',c�� �G y;�4 G�j� �- oc.e.�,,,., ,-v�.�
S�v..r'zt �► , �U,�� 3�x✓ N• ���h Hw� C�6o) U3S �ol(d
I �-ri�i �.
x� 2 `��219�G�uv �tY�s c;+� drSG�`p,�,,,��.
� � S �u-v.t C�`� a�4s � '�,r,;��►13��t-6��
sa�.,I� 4. .�'f i7)
� 3.�����-��b•3��� �-�-�r�s � �.;�Q�-�t,,,�,,,�,.
� �� u�v s, v;�w�;a�Vsi)')3q H (��
a� Cw
;:�
o':�
� Page D-1
e.::� �
k�
(9) List the names and addresses of each Subcontractor who will perform work in or
� ,� about the work improvement, and indicate what portion of the work will be done
�,� by each Subcontractor:
�: Subcontractor's Name:—��-1-,. �'�r'�
��
License Number: �
�.� � S �� t�
� , Address: .� ��
.
w` ��l � +'`1 —(�� �
,:+F� ,
Telephone: � � ( �
� Work to be perFormed: ` � �
Subcontractor's Name:
;�-:
License Number:
�� Address:
,
� Telephone:
� Work to be performed:
Subcontractor's Name:
� License Number:
Address:
�
� Telephone:
Work to be performed:
�
� (10) List the name of the person who inspected the site of the proposed work for
firm ����, y����, your
� (11) A financial statement or oth .
er information and references sufficiently
comprehensive to permit an appraisal of your current financial condition may be
:� required by the City.
r
�
�
� Page D-2
�
�y,,� ', • .
�a�
E - NON-COLLUSION AFFIDAVIT
���
�..
� To be Executed by Bidder and Submitted with Bid
� STATE OF CALIFORNIA )
'`� ) SS
COUNTY OF �
r� 0.`�C`
``� �f`
`� says that he/she is , being �rst duly sworn, deposes and
party making the foregoing bid; that the bid is not made in the int � � `�''r•the
k�
any undisclosed person, partnership, company, associat onSt organ zat�iona'f or
corporation; that the bid is genuine and not collusive or sham; that the bidder has not
directly or indirectly induced or solicited any other bidder to put in a false or sham bid,
and has not directly or indirectly colluded, conspired, connived, or agreed with any
bidder or anyone else to put in a sham bid, or that anyone shall refrain from biddin •
that the bidder has not in any manner, directly or indirectly, sought by agreeme t,
communication, or conference with anyone to fix the bid price of the bidder or any other
bidder, or to fix any overhead, profit, or cost element of the bid price, or of that of an
_�+ other bidder, or to secure any advantage against the pubic body awarding the contra t
;�-� of anyone interested in the proposed contract; that all statements contained in th
are true; and, further, that the bidder has not, directly or indirectly, submitted his or her
� bid price or any breakdown thereof, or the contents thereof, or divulged information or
data relative thereto, or paid, and will not pay, any fee to any corporation, partnership,
company, association, organization, bid depository, or to any member or agent thereof
� to effectuate a collusive or sham bid.
� By: �_
Signature
Title: �.J� �
� CONTRACTOR 1(��
:'�
State of California
County of
�
Subscribed and sworn to (or a�rmed), before me this day of
(month), 20 (year), by
� basis of satisfactory evidence to be the person who a , proved to me on the
� ppeared before me.
�
�' Signature of Notary:
County and State Notary Public in and for said
� (seal of notary)
� s�� �,-��CG� �d�.ti.,� Page E-1
� �
State of California
County of Oranqe
Subscribed and sworn to (or affrrmed) before me on this �1�
of_ N�Arck1 , 201� , by- Lc��rQ�lc�. �\1u�1 day
proved to me on the basis of satisfactory evidence to be the person(s) who
appeared before me.
., ANN•MARIE q �qL N�
V` NO ARMPUBII'CA52 RNIA V!
�NANGE COUNTY r
Mr Coµy.Ezv.Jutr 3,2011 � -
(Seal) Signature
F- BIDD�R�S BpND
To Accompany PropQ�a�
KN�W ALL MEN BY THESE PRESENTS,
That we, Roy Allan Slurry Seal,Inc.
and ULLICO Casual Com an as prin�ip�l,
firmiy bound un#o the City of Paim besert in the sum Qf$ a5**surety, are o eld and
to be paid to.the said City or its certain attomey, its successcrs and assigns�for which
payment, weH and truly to be mad$, w� bind ourselves,
adrninistrators, successors or as�igns,jointly�nd severalty, firmly by these p esen$,�nd
�'HE COND(TION OF THIS pBLIGATION !S SU�H, that if the�r,erta�riepropnsa�noff theb�d .
above bounden principal to perForm certain work desGrib�d as ft�llowss
The gpnera! items af work to be done hereunder consisf of: mobilizatlan; application of
rubher�Zed s(urry seal; Installatian of striping, p�vement markings,, a�d pavement
markers; and installation af traffic control devices r�quired during construction of the
improvements and al! ap�,urtenant wvrk as required by the plans and specifications,
and dated March 9,zo�o is acc�pted by the City of P�►m Desert,
and if the above bounden principa! Ro�Ai�an s�urry seai [r,c
du{y enter into and execute a contr�ct for such constru�tion, and shaN executehan�d
deliver the Pertormance Bond and Payment Bond and insurance certificates as r�quirsd
by said contract, then this obligation shall become null and void; otherwise it shall be
�nd remain in futl force and effect.
Should i# became nec�ssary for the City to instftute a lawsuit, or any other legal
proceeding ta eninrce the terms and r,onditions oF this bond, then all costs of said
, proceeding, including attomey's fees, shall be awarded ta the prevailing party,
Page F-1
iN WITNESS WHEREOF, We hereunto set our Hands and Seais this 4th da
Of March � 2010 , . ---------- Y
Contractor's Name; koY Allan Slurry Seal, Inc. '
�ontractor's Signature: �_
Title: �\ ��„ .
Addr�ss: �1922 Bloomfieid Ave.,Santa Fe Springs,CA 90670
Telephone: (562)864-3363
$t1t'9�/'s Name' ULLICO Casualty Company '
Surety's Signature: .� - `� '�
✓
c'�.c.-�
TItl9: Attorney in Fact,Matthew J. Coats
f�t�C�fBSS: 2600 West Olive Ave.,Sth Floor,Burbank,CA 91505 --'
Telephone: (g�g)333-5195
Page F-2
ACKNOWLEDGMENT
State of California
County of Oranae �
On Mc�rc.h `1 �2C�t O before me, Ann-Marie Allan Nota Public
(insert name and title of the officer)
personally appeared Lawrence Allan
who proved to me on the basis of satisfactory evidence to be the erson �
is�a�e subscribed to the within instrument and acknowledged to e that �Whose name�
the same in his�#er�qeif authorized capacity(ies), and that by his�t}eif s1gn��Xon the
instrument the person{�}, or the entity upon behalf of which the person� acted, executed the
instrument.
I certify under PENALTY OF PERJURY under the laws of the State of California that the
foregoing paragraph is true and correct.
WITNESS my hand and official seal.
��+ ANN-MARIE AILAN�
�r^ Cor�M.q 1755275 1^
y' NOTARY PUBUGC�UFORNU V'
ORANGE COUNT7 �'
Mr CoMM.ExP.Jui�3,2�011^�
Signature �
� (Seal)
�.������������������������������������������������������������������������������������������������������������������������������������������������������
�
i �
i �
' CALI FO RNIA '
; ;
' ALL-PURPOSE ACKN4WLEDG �
' EMENT '
,
,
; ;
; ;
,
j State of California �
% %
♦ /
� County of Orange i
i
i
i • i
% On March 4, 2010 before me, Adelaide C. Hunter, Notary Public �
j/ (insert name and title of the ot�icer) �
personally appeared Matthew J. COatS �
jwlio proved to me on the basis of satisfactory evidence to be the person(s�whose namef s}is/arc � �
j subscribed to the wirhin instruinent and acknowled ed to me that he /
/ g r�s�tcft}►tq executed tlie j
� same in hisfh�er�thcir authorized capacity{ies�,and that b his /
j instrument the person�,or the entity upon behalf of wh ch the p��er�s�On(s�}ct d,e�e uted the j
♦
jinstrument. /
/ j
j/ �
I certify under P�NALTY OF PERJURY under the laws of the State of California that the j
/
jforegoing paragraph is true and correct. /
j /
%♦ ,
WITNESS �ny hand and oflicial seal. j
j/ j
+.�►�.0rt►rr�..i�:.� ti.,r,.,s��w.�...�..w._, �
� �.-� Aar�ai� s c. r,�_��ri�x� i
� �,r � ': Commis ���n,� 1,�_;�133 � %
j �. �� '� _ � ; tVotary��ut�,�c Ca��tnrnia � �
/ Signature ,,�t•y ar� ��
/
/ 1 Cair;'y /
� N!y Comrn. Exp:res ��;g FJ, 2�1?� %
/ �'i--���"��. /
% %
/ %
'�\\\\�\\\\�\�\��\�\\�\���\�\�\\����\���\��\�\\\\\\�\�\\�\\�\\\\\\�\����\\\\���\\��\�\\�����\�\\��\\\�\\�\\\�����\\\�\�\�����\�\��\\�\\\\\\\��\\\�\\�\\\�
/
�i�}�("� ULL(CO Casualty Company
I 1 1�,) 1625 Eye Street,N.W.Washington D.C.20006
Power of Attorney
KNOW ALL PERSONS BY THESE PRESENTS� That ULLICO CASUALTY COMPANY(the Company),a corporation organized and existing under the laws
of the State of Delaware,does hereby constitute and appoint: Linda U.Coats,Matthew J.Coats,Douglas A. Rapp,&Timothy D. Rapp of Linda D.
Coats Surety Insurance Services,Inc.
Its true and lawful Attorney(s)in fact with full authority to execute on its behalf bonds,undertakings,recognizances and other contracts of indemnity and writings
obligatory in the nature thereof,issued in the course of its business and to bind the Company thereby,in an amount not to exceed$5,000,000.00.
This Power of Attomey is granted and is signed and sealed by facsimile under and by the authority of the following Resolution adopted by the Board of'Directors
of ULLICO Casualty Company at a meeting duly called the I Sth day of 1uly,2009.
RESOLVED: That the Board of Directors hereby authorizes the President or any Vice Presiden[of
the Company to: (1) Appoint Attomey(s) in Fact and authorize the Attorney(s) in
Fact to execute on behalf of the Company bonds and undertakings, contracts of
indemnity and other wri[ings obligatory in the nature thereof and to attach the seal of
the Company thereto;and(2)to remove,at any time,any such Attomey-in-Fact and
revoke the authority given. Md,be it
FURTHER
RESOLVED: That the signatures of'such otiicers and the seal of the Company may be a�xed ro
any such Power of Attorney or certificate relAting thereto by facsimile,and nny such
Power of Attorney so executed and certified by facsimile signatures and facsimile
seal shall be valid and biding upon the Company in the future with the respect to any
bond or undertaking to which it is attached.
IN TESTlMONY WHERE�F, ULLICO CASU�TY COMPANY has caused this instrument to be signed and its corporate seal to be affixed by its
authorized o�ce this�day of�-�,y,�",�, a 20�.
``��y11111�//�/
,\ ��UBf� /��
w�O�.U'�41P�/Q��,1��
� .O r �
=�=; SFAL"';�'
, � � -
- ,.� -
� ,�y: 1`��9 .• � SioENr
� �
'�•�`����� `
,'���<«��t t���t�`` President UI.LICO Casualty Company,a Delaware Corporation.
On this 16ch day of July 2009,before me came the individual who executed the preceding instrument,to me personally known,and being by me duly
sworn said that he is the therein described and authorized oRicer of the ULUCO CASUALTY COMPANY;that the seal affixed to said instrument is the
Corporate seal of said Company;that the said Corporate Seal and his signature were duly affixed.
C�:��oia P 1'� t /�' ' ,
ry ublic
CATNERINE M.OBRIEN
NOTARY PUBLIC STAT�OF MARYLAND
MONTGOMERY COUNTY
MY COMMISSION EXPIRES JANUARY 21,2012
CERTIFICATE
I,Teresa E.Valentine,Senior Vice President,General Counsef and Secretary of ULLICO Casualty Company,do herby certify that the foregoing resolution of the
Board of Directors and this Power of Attomey issued pursuant thereto on this l6th day of July 2009 are true and correct and are still in f'ull force and effect. I do
further certify that that Daniel Aronowitz,who executed the Power of Attorney as President,was on the date of execution of the attached Power of Attomey the
duly elected President of ULLfCO Casuatry Company,
In Testimony Whereof 1 have subscribed my name and aftixed the facsimile seal of each Company this 16°i day of July 2009.
� ��y
Teresa E.Valentine
Senior Vice President,General Counsel&Secretary
ULLICO Casualty Company
,�.�..r
�• "� ""��.+V-rVU1L
PAGE 02/0g
oy �,
.
y�822 BLOOMFIELD AVE.
SANTA FE SPRINGS, CA 8p67p
(562)864,3383
FAX (562)8g4.6612
March 9�', zp�,0
City Engineer
City of Palrn pe,serr
73510 Fred Waring Dr.
Palm Desert,CA 9226U
R�:Citywide S)urry Seat Project No.C28040
To whom it may concer�:
Pursua�t to G�neral5pecifications page 25,5ection Brand or Trade Name�Substitute of Equals we ar
submi�ting a substitution of Tire Rubber Modffted 5(urry SeaI�TRMssj for bid item number 3,REAS s e
seat. IUrry
Sincererly,
�� '' C'-----
Lawrence Altan
Vice President
Roy Ailan Slurry Sea1,tnc,
• LICENSE NQ. 372798•
PAGE 03/08
P�rc ' • -
�r�`i�
E�
urls�o
12643 Em,ai �� ���,�
ens Way, Santa fe Sprin$s, C,q� 9p�70 (562)903-8989 �
( )903-8988�'ax
STANDA,� SPECLF'.ICATIONS
FOR �
T� RUBB�R 1VIODIFIED
SLURRy SEAL
REVISION 1/1/2009
PAGE 04r08
1� �E RUBBER MODIFI�D SI,iJRRY SEAL.
. 100-1 GENE,R.q,I,. T'�.�e�ub�r modified as halt sl
emulsified aspha��m�aner�.i agSz�egate, water,and retardant an,d s here.ua re erred�to�as�sl o£
�7'•
100-2 Mate�aaa.(Greenbook)203.52 1',�e xngedi�aats o�tt�e slwry shall conform to the
following:
10Q-2.� Tzxe ntbbe:��a.odiifited emtilsified asplaalt shall be cationic quick-set type CQS-Xh �'R and
co�tai,u 2%aate� by weight of thc emulsif ed asphalt,
(Grceabook)203.3.Z
1) The quick-set type shall be cat�on�c uu,less othervvise specified aad shall conform to the
requiremertts o£CQS-��,o�f 203-I.3,Test
speci�cataons when tested according to appr p at ASTM.'�8to thc following
TABLE 2Q3,S.2 (A�)—Qi1�Ci{5ET EM[1L,STON'� "
TESTS ASTM
e�t eth d �Q����S
• M a.
Furol Viscosity at 25°C(77°�), sea, p24,4
Residue from distillation, %by weight D244 �5 ��
Sievc Test(°�o retained on 850 µm [No.20]) D244 �M�•
Paztic�e Cbiarge�'est(Cabtonic) D24�t Q�4 Max.
Particle Charge Test(Anionic) D244 �'osxtive
Storage Stab��it3', 1�nay Sett�ement �4q N�B�ve
Residue I%Msx.
Pex�etrabion 0.� zx�ta D 5
Solubi�ity iu�'CE, % 45 80
Ductility,25°C(77°F7,mm D 20�42 97.5 Min.
D I 13 4��
]. Table does not app�y to�azex ox'polymer,atudi�ed emulsion.
2. T'�ie base asphalt shall c�oz�tain a mini�murn of t 0%recycled tire rubber. The fi�aishcd
aspb�alt binder composition sha�ll ba smoo#h and homogcucous. The tire zubbe�r�aaterial s,hall
be totally incorporatcd into the asphalt cement yielding a£'ibished product of singular
composition.
2) Tbe additivc�s for quick—sud slow-setting emulsion aad the a,yphalt xnodi�e�.��a type
approved hy tbe Engineer. The Amouirt of additive and asp]aalt�aodi�;6e�to be iu�cluded in the
quickset slwc�y sk�be tbe a�a,Qu�t�eccssary to e�ostue that the applied s1
vehict�lar traff c within 60 minutes after the last app�icatio�. �Y caa support
3) Watex shail be potable and compatible with the other ingredients of t,�e slw�ry.
Rcv. 1/2/2009
1
rHut e5�b�
4) The Contracto�shall provide an a8g'eBatc stockp,�e 24 hou�s prior to
5} ABP,�Bate sb�all be mck dust ox other mi�ral aggt�eg�et�s �t�te work.
shall conform ta the raq�w�ements of Section 200. The a �p�toved by the Ettgiaeer anci
conform to the follow�ing r�quirements: 88�8Ate without ao�y additive shall
TABLE 203-5.2
TESTS AST�i Te,r Method
kt wbrebacnb
Percentage Wear SQQ�2e„olutions I C �3 a
Sand�c�uivalcnt 44'�o Maximtun
C 24 2 9 SS%Ma,�,uz�
Soandness(S Cycles)'
1• ASTM C 131 to be nua on lus four C 88 15% Maa��imum
P graded materia!be�oze fi�a�crus�iag.
I00-3 Com�ition and g�ding
(Greenbool�203-3.3 The grading of the comb�cd g88�6�e a�ad tbt�
asPl�alt shatI co�t,fo�am to the requiremenis indicated i�a T�b�e 203-5.3 (A,���e of emulsified
TABLE 203-53(A)
Psrcen� e Paasin SiQvaa
Cfa�a T I T s 11 T • 11!
Sieve Size ,M�, �z M}� M�z.
3/8 in 9,5 mrn 1 pp __ M�- Maz.
No. 4 4.74 mm 140 ._,. �aQ .� �p� "'
No. 6 2.38 mm 90 �00 � 100 �p �
No. 16 1.18 mm 65 90 45 90 4$ �0
No. 30 600 m 40 �� 2� SO
� �� 50 �9 34
No. 50 300 m 25 42 �$ 36 �2 25
No. 100 1 SO m 1 S 30 �p 24, �
No. 200 5 m I O �p X g
� �s 5 �5
�te�s�idu�,A,spb�at�t% 1 Q min 7.5 min 6.5 min
of Dry Aggregat,�
Wei t
Emulsified asphait%of dry aggregate wef ght inust meet resf dua!asp}ia(t requiremeat.
�00-�4 Mx�c Deeigu
(Greenboak)203-5.� The Contractor,at its ex�cn�e, shall submit�a.
laboxatory repo�cts o�mi�x dGs�i ��ee�approva,�
utili ' the s S�P�o�od iuo acco�da,nce with ASTM D 3910 procedures,
�8 peczfic materials to be used. ASTNI D 3910 procedures shall be modified to
include the retaiz��d 4.75 nam(No. 4)a8�re8ate iuf presemt iw the mix de '
app�ove the mia praportions that art best suited for usc on the ro'ect � �����
content at�d water r�eeded to;pxoduce a sl p � , upon the emulsion
metex(SO gza,tias r �'��a���m�loss of 540 grams per square
Pe square foot)by th�e bnodifzed Wet T�rack A,br��oz�Test. For r�x designs
Rev. 1/1/2009
2
' ^u� �u� uu
containi�mo���4%agg�g�re�n�on the 4.75 ct�t(No. 4
will be 650 gr�P�'�,uare met�e�r(b0 grams )sicve, the�um loss
Per squarc fout).
The Cotth�Ctor, at its e�cpe�t,ge, shall c$librate eacht sl
a�ccording to the approved sl �Y r�nixer to be used iu the work
of work for calibration and t�� ��1� �e Coutractor shall allow,2 days prior to thc start
csti�g at a location to be�pproved by thc Engi,�eer. T,he E
will obtain fieId samples at the time of c�b�on for Extrac�io�Test(ASTM D 21�2, C��a
Tcst 382). Cot�sisteney Test,�d Wet Track Abrasiorz Test(Modi.6ed AST�D 39I0). W�en in
the judgment of tho E�agi.neer,the field samples meet the rec�uirzments sti;pulated�in thcse
Sp����O�s► tbte Eag�neer witl notify the Contractor to sta�rt the woxk.
100-5 Miaiag
(Greenbook) 302-4.2.� Ge�aerat. Mixing shatl be pc�a��,by a continuvus-flow mixez�. ,qu
agg�regate particl�s will be umiformly saturateL��d coated with asphalt.
302-4.2.Z Co�#tinuoas-�'!ow M�e�. �e slurry mixer shall be a multib�ade ox sp�ral
co,�tiz�uous-flow in good working condit�o�t cap�ble of accurately del�ivex�i�g a p�+edete��
�.►roportion�f ag�e�ate, water,emulsfon, addit{ve�d asp�ia�it mo�er to the mixer and of
discharging the thoroughly mixed�lwry on a continuous basia. Eac,h r�nixex shalt�a.ave a
metering device to measure the qu�,rity of wa�t in liters(gallons)used I ea�ch load of s�w�y aud
a separate metering devxce or equiva�lent which m�ets the appraval o�the Engineer to z�easurc
the q�tity o�'emu�sified asphalt used in eac�Xoaci o£slur.ty.
The spreadex box sha�l b�oquippod with flcxible�atedal�n cornact�tt�tb�e
shaLl be naair�tained so as to prevent loss o�slwxy. lt sb�a.tl bo adjustab�e to ensu�+e a�imiforn�d
ccmtrolled spread and be equipped with a mechanical or hydraulic type horizo.ntal shif�ing
device.
100-6 Ap�pi;icatioti
(G��mbook) 302-d.3.1 Gcneral. The work shall consist of mixing asphaltic e�mulsion,
a88�'egate, additive,at�d water a�ad spz�ea.diing the ttu�ttue on t�e pavem�t wlxere showia on the
Plans, Type I and Type II slurry shali be applied at the application rate showrl in Table 302-4.3.1
(A).
TABLE 3Q1-4.3.1 (A)
A' 'u�a�O��� AuYsa Coveted
Sluriry Scal M�a�aum Max�,aa.uw Mtubna�;�,nu
Mazimum
TYl� I 4.3 kg/rn� 5.4 k8/m' �67 ba�/EL'z' 209�on�/ELT
(Slbs/yd� (l O lbs/yd') (1 S00 fl�/ELT) (2250 ft�/EZ.T�
Type TI 6.5 kg/m2 8.1 kg/m' 112 m2/ELT 2 39 ma/ELT
(12 Ibslydz) (1S lbs/yd� (1Z00 ft�/EL'1� (1500 ftZ/EL�
Rev. 1/1/2009
3
TYPe� 8.7 kg/m� 10.8 kg/m2 93 u;�/EL,T 116 m�'/EI,T
(16�bs/yd� (20 tbs/yd� (900:ft'/�L� (1125 �/ELT�
An ELT of siurry is m�ade up pf 9p7 kg(2040 poe�nds)of dry aggreg�� ����i��
asphalt, acceleratox or�et�r p
t1�e E �,and water. Quantities and applica�io�rate shall be appr+�ved by
ztg�z�eer. When the Engineer determi,ned that tt�e application rate does not conufozxn to the
requirerr�ents,tbe Contractor shail take immediate comectivie act�on. W�en the rate is l�ss than
the manimum amaunt nqu�d, the Contractor skaa.l�l reapply additional sl
aaaz�confnrnning are�a to meet the requirements. When t�e rate�exceed the xn.axiumum speciSed
Table 302-4.3,l (A),the Engineer shouid refer to 4-1.I.
The sites�or stockpiiing and batclu�g�riais shatl be clean and fi��'irom objectianable
materials. Arrangemez�ts for these sites shall be the responsibility of the Contractor.
Han.d squeegces and ather hand equi,pxucnt sha11 be provided to remo�ve spillage and spread
s�wry in azeas iu�aaccessible to the sp�eadex bo�r,
T'�e Coz��ractox sb�l have twv fully operatio�ta,l zuaxe�s�ar use at the project site at all times.
xhese mixars shall be a�ailab�e�or i.uspectiort by the Agcncy at least 48 h�urs prior to
cammencing,woxk.
3��Z Spread[ng. Slurry shall not be appixed w�en tl�e atrnosp$ex�ic tezn
tttaa 14 C(50 F). The maxirawn speed o�'tb,e s� ��is less
muiute 270 feet �`���e s.haitl not exceed SO meters per
(. per minute).
�applicata,vz�of siwnry sha.0 nat commence until atter 7:00�.m.and thc sluny sball bc
su#ficieaYtly cured to be ope�to t�iic by 4:00 p.m. 2'he stre�t,s to be sealed sbaal be cloaed�&om
tt�e ti.tne tt�e app�icatio�begims until the B�gineer determines the mixhu�e tias aGhieved su,�cxern
set to be o�es�ed ta tra�c.
Pzio,�to applying slurty,tbte siu�ce to be sealed shail be cleaned by the Con,txactor unless
otherwise specified. Lrnm�disteiy ahesd of the mixer,th�parrement shall be prewe�tted by a
pressu�re water distrabution systezia equipped wxtb�$�og-type spraY b�r which will completely�og
the s��e of the paveme�ut. Th�necd for application and the rate of appticatioa�w�b�
dete�mined by tbe Engirxeez.
Evidence of solidification of the aaphslt,balling o�r lump�rag of the aggregates,vr the presence
of uncoated aggregate w�ill be cause for rejection of thc sturry,
Slurry shall be appued in such a r�er that no zidges sha11 remain.
The Contt�tor shall�revent slurry fi�om beirig deposi�ted on o�er tha�s��t concnete
stufaces aud sha�ramove s�ucx�y&om swrfaces z�ot desxgnated to be sea(ed at no cost to rhe
Agency. The�ethod of sltu�ry xeem�oval sk�all be appruved by the Enginecx,
�tev. ,�/1/2pp9
4
At thc direcbio�of thc Engittec,x, the Contractor s�a�$it ze
which have.aot b�en sea2�ci properly or complerely, at no cos�t��e���o��'e streets
Whex+e khe cobnpleted slurry is ttot uui�farn���o�����t
color var�iaLion at the Contractor's expense. The method of treatm�shall�� to eliminate ttxo
Engineer. appruved by the
100�7 PUBLIC CO,NVEN.IENCE ANb T�F,�C CONTRO,i,.
(Greenbook)302-4.4 At least S vy�x,��n � s
siunmit its s re S Y pric�r tcy commcncing wvrk,the Contractor sha.11
P �A,g sch�dule to the Agency�o�app�ov�, �s���e shall allow residents
an the streets to be sea�ed ample"on street"parlcir�g withi�a z�easanable distance from their
�o��s• .Based upo.n the spreading schedwe, t�,e Cont�actor shall notify residents and business of
subnutted bd����� ��to Packiz�g"signs- Itequests for chauges in the schedule sha11 be
Y the Co�qnractox to tha Enginecr for appxoval at least 48 hows prior ta the scheduled
seati,�ag of the strcets affectcd.
The Contractor slaa�X be responsible for�dequate barra
o#'bra�ic iw tbe vicit�ty of the �� ����t�te wo�area aad conirolling
Engineer. �'0.1 spec�,fied in these specifications,ar as directed by the
When nccessar�to pxovide vehicular or pcdcstrian cz�o�s�ng8 ovcr tha,�resh sturry
.�ngiwc�shall direct the Contractar to read > tb�e
eliminate tracking or damage ta the sl � su�c�ent sa�zd ox xock dwst on th�affect�d area to
Cp�,ixactOX'S e�peAge, �'• S�d or rock dust used for this purpvse shall bc at the
X00-8 NYEA►SU�2EMENT AtY�PAYML�'NT.
(Grcenbvok) 302-4.5 Slurry will be paid at tti�Contrac�t Unit Price
9ua�rtity will be determined by the w�eight of dz�Y aggrc8ate usod iva the��y. The payment
Thc contract unit price paid per extra long con sbal�include full compe�tasation�or fiunisbi�g
emulsion, acc;e]eratox or retarda�t,a�d water.
Rev, 1/1/2009
S
LOCATION OF WORK
Shadow Mountain —from Portola Avenue to Chicory Street
Chicory Street—from Portola Avenue to Quailbrush Avenue
Chicory Street—from Abronia Trail to Cul-de-Sac
Quailbrush Avenue — entire street
Parosella Street—from Lantana Avenue to Quailbrush Avenue
Parosella Street—from Abronia Trail to Cul-de-Sac
Peppergrass Street—from Lantana Avenue to Quailbrush Avenue
Peppergrass Street—from Abronia Trail to Cul-de-Sac
EI Camino — entire street
Sunset Lane — entire street
Sunrise Lane — entire street
Driftwood Drive —from Sunset Lane to Deep Canyon Road
Sagebrush Drive — entire street
Shadow Hills Road — entire street
Pepper Tree Drive - entire street
Yucca Tree Drive - entire street
Toro Peak Road - entire street
Old Prospector Trail - entire street
Borrego Drive - entire street
Wingfoot Drive - entire street
Sandpiper Court - entire street
-0E AN2A WAY � '
���......, ; DE��ANZA.Wq.y �� �'P���� � ( i c9 i
�� , , ,
P SAN j 'Z�, ��'y`.,,.... .�y O,�P i CIR ._i N Q __._Q.._�._._v�n-o,�.¢���wNo
.. ' � I aa ° w az
MARINO;L.._SAN MARINO ._O 99L�, 9t ,\9�Q$"� � _..........__.............. s s s a a o Q�a h a�
� � :� 2 � '! I � s� s� sa aa
' WAY u y �- c �`- �
� CIR_.• � � �1 fh� ; .-......_TERRAZA-DR---,-
'9 � Q a
m � � � �� 4p mu � Q��O ��'S'.RECT
� m m N � " �� a� o < ��'
� D I _..�� � a
_� ALESSANDRO DR (.- __.__.. ; ._..._..ALESSANDRO DR `z __... _...i a o
i ..�� � m 5 �
I
� PAIM DESERT DR N� _, � . � .MC�VL�Y L.I'��� --�--_ . .._. _�trrs
, .,
__ _
'..... ._.. � ......... � -.___ ........_. _ ..._..... W q a�a a� a a � "w o
PALM-DESERT DR 5 '
I - ' PA6M DESERT DR S— ; 1 — PAl/K., o� w�� z a i a° a 3 a v �
: t,.� ( tn D,�c �a >a �w w� c� °z
'' 'S/ ' ; = a a�' arc aa � a
� --ALLEY _ .��y,� I � O z`�'
��;: '�*EL�CC•'AMINO� _ �_�..__._SAN-ftEMO_.�._.' � y-
� ,....,.� I , .... �
. ., _.__ ... Q '(,(L�`" � � 0
n �
... Z ,,, O,�,P' i N w
z¢ �. �' u�G.p,B� � ¢?� veHioq_ps� ��i,��A-wqr,� '�
.� _LARREA ST g ;GARDEN /�yO'� �y�'�CZ ? sf SAGE��,BR,,.�,5� ""� � ����m��° .�_.:siEit
; � / �� G_ _� �'
�
� � SQ.� l 9 ; � ` `,4 �
�.�,
..� '' ; i9� DRIFTWOOD DR .........--- i
� \ � !
� i �'. � !
i
CANDCEWOOD ST - _.__.___CANDCEWOOD ST---- � --CANDLEWOOD ST . -....-�
C3 `�, i
CL ; � ;
CHICQRYLST ��CHICDRYlS�TiL� � �
w t 1 ��REP_PER�TREE�D'R i
W �Q J l � �
� �
qiP,AROSELL.�AF� ��P.ARQ$EL'L"A�ST�'3� �`^ j p �
F ; ,z gT � Q l� W�YUCCA�*TREE�DR �--��` _ _ _ �^_.
zt$,! .._.._.._.._.._.._._„_. �
¢ m Z � [�MONTE Q p�
z.EP.P,ERGRAS.S1 � � I� VERDE � Z Oj
'P.EP,P.ERC+RAS_SSSTii� LL,
� ST � Q ~ � WAY Y p� BORREGO DR Z
, I ; a o _
i _ i � 1 � _..._��I`Rl/V��C7R'............ •a � i
_... ' ...F`dIR1f4Ii41'DR _., t _.._... .__._.._... . o o J } N .I _.......
,� -
' i 'O -' � � i
; o ._.._.._.�.._.._..—
; � ; ; _ -•- m-••-.- °o-.._
F- . .V .
X ..,�� . ..a��
m�OLD7P.RQSP.EC�TORITRL�;��� d F V �v
m OLD7RR'OSRECT.ORITRL� ¢ �
t._CYPRESS 4 i � i U Q
�
; ESTATES v COVERED WAGON-TRL„_, ':, J i
Q __. , �.___.._.._.._.._.._..___._.._.._.._.._.._.._..�
� � _. , ,
FLN ' CT � �. ;.
, �i� ,,.�..___.�.._.._.._.._.._..�..�.._..�„�..�, ,
, ,,,
•. �...�,.�� f%
�
� -`! ..���
�- SETTING SUN SftL ,, �
�.;
�.._.._.._..___.._.._..�.._ -
i
I
i
_.....-- _�
�
�
.....� �
d �g
Q ' t�.
� � 751-10 SLURRY
� �� APPROXIMATELY 669,000 TOTAL S�UARE FEET
� � VERIFY IN FIELD
Y !
Q
,,y0�`Y�'MD TORO PEAK ROAD 44,000 PEPPERGRASS STREET 49,000 DATE:
�,5� � �, WINGFOOT DRIVE 16,000 SANDPIPER COURT 22,000
�'�" `"""""�►. YUCCA TREE DRIVE 38,000 SUNSET LANE 24,000 12�ZOO9
s�,� -�� � CHICORY STREET 73,000 OLD PROSPECTOR TRAIL 120,000
,, DRIFTWOOD DRIVE 16,000 SAGEBRUSH DRIVE 15,000
EL CAMINO 30,000 SHADOW HILLS ROAD 29,000
� QUAILBRUSH AVENUE 33,000 BORREGO DRIVE 31,000
� ' , � SUNRISE LANE 18,000 PEPPER TREE DRIVE 40,000
PAROSELLA STREET 48,000 SHADOW MOUNTAIN DRIVE 23,000
°�o�'�'°� 1 inch = 700 feet