Loading...
HomeMy WebLinkAboutC30530 Kansas Street Retention Basin Landsccape 910-10 - Joint ConsiderationContract No. C30530 CITY OF PALM DESERT/PALM DESERT REDEVELOPMENT AGENCY STAFF REPORT REQUEST: AWARD CONTRACT NO. C30530 FOR CONSTRUCTION OF THE KANSAS STREET RETENTION BASIN LANDSCAPE TO LEON'S LANDSCAPING OF THOUSAND PALMS, CALIFORNIA, IN THE AMOUNT OF $13,639.25 (PROJECT NO. 910-10) SUBMITTED BY: Mark Greenwood, P.E., Director of Public Works CONTRACTOR: Leon's Landscaping and Tree Service, Inc. P.O. Box 96 Thousand Palms, CA 92276 DATE: February 24, 2011 CONTENTS: Contract Agreement Contractor's Proposal Location Map Recommendation By Minute Motion: 1. Award Contract No. C30530 for Construction of the Kansas Street Retention Basin Landscape to Leon's Landscaping of Thousand Palms, California, in the amount of $13,639.25 (Project No. 910-10); 2. Authorize the Director of Finance to set aside a 10 percent contingency in the amount of $1,363.93; and 3. Authorize the Mayor to execute the subject agreement. Funds are available in Account Number 854-4625-454-4001, Palm Desert CC Park. No General Funds are being used for this expenditure. Committee Recommendation The landscape plan was presented to the Landscape Beautification Committee on May 19, 2010, and following a brief discussion of the size of the plant material and shape of the retention basin, the Committee unanimously approved the landscape design. Palm Desert Country Club Association was also contacted and has no objections to the proposed use of the property. Background On November 12, 2009, the City Council authorized staff to proceed with the purchase of the property at 42-135 Kansas Street, which is located on the southwest corner of Kansas Street and Hovley Lane East. This is not a desirable residential property Staff Report Award Contract C30530 to Leon's Landscaping February 24, 2010 Page 2 of 2 location due to the fact that Oasis Club Drive dead ends at the property, and there has been a history of vehicles crashing through the block wall into the back yard. The City's plan is to use the property as a retention basin to collect nuisance and stormwater runoff thereby diverting the water from nearby intersections. City crews have begun installing the stormwater retention system, and upon completion of the final grading the landscaping will be installed. A call for bids was advertised and on February 8, 2011, sealed bids were opened and read aloud. The following is a summary of the bids received: Contractor Location Bid Amount Leon's Landscaping Thousand Palms, CA $13,639.25 All Seasons Landscape San Bernardino, CA $15,129.25 Earth Sculptures, Inc. Indio, CA $19,330.00 Desert Concepts Palm Desert, CA $22,869.00 Mariposa Landscapes, Inc. Irwindale, CA $26,049.00 Candyl Golf Group La Quinta, CA $29,109.00 Robert D. Gosney Construction Hesperia, CA $39,822.50 Leon's Landscaping submitted the lowest apparent bid in the amount of $13,639.25, which is below the engineer's estimate. Leon's Landscaping has successfully completed previous projects for the City, and staff is confident that the contractor will be able to construct the landscape in accordance with the project specifications. Fiscal Analysis Beyond the initial cost of installing the landscaping, the maintenance of the landscape is estimated to cost $3,000 per year. Pre Vary" Z 4 Depa e ad: Rya Gayl roject Administrator Mark Green ood, P.E. Dir r f u lic Works J ti McCarthy, ACM R development Paul S. Gibson, Director of Finance CITY COUNCIL APPROVED ✓✓AyCTION DENIED RE[r LM,l) OTHER Jon . Wohlmuth, City Ma ' NOES: ABSENT: ABSTAIN: VERIFIED BY: Original on File with City erk's Office AGREEMENT THIS AGREEMENT is made and entered into this 24th day of February, 2011, by and between City of Palm Desert, California, hereafter called "CITY" and Leon's Landscaping and Tree Service hereinafter called "CONTRACTOR". WITNESSETH RF('.ITAI R- CONTRACTOR has submitted to CITY its Contractor's Proposal for the construction of CITY Project, 1. KANSAS STREET RETENTION BASIN LANDSCAPE, PROJECT NO. 910-10, CONTRACT NO. C30530, in strict accordance with the Contract Documents identified below, CITY has accepted said Proposal. 2. CONTRACTOR states that it has re-examined its CONTRACTOR'S Proposal and found it to be correct, has ascertained that its Subcontractors are properly licensed and possess the requisite skill and forces, has examined the site and Contract in accordance with the Contract Documents for the money set forth in its Proposal to be paid as provided in the Contract Documents. AGREEMENT: IT IS AGREED BY THE PARTIES AS FOLLOWS: 1. Contract Documents: The entire contract consists of the following: (a) The Agreement; (b) The Notice Inviting Bids; (c) The Instruction to Bidders; (d) The Contractor's Proposal; (e) The Bidder's Bond; (f) The Performance Bond; (g) The Payment Bond; (h) The General Specifications; (i) The Special Provisions; 0) The Standard Specifications as modified in other portions of the Contract Documents; (k) The Plans; (1) Addenda Nos. n/a; (m) The Determination of Prevailing Wage Rates for Public Work; (n) Any Change Orders issued; (o) Any additional or supplemental specifications, notices, instructions and drawings issued in accordance with the provisions of the Contract Documents. All of said Documents presently in existence are by this reference incorporated herein as if here set forth in full and upon the proper issuance of their documents they shall likewise be deemed incorporated. 2. Contractor shall commence the work within ten calendar days after the date of the Notice to Proceed and will do all things necessary to construct the work generally described in Recital No. 1 in accordance with the Contract Documents and will complete said work within 30 Calendar Days from the Notice to Proceed date to the satisfaction of the Engineer. 3. Contractor agrees to indemnify, defend and save CITY and its officers, agents and employees, and the Engineer harmless from: a. Any and all liability, claims, damages, losses or injuries to any person or other entity, including injury to Contractor's employees, and all claims which arise from or are connected with the negligent performance of or failure to perform the work or other obligations of this Agreement, or which are caused or which are claimed to be caused by the negligent or intentional acts or omissions of Contractor, its subcontractors, its agents or employees, and, all expenses of investigating and defending against same, b. Any and all liability, claims, damages, losses or injuries to any and all contractors, subcontractors, material -men, laborers, or any other person, firm or corporation furnishing or supplying work, services, materials or supplies in connection with the performance of the Agreement. C. Attention is directed to the General Specifications - Claims, Liability, and Indemnity Agreement/Hold Harmless sections, which specifications are made part of this Agreement as set forth in Agreement paragraph 1, above. d. Attention is directed to Section 6-9, "Liquidated Damages" of the Standard Specifications and is hereby amended to substitute the "City of Palm Desert" in place of "Agency." Liquidated damages shall be $1,000 dollars per calendar day of delay. 4. Should any litigation or arbitration be commenced between the parties concerning the works of improvements as referenced herein, the prevailing party in any such litigation, being the CITY or the Contractor, should be entitled to a reasonable sum for attorney's fees incurred in any such litigation relating to this Contract. 5. This Agreement shall be binding upon all parties hereto and their respective heirs, executors, administrators, successors, and assigns. 6. Contractor shall be paid in the manner set forth in the Contract Documents the amount of its Proposal as accepted by CITY, subject to such additions and deductions as may be made pursuant to the Contact Documents and applicable law. Satisfactory Performance: The prime Contractor agrees to pay each Subcontractor under this prime contract for satisfactory performance of its contract no later than 10 days from the receipt of each payment the prime Contractor receives from City of Palm Desert. Any delay or postponement of payment from the above referenced time frame may occur only for good cause following written approval of the City of Palm Desert. Release of Retention: The prime Contractor agrees further to release retention payments to each Subcontractor within 30 days after the Subcontractor's work is satisfactorily completed. Any delay or postponement of payment from the above referenced time frame may occur only for good cause following written approval of the City of Palm Desert. 7. Execution of the Agreement by the parties constitutes their agreement to abide by all applicable provisions of the California Labor Code; constitutes contractor's certification that he is aware of the provisions of said Code and will comply with them; and further constitutes Contractor's certification as follows: "I am aware of the provisions of Section 3700 of the California Labor Code which requires every employer to be insured against liability for worker's compensation or to undertake self insurance in accordance with the provisions of that Code, and I will comply with such provisions before commencing the performance of the work of this contract." IN WITNESS WHEREOF the parties hereto have executed or caused to be executed by their duly authorized officials, this Agreement which shall be deemed an original on the date first above written. CONTRACTOR: BY: Signature to be notarized 19194:1 CITY: BY: Signature to be notarized TITLE: Mayor of Palm Desert, CA APPROVED AS TO CONTENT: MARK GREENWOOD, P.E. DIRECTOR OF PUBLIC WORKS ATTEST BY: TITLE: ATTEST BY: TITLE: City Clerk of Palm Desert, CA APPROVED AS TO FORM: DAVID J. ERWIN CITY ATTORNEY State of California ) County of ) On before me, personally appeared who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. Signature (Seal) PERFORMANCE BOND KNOW ALL MEN BY THESE PRESENTS: That whereas the City of Palm Desert has awarded to Leon's Landscaping and Tree Service hereinafter designated as the "Principal", a contract for: KANSAS STREET RETENTION BASIN LANDSCAPE PROJECT NO. 910-10 CONTRACT NO. C30530 WHEREAS, said Principal is required under the terms of said contract to furnish a good and sufficient bond for the performance of said contract: NOW THEREFORE, WE, Leon's Landscaping and Tree Service the Principal, and as Surety, are held and firmly bound unto the City of Palm Desert hereinafter called the City, in the penal sum of Thirteen thousand six hundred thirty-nine and 25/100 Dollars ($13,639.25), being 100% of the contract amount in lawful money of the United States of America for the payment of which sum well and truly to be made, we hereby bind ourselves, our heirs, executors, administrators, and successors, jointly and severally, firmly by these presents. THE CONDITION OF THIS OBLIGATION IS SUCH that if the above bounded Principal, his executors, heirs, administrators, and successors, or assigns, shall in all things stand to and abide by, and well and truly keep and perform the covenants and agreements in the said contract and any alterations thereof made as therein provided, on his or their part, to be kept and performed at the time and in the manner therein specified, and in all respects according to their true intent and meaning, and shall indemnify and save harmless the City, its officers and agents, as therein stipulated, then this obligation shall become null and void; otherwise, it shall be and remain in full force and virtue. And the said Surety, for value received, hereby stipulates and agrees that no change, extension of time, alteration or addition to terms of the contract or to the work to be performed thereunder or the specifications accompanying the same shall in any wise affect its obligations on this bond, and it does hereby waive notice of any such change, extension of time, alterations or additions to the terms of the contract or to the work or the specifications. Should it become necessary for the City to institute a lawsuit or any other legal proceeding to enforce the terms and conditions of this bond, then all costs of said proceeding, including attorneys' fees, shall be awarded to the prevailing party. IN WITNESS WHEREOF, identical counterparts of this instrument, each of which shall for all purposes be deemed an original thereof, have been duly executed by the Principal and Surety above named, on this day of , 20 SURETY UZ INSURANCE COMPANY and/or AGENT TELEPHONE NUMBE State of California County of On before me, M personally appeared who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. Signature (Seal) PAYMENT BOND KNOW ALL MEN BY THESE PRESENTS: THAT WHEREAS, the City of Palm Desert (sometimes referred to hereinafter as "Obligee") has awarded to Leon's Landscaping and Tree Service (hereinafter designated as the "CONTRACTOR"), an agreement dated February 24, 2011 described as follows: KANSAS STREET RETENTION BASIN LANDSCAPE, PROJECT NO. 910- 10, CONTRACT NO. C30530, (hereinafter referred to as the "Contract"); and WHEREAS, said CONTRACTOR is required to furnish a bond in connection with said Contract, and pursuant to Section 3247 of the California Civil Code; NOW, THEREFORE, we, Leon's Landscaping and Tree Service the undersigned CONTRACTOR, as Principal, and a corporation organized and existing under the laws of the State of , and duly authorized to transact business under the laws of the State of California, as Surety, are held and firmly bound unto the City of Palm Desert and to any and all persons, companies or corporations entitled to file stop notices under Section 3181 of the California Civil Code, in the sum of Thirteen thousand six hundred thirty-nine and 25/100 Dollars ($13,639.25), said sum being not less than one hundred percent (100%) of the total amount payable by the said Obligee under the terms of the said Contract, for which payment well and truly to be made, we bind ourselves, our heirs, executors and administrators, successors and assigns, jointly and severally, firmly by these presents. THE CONDITION OF THIS OBLIGATION IS SUCH, that, if said CONTRACTOR, his or its heirs, executors, administrators, successors or assigns, or Subcontractors, shall fail to pay for any materials, provisions or other supplies, implements, machinery or power used in, upon, for or about the performance of the Public Work contracted to be done, or to pay any person for any work or labor of any kind, or for bestowing skills or other necessary services thereon, or for amounts due under the Unemployment Insurance Code with respect to such work or labor, or for any amounts required to be deducted, withheld, and paid over to the Employment Development Department from the wages of employees of said CONTRACTOR and his or its Subcontractors pursuant to Section 13020 of the Unemployment Insurance Code with respect to such work and labor as required by the provisions of Section 3247 through 3252 of the Civil Code, or for any amounts required to be deducted, withheld, and paid over to the Franchise Tax Board or Internal Revenue Service from the wages of employees of the CONTRACTOR or his or its Subcontractors, the Surety or Sureties hereon will pay for the same in an amount not exceeding the sum specified in this bond, otherwise the above obligation shall be void. In addition to the provisions herein above, it is agreed that this bond will inure to the benefit of any and all persons, companies and corporations entitled to serve stop notices under Section 3181 of the Civil Code, so as to give a right of action to them or their assigns in any suit brought upon this bond. The Surety, for value received, hereby stipulates and agrees that no change, extension of time, alteration or addition to the terms of the said Contract or to the work to be performed thereunder or the Specifications accompanying the same shall in any way affect its obligations on this bond, and it does hereby waive notice of any such change, extension of time, alteration or addition to the terms of the Contract or to the Specifications. No final settlement between the Obligee and the CONTRACTOR hereunder shall abridge the right of any beneficiary hereunder, whose claim may be unsatisfied. CONTRACTOR and Surety agree that if the Obligee is required to engage the services of an attorney in connection with the enforcement of the bond, each shall pay Obligee's reasonable attorney's fees incurred, with or without suit, in addition to the above sum. IN WITNESS WHEREOF, we have hereunto set our hands and seals this day of , 20 PRINCIPAL/CONTRACTOR: (Typed Name of CONTRACTOR) (Signature) (Typed Name and Title) The rate of premium on this bond is $ SURETY: (Typed Name of Surety) (Signature of Attorney -in -Fact) (Typed Name of Attorney -in -Fact) The total amount of premium charged: $ (the above must be filled in by corporate surety). per thousand. IMPORTANT: Surety companies executing bonds must possess a certificate of authority from the California Insurance Commissioner authorizing them to write surety insurance defined in Section 105 of the California Insurance Code, and if the work or project is financed, in whole or in part, with federal, grant or loan funds, it must also appear on the Treasury Department's most current list (Circular 570 as amended). THIS IS A REQUIRED FORM. Any claims under this bond may be addressed to: (Name, Address and Telephone No. of Surety) (Name, Address and Telephone No. of agent or representative for service of process in California if different from above) C - CONTRACTOR'S PROPOSAL KANSAS STREET RETENTION BASIN LANDSCAPE PROJECT NO.910-10 CONTRACT NO. C30530 TO: CITY OF PALM DESERT, "CITY" DATE: a / (3111 BIDDER: ` L, rjS ca i ►n q T �e rvyte "CONTRACTOR" The UNDERSIGNED, "CONTRACTOR", having carefully examined the site and the Contract Documents for the construction of, KANSAS STREET RETENTION BASIN LANDSCAPE, PROJECT NO. 910-10, CONTRACT NO. C30530, hereby proposes to construct the work in accordance with the Contract Documents, including Addenda No(s). for the amount stated in this Proposal. By submitting this Proposal, CONTRACTOR agrees with CITY: 1. That unless withdrawn in person by CONTRACTOR or some person authorized in writing by CONTRACTOR — not by telephone or telegram — before the time specified in the Notice Inviting Bids for the public opening of bids, this Proposal constitutes an irrevocable offer for 60 calendar days after that date. 2. The CITY has the right to reject any or all Proposals and to waive any irregularities or informalities contained in a Proposal. 3. That the contract shall be awarded only by the governing body of CITY. Said contract shall only be deemed awarded after the CONTRACTOR'S complete submission of all contract documents, bonds, insurance documentation, and the CITY shall obtain all necessary signatures of the governing body, at which time the contract shall be deemed awarded. 4. To submit to CITY such information as CITY may require to determine the Bidder's financial standing experience and to perform the work. 5. That the accompanying certified or cashier's check or Bid Bond constitutes a guarantee that if awarded the contract, CONTRACTOR will execute the Agreement and deliver the required bonds and certificates of insurance within 10 days after notice of award. If CONTRACTOR fails to execute and deliver said documents, the check or bond is to be charged with the costs of the resultant damages to CITY, including but not limited to publication costs, the difference in money between the amount bid and the amount in excess of the bid which costs CITY to do or cause to be done the work involved, lease and rental costs, additional salaries and overhead, increased interest and costs of funding the project, attorney expense, additional engineering and architectural expense and Page C-1 cost of maintaining or construction alternate facilities occasioned by the failure to execute and deliver said documents. It is understood that the quantities shown hereon, except for those quantities marked "Lump Sum", are estimates and the final payment will be based upon the actual work performed, subject to such adjustment and alterations as elsewhere provided herein. 1 Earthwork and Grading (F) SF 6,000 $ _ 10 $ ®� 2 Irrigation System LS 1 $ 3 7 5` $ 3 Install Boulders — 4'to 5' EA 9 $ i $ a 8Q oc? 4 Install Rock Cobble SF 925 $ /• ©S. $ 9-7 5 Callistemon Viminals — 5 Gal "little john" EA 10 $ / 9-5z) $ / 6 5. 0 0 6 Agave Americana — 5 Gal EA 5 $ �a ao $ 1 / 0. Oo 7 Tacoma Stans — 5 Gal EA 12 $ 00 $ -7yy 00 8 Lagerstroemia Indica — 5 Gal EA 3 $ q0 M $ / 00 , 00 9 Acacia Redolens — 5 Gal "desert carpet" Tm EA 7 $99.M $ t� 10 Washingtonia Filifera — relocate and install EA 3 $ 77 ° 0 $ o?3 2- • 60 11 Decomposed Granite (F) SF 6,000 $ $ 3�o OQ . oa 12 Plant Establishment Period LS 1 $ TOTAL BID PRICE $ ,y�--- Page C-2 The costs of any work shown or required in the Plans and Specifications, but not specifically identified as a Pay Item are included in the related Pay Item(s), and no additional compensation shall be due CONTRACTOR by virtue of CONTRACTOR'S compliance with the Plans and Specifications. TOTAL AMOUNT BASE BID IN FIGURES $Jr -- TOTAL AMOUNT BASE BID IN WORDSS�— > rx !mil r�no(f 11A 4ti n -, r,2 . o IN WITNESS WHEREOF CONTRACTOR executed this proposal of date set forth on Page C-1: Si re Title: t. rj_- e :� CONTRACTOR State of California ) County of Subscribed and sworn to (or affirmed) before me on this g day of S�rUL_ Ar (month), 20 i 1 (year), by 5 , proved to me on the basis of satisfactory evidence to be the person who appeared before me. � Signature of Notary Page C-3 (Seal of Notary) R. KA'.- ALLMANN 'n 162 MP.U8LIC8CA3 p� 1 ORNiA RIVERSIDECOu UI EXP. 1AN 14, 201a D - INFORMATION REQUIRED OF BIDDER The bidder is required to supply the following information. Additional sheets may be attached if necessary. (1) Address P- O•P120k CP- 9aa7� (2) Telephone No. _Roo) 73y 3--/ 09 (3) Type of Firm (Individual, Partnership or Corporation) 21 (4) Corporation organized under the laws of the State of (5) Contractor's License No. 010r7— 945'%aExp. Date ��I / !a• Contractor hereby swears under penalty of perjury that this information provided is true and correct. Title: � fd e_� Signfau e Contractor (6) List the names and addresses of all owners of the firm or names and titles of all officers of the corporation: S'P11Z� r1 Leci y1 foa-0 rnW,-3 o _rh,� ' -. (7) Number of years' experience as a Contractor in construction work I a- (8) List at least three similar projects completed recently: Contract Amount Class of Work Date Completed Name, Address & Telephone No. of Owner }rat ,f 1 / ian {AFL �iYA•�=' . i`tl� rrl r tb As e� 2. k.0-W �j s ruaviShed w`p-s ,G( / l-70 ®00 W-d5 o ��c��Q 7� f7�� �t+iCY► 41� a�� l 70 -- 570 3 3. :3y, c13 7 14 P-0- -l-ro �Zl 4- rp --f-tq,4 16 4— of"P�,t w, bgie-4 e .18A k)0 �j IF, (9) List the names and addresses of each Subcontractor who will perform work in or about the work improvement, and indicate what portion of the work will be done by each Subcontractor: Subcontractor's Name: License Number: Address: Telephone: Work to be performed: Subcontractor's Name: License Number: Address: Telephone: Work to be performed: Subcontractor's Name: License Number: Address: Telephone: Work to be performed: (10) List the name of the person who inspe ted the site f th proposed ork for your firm Yl (11) A financial statement or other information and references sufficiently comprehensive to permit an appraisal of your current financial condition may be required by the City. Page D-2 E — NON -COLLUSION AFFIDAVIT To be Executed by Bidder and Submitted with Bid STATE OF CALIFORNIA ) �) COUNTY OF RIJ'' ) SS 'r-'q_ ern , being first duly sworn, deposes and says that he/she is Pre 51 of the party making the foregoing bid; that the bid is not made in the interest of, or on behalf of any undisclosed person, partnership, company, association, organization, or corporation; that the bid is genuine and not collusive or sham; that the bidder has not directly or indirectly induced or solicited any other bidder to put in a false or sham bid, and has not directly or indirectly colluded, conspired, connived, or agreed with any bidder or anyone else to put in a sham bid, or that anyone shall refrain from bidding; that the bidder has not in any manner, directly or indirectly, sought by agreement, communication, or conference with anyone to fix the bid price of the bidder or any other bidder, or to fix any overhead, profit, or cost element of the bid price, or of that of any other bidder, or to secure any advantage against the pubic body awarding the contract of anyone interested in the proposed contract; that all statements contained in the bid are true; and, further, that the bidder has not, directly or indirectly, submitted his or her bid price or any breakdown thereof, or the contents thereof, or divulged information or data relative thereto, or paid, and will not pay, any fee to any corporation, partnership, company, association, organization, bid depository, or to any member or agent thereof to effectuate a collusive or sham bid. lyi re Title: �Sif CONTRACTOR State of Califomi ((�� County of ,ver c2 P2 Subscribed anj sworn to (or affirmed), before me this Q day of r�r octr _ (month), 20- I (year), by 5 e.cac11 kP—G E ., proved t me n the basis of satisfactory evidence to be the person who appeared before me. Signature of Notary. Notary Public in and for said County and State ZL(seal of notary) JEFF R. KALLMANN Page E-1 ,' COMM. # 1873162 rn Vl;` NOTARY PUBLIC-CALIFORNIA V1 RIVER31DE COUNTY I/y Colt Exv J+N 18, PG14 '' r Cv y T O O O tl/ 0 D w amD O o rn (a O rt m � O o o Fm<Q1 z O = M N a O y m M N ru w 5 O 0 m a W Q In N Ln Oru CD 7f 0 O O' 00 n V� •-• a r i r o m n O m cn A r X _ C3 —* m r ti N co m z 0 r Q = Ln W 0 O m X L O ru 03 * o Ep ~ crcil W m `Z N �O O w w i j Project No. 910-10 Kansas Street Retention Basin Landscape Project Date: 2/2011 e VICINITY MAP