Loading...
HomeMy WebLinkAboutC31850 - 2012 Civic Center Parking Lot Resurfacing 750-12Contract No. C31850 CITY OF PALM DESERT PUBLIC WORKS DEPARTMENT STAFF REPORT REQUEST: AWARD CONTRACT NO. C31850 FOR CONSTRUCTION OF THE CIVIC CENTER PARKING LOT RESURFACING PROJECT TO BEN'S ASPHALT OF SANTA ANA, CALIFORNIA, IN THE AMOUNT OF $82,270.00 (PROJECT NO. 750-12) SUBMITTED BY: Mark Greenwood, P.E., Director of Public Works CONTRACTOR: Ben's Asphalt 2200 S. Yale Street Santa Ana, California 92704 DATE: June 28, 2012 CONTENTS: Contract Agreement Performance Bond Payment Bond Contractor's Proposal Location Map Recommendation By Minute Motion: 1. Award Contract No. C31850 for Construction of the 2012 Civic Center Parking Lot Resurfacing Project to Ben's Asphalt of Santa Ana, California, in the amount of $82,270 (Project No. 750-12); 2. Authorize the Director of Finance to set aside a contingency in the amount of $7,796; and 3. Authorize the Mayor to execute the subject agreement. Funding is available for this project in General Fund Account No. 110-4313-433-3320. Background The 2012 Civic Center Parking Lot Resurfacing Project will rehabilitate the Civic Center parking lot with a 4" course of crushed aggregate base material and a 4" course of warm -mix asphalt. Staff Report Award Contract C31850 to Ben's Asphalt June 28, 2012 Page 2 of 2 A call for bids was advertised, and on May 30, 2012, sealed bids were opened and read aloud. The following is a summary of the bids received: Contractor Location Bid Amount Ben's Asphalt Santa Ana, CA $82,270 NPG, Inc. Perris, CA $91,960 Ben's Asphalt submitted the lowest responsive bid in the amount of $82,270. This bid is in keeping with cost projections currently budgeted for this project. Fiscal Analysis This is an on -going maintenance activity with no fiscal impact beyond the contract amount. Prepared By: All Paul S. Gibson, Director of Finance n M. Wohlmuth, City Manager Mark Gr Director CITY COUNCILA 'i`ION APPROVED...,. DENIED RECEIVED OTHER MEETING DATE ,.. AYES: NOES: ABSENT: ABSTAIN: VERIFIED BY:t Original on File with lerk's Office Contract No. C31850 AGREEMENT THIS AGREEMENT is made and entered into this 28 day of June, 2012, by and between City of Palm Desert, California, hereafter called "CITY" and Ben's Asphalt hereinafter called "CONTRACTOR". WITNESSETH RECITALS: CONTRACTOR has submitted to CITY its Contractor's Proposal for the construction of CITY Project, 1. CIVIC CENTER PARKING LOT RESURFACING, PROJECT NO. 750-12, CONTRACT NO. C31850, in strict accordance with the Contract Documents identified below, CITY has accepted said Proposal. 2. CONTRACTOR states that it has re-examined its CONTRACTOR'S Proposal and found it to be correct, has ascertained that its Subcontractors are properly licensed and possess the requisite skill and forces, has examined the site and Contract in accordance with the Contract Documents for the money set forth in its Proposal to be paid as provided in the Contract Documents. AGREEMENT: IT IS AGREED BY THE PARTIES AS FOLLOWS: 1. Contract Documents: The entire contract consists of the following: (a) The Agreement; (b) The Notice Inviting Bids; (c) The Instruction to Bidders; (d) The Contractor's Proposal; (e) The Bidder's Bond; (f) The Performance Bond; (g) The Payment Bond; (h) The General Specifications; (i) The Special Provisions; Q) The Standard Specifications as modified in other portions of the Contract Documents; (k) The Plans; (1) Addenda Nos. n/a; (m) The Determination of Prevailing Wage Rates for Public Work; (n) Any Change Orders issued; (o) Any additional or supplemental specifications, notices, instructions and drawings issued in accordance with the provisions of the Contract Documents. All of said Documents presently in existence are by this reference incorporated herein as if here set forth in full and upon the proper issuance of their documents they shall likewise be deemed incorporated. 2. Contractor shall commence the work within ten calendar days after the date of the Notice to Proceed and will do all things necessary to construct the work generally described in Recital No. 1 in accordance with the Contract Documents and will complete said work within 21 Calendar Days from the Notice to Proceed date to the satisfaction of the Engineer. Contract No. C31850 3. Contractor agrees to indemnify, defend and save CITY and its officers, agents and employees, and the Engineer harmless from: a. Any and all liability, claims, damages, losses or injuries to any person or other entity, including injury to Contractor's employees, and all claims which arise from or are connected with the negligent performance of or failure to perform the work or other obligations of this Agreement, or which are caused or which are claimed to be caused by the negligent or intentional acts or omissions of Contractor, its subcontractors, its agents or employees, and, all expenses of investigating and defending against same, b. Any and all liability, claims, damages, losses or injuries to any and all contractors, subcontractors, material -men, laborers, or any other person, firm or corporation furnishing or supplying work, services, materials or supplies in connection with the performance of the Agreement. C. Attention is directed to the General Specifications - Claims, Liability, and Indemnity Agreement/Hold Harmless sections, which specifications are made part of this Agreement as set forth in Agreement paragraph 1, above. d. Attention is directed to Section 6-9, "Liquidated Damages" of the Standard Specifications and is hereby amended to substitute the "City of Palm Desert" in place of "Agency." Liquidated damages shall be $1,000.00 dollars per calendar day of delay. 4. Should any litigation or arbitration be commenced between the parties concerning the works of improvements as referenced herein, the prevailing party in any such litigation, being the CITY or the Contractor, should be entitled to a reasonable sum for attorney's fees incurred in any such litigation relating to this Contract. 5. This Agreement shall be binding upon all parties hereto and their respective heirs, executors, administrators, successors, and assigns. 6. Contractor shall be paid in the manner set forth in the Contract Documents the amount of its Proposal as accepted by CITY, subject to such additions and deductions as may be made pursuant to the Contact Documents and applicable law. Satisfactory Performance: The prime Contractor agrees to pay each Subcontractor under this prime contract for satisfactory performance of its contract no later than 10 days from the receipt of each payment the prime Contractor receives from City of Palm Desert. Any delay or postponement of payment from the above referenced time frame may occur only for good cause following written approval of the City of Palm Desert. Contract No. C31850 Release of Retention: The prime Contractor agrees further to release retention payments to each Subcontractor within 30 days after the Subcontractor's work is satisfactorily completed. Any delay or postponement of payment from the above referenced time frame may occur only for good cause following written approval of the City of Palm Desert. 7. Execution of the Agreement by the parties constitutes their agreement to abide by all applicable provisions of the California Labor Code; constitutes contractor's certification that he is aware of the provisions of said Code and will comply with them; and further constitutes Contractor's certification as follows: "I am aware of the provisions of Section 3700 of the California Labor Code which requires every employer to be insured against liability for worker's compensation or to undertake self insurance in accordance with the provisions of that Code, and I will comply with such provisions before commencing the performance of the work of this contract." IN WITNESS WHEREOF the parties hereto have executed or caused to be executed by their duly authorized officials, this Agreement which shall be deemed an original on the date first above written. CONTRACTOR: Ben's Asphalt BY: Signature to be notarized TITLE: CITY: BY: Signature to be notarized TITLE: Mayor of Palm Desert, CA APPROVED AS TO CONTENT: MARK GREENWOOD, P.E. DIRECTOR OF PUBLIC WORKS ATTEST BY: TITLE: ATTEST BY: TITLE: City Clerk of Palm Desert, CA APPROVED AS TO FORM: DAVID J. ERWIN CITY ATTORNEY CONTRACTOR ACKNOWLEDGMENT State of California ) SS. County of On , 20 , before me, , a Notary Public, personally appeared , who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. Signature State of California County of Riverside CITY ACKNOWLEDGMENT ) SS. (seal) On , 20 , before me, , a Notary Public, personally appeared , who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal Signature (seal) PERFORMANCE BOND KNOW ALL MEN BY THESE PRESENTS: That whereas the City of Palm Desert has awarded to Ben's Asphalt hereinafter designated as the "Principal", a contract for: CIVIC CENTER PARKING LOT RESURFACING PROJECT NO. 750-12 CONTRACT NO. C31850 WHEREAS, said Principal is required under the terms of said contract to furnish a good and sufficient bond for the performance of said contract: NOW THEREFORE, WE, the Principal, and as Surety, are held and firmly bound unto the City of Palm Desert hereinafter called the City, in the penal sum of Eighty -Two Thousand, Two Hundred and Seventy and no/00 Dollars ($82,270.00), being 100% of the contract amount in lawful money of the United States of America for the payment of which sum well and truly to be made, we hereby bind ourselves, our heirs, executors, administrators, and successors, jointly and severally, firmly by these presents. THE CONDITION OF THIS OBLIGATION IS SUCH that if the above bounded Principal, his executors, heirs, administrators, and successors, or assigns, shall in all things stand to and abide by, and well and truly keep and perform the covenants and agreements in the said contract and any alterations thereof made as therein provided, on his or their part, to be kept and performed at the time and in the manner therein specified, and in all respects according to their true intent and meaning, and shall indemnify and save harmless the City, its officers and agents, as therein stipulated, then this obligation shall become null and void; otherwise, it shall be and remain in full force and virtue. And the said Surety, for value received, hereby stipulates and agrees that no change, extension of time, alteration or addition to terms of the contract or to the work to be performed thereunder or the specifications accompanying the same shall in any wise affect its obligations on this bond, and it does hereby waive notice of any such change, extension of time, alterations or additions to the terms of the contract or to the work or the specifications. Should it become necessary for the City to institute a lawsuit or any other legal proceeding to enforce the terms and conditions of this bond, then all costs of said proceeding, including attorneys' fees, shall be awarded to the prevailing party. IN WITNESS WHEREOF, identical counterparts of this instrument, each of which shall for all purposes be deemed an original thereof, have been duly executed by the Principal and Surety above named, on this day of , 20 SURETY INSURANCE COMPANY and/or AGENT ADDRESS TELEPHONE NUMBER State of California County of On before me, PRINCIPAL personally appeared who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. Signature (Seal) PAYMENT BOND KNOW ALL MEN BY THESE PRESENTS: THAT WHEREAS, the City of Palm Desert (sometimes referred to hereinafter as "Obligee") has awarded to Ben's Asphalt (hereinafter designated as the 'CONTRACTOR"), an agreement dated June 28, 2012 described as follows: CIVIC CENTER PARKING LOT RESURFACING, PROJECT NO. 750-12, CONTRACT NO. C31850, (hereinafter referred to as the "Contract"); and WHEREAS, said CONTRACTOR is required to furnish a bond in connection with said Contract, and pursuant to Section 3247 of the California Civil Code; NOW, THEREFORE, we, the undersigned CONTRACTOR, as Principal, and a corporation organized and existing under the laws of the State of and duly authorized to transact business under the laws of the State of California, as Surety, are held and firmly bound unto the City of Palm Desert and to any and all persons, companies or corporations entitled to file stop notices under Section 3181 of the California Civil Code, in the sum of Eighty -Two Thousand, Two Hundred and Seventy and no/00 Dollars ($82,270.00), said sum being not less than one hundred percent (100%) of the total amount payable by the said Obligee under the terms of the said Contract, for which payment well and truly to be made, we bind ourselves, our heirs, executors and administrators, successors and assigns, jointly and severally, firmly by these presents. THE CONDITION OF THIS OBLIGATION IS SUCH, that, if said CONTRACTOR, his or its heirs, executors, administrators, successors or assigns, or Subcontractors, shall fail to pay for any materials, provisions or other supplies, implements, machinery or power used in, upon, for or about the performance of the Public Work contracted to be done, or to pay any person for any work or labor of any kind, or for bestowing skills or other necessary services thereon, or for amounts due under the Unemployment Insurance Code with respect to such work or labor, or for any amounts required to be deducted, withheld, and paid over to the Employment Development Department from the wages of employees of said CONTRACTOR and his or its Subcontractors pursuant to Section 13020 of the Unemployment Insurance Code with respect to such work and labor as required by the provisions of Section 3247 through 3252 of the Civil Code, or for any amounts required to be deducted, withheld, and paid over to the Franchise Tax Board or Internal Revenue Service from the wages of employees of the CONTRACTOR or his or its Subcontractors, the Surety or Sureties hereon will pay for the same in an amount not exceeding the sum specified in this bond, otherwise the above obligation shall be void. In addition to the provisions herein above, it is agreed that this bond will inure to the benefit of any and all persons, companies and corporations entitled to serve stop notices under Section 3181 of the Civil Code, so as to give a right of action to them or their assigns in any suit brought upon this bond. The Surety, for value received, hereby stipulates and agrees that no change, extension of time, alteration or addition to the terms of the said Contract or to the work to be performed thereunder or the Specifications accompanying the same shall in any way affect its obligations on this bond, and it does hereby waive notice of any such change, extension of time, alteration or addition to the terms of the Contract or to the Specifications. No final settlement between the Obligee and the CONTRACTOR hereunder shall abridge the right of any beneficiary hereunder, whose claim may be unsatisfied. CONTRACTOR and Surety agree that if the Obligee is required to engage the services of an attorney in connection with the enforcement of the bond, each shall pay Obligee's reasonable attorney's fees incurred, with or without suit, in addition to the above sum. IN WITNESS WHEREOF, we have hereunto set our hands and seals this day of , 20 PRINCIPAL/CONTRACTOR: Ben's Asphalt By: (Signature) (Typed Name and Title) The rate of premium on this bond is $ SURETY: (Typed Name of Surety) (Signature of Attorney -in -Fact) (Typed Name of Attorney -in -Fact) The total amount of premium charged: $ (the above must be filled in by corporate surety). per thousand. IMPORTANT: Surety companies executing bonds must possess a certificate of authority from the California Insurance Commissioner authorizing them to write surety insurance defined in Section 105 of the California Insurance Code, and if the work or project is financed, in whole or in part, with federal, grant or loan funds, it must also appear on the Treasury Department's most current list (Circular 570 as amended). THIS IS A REQUIRED FORM. Any claims under this bond may be addressed to: (Name, Address and Telephone No. of Surety) (Name, Address and Telephone No. of agent or representative for service of process in California if different from above) Acknowledgment State of California ) County of ) On before me, personally appeared who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. Signature (Seal) C - CONTRACTOR'S PROPOSAL CIVIC CENTER PARKING LOT RESURFACING PROJECT NO.750-12 CONTRACT NO. C31850 TO: CITY OF PALM DESERT, "CITY" DATE: --a L BIDDER: ✓-- , ,,.Q�c� .:�- . "CONTRACTOR" The UNDERSIGNED, "CONTRACTOR having carefully examined the site and the Contract Documents for the construction of, CIVIC CENTER PARKING LOT RESURFACING, PROJECT NO. 750-12, CONTRACT NO. C31850, hereby proposes to construct the work in accordance with the Contract Documents, including Addenda No(s). P -A, for the amount stated in this Proposal. By submitting this Proposal, CONTRACTOR agrees with CITY: That unless withdrawn in person by CONTRACTOR or some person authorized in writing by CONTRACTOR — not by telephone or telegram — before the time specified in the Notice Inviting Bids for the public opening of bids, this Proposal constitutes an irrevocable offer for 60 calendar days after that date. 2. The CITY has the right to reject any or all Proposals and to waive any irregularities or informalities contained in a Proposal. 3. That the contract shall be awarded only by the governing body of CITY. Said contract shall only be deemed awarded after the CONTRACTOR'S complete submission of all contract documents, bonds, insurance documentation, and the CITY shall obtain all necessary signatures of the governing body, at which time the contract shall be deemed awarded. 4. To submit to CITY such information as CITY may require to determine the tBidder's financial standing experience and to perform the work. 5. That the accompanying certified or cashier's check or Bid Bond constitutes a guarantee that if awarded the contract, CONTRACTOR will execute the Agreement and deliver the required bonds and certificates of insurance within 10 days after notice of award. If CONTRACTOR fails to execute and deliver said documents, the check or bond is to be charged with the costs of the resultant damages to CITY, including but not limited to publication costs, the difference in money between the amount bid and the amount in excess of the bid which costs CITY to do or cause to be done the work involved, lease and rental costs, additional salaries and overhead, increased interest and costs of funding the a project, attorney expense, additional engineering and architectural expense and Page C-1 cost of maintaining or construction alternate facilities occasioned by the failure to execute and deliver said documents. It is understood that the quantities shown hereon, except for those quantities marked "Lump Sum", are estimates and the final payment will be based upon the actual work performed, subject to such adjustment and alterations as elsewhere provided herein. Page C-2 The costs of any work shown or required in the Plans and Specifications, but not specifically identified as a Pay Item are included in the related Pay Item(s), and no additional compensation shall be due CONTRACTOR by virtue of CONTRACTOR'S compliance with the Plans and Specifications. TOTAL AMOUNT BASE BID IN FIGURES $ TOTAL/AMOUNT BASE BID IN WORDS IN WITNESS WHEREOF CONTRACTOR executed this proposal as of date set forth on Page C-1: %, State of California j County of ) Subscribed and sworn to (or affirmed) before me on this day of (month), (year), by proved to me on the basis of satisfactory evidence to be the person(s) who appeared before me. Signature of Notary Page C-3 (Seal of Notary) II • -- a c>!.. � a a 'Nt.S�t-l:S�...' s�S/.vf3.A �'1 v State of California ss. County of ' V CA -11 Nk 0,L-DIL On Date personally appeared before me, J i,IV) TERI BRAOM Commission # 1924994 Notary Public - California Orange County • Comm. E ires Feb 10, 2015 t e r i Y t e #j H o +6ir� Name and Title of Officer (e.:g„ "Janb Doe, Notary Public') I *personally known to me 0 proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. WITNESSand official seal. Place Notary Seal Above signature of Notary Public OPTIONAL Though the information below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent removal and reattachment of this form to another document. Description of Attached Document Title or Type of Document: Document Date: Signer(s) Other Than Named Above: Capacity(ies) Claimed by Signer(s) Signer's Name: El Individual 7 Corporate Officer — Ttle(s): _ El Partner — O Limited E7 General [] Attorney in Fact ❑ Trustee ED Guardian or Conservator © Other: Signer Is Representing: RIGHT THUMBPRINT OF°SIGNER Top of thumb her Number of Pages: Signer's Name: O Individual ❑ Corporate Officer — Title(s): _ ❑ Partner — ❑ Limited ❑ General ❑ Attorney in Fact ❑ Trustee O Guardian or Conservator O Other: Signer Is Representing: RIGHT THUMBPRINT OF SIGNER I 0 2004 National Notary Association • 9350 De Soto Ave., P.O. Box 2402 - Chatsworth, CA 91313�2402 Item No. 5907 Reorder. Call ToW Free 1-800-876-6827 N _ N a � Com m 0 C c 0 U K 0 co� 7 � p d U cn 6 a N ■